Thursday, March 28, 2024
48.0°F

Legals for May, 17 2023

| May 17, 2023 12:00 AM

2023 MRSC ROSTERS SMALL PUBLIC WORKS, CONSULTANT, and VENDOR ROSTERS FOR PARTICIPATING WASHINGTON STATE LOCAL GOVERNMENT AGENCIES LOCATED IN EASTERN WASHINGTON The Municipal Research and Services Center of Washington (MRSC) hereby advertises on behalf of the below listed local government agencies in Washington State (local governments) in Eastern Washington (Okanogan, Chelan, Douglas, Grant, Adams, Whitman, Garfield, Asotin, Spokane, Lincoln, Ferry Stevens, and Pend Oreille counties), including - but not limited to - cities (Title 35 RCW and Title 35A RCW), counties (Title 36 RCW), port districts (Title 53 RCW), water-sewer districts (Title 57 RCW), irrigation districts (Title 83 RCW), school districts and educational service districts (Title 28A RCW), fire districts (Title 52 RCW), transit agencies (e.g., Ch. 35.58 RCW, Ch. 36.57A RCW, Ch. 36.73 RCW, Title 81 RCW), and public utility districts (Title 54 RCW), for their projected needs for small public works, and for consulting services throughout 2023. Additionally, MRSC advertises on behalf of some local government for their projected needs for vendor services throughout 2023. Interested businesses may apply at any time by visiting the MRSC Rosters website at www.mrscrosters.org. For questions about MRSC Rosters, email mrscrosters@mrsc.org. Some or all of the listed local governments may choose to use the MRSC Rosters service to select businesses. Master contracts for certain types of work may be required. SMALL PUBLIC WORKS ROSTERS: Service categories include construction, building, renovation, remodeling, alteration, repair, or improvement of real property as referenced in RCW 39.04.155. Sub-categories can be viewed on the MRSC Rosters website.  CONSULTANT ROSTERS: Service categories include architectural, engineering, and surveying services as referenced in Chapter 39.80 RCW, as well as other personal and professional consulting services. Sub-categories can be viewed on the MRSC Rosters website. VENDOR ROSTERS: Service categories include supplies, materials, and equipment not being purchased in connection with public works contracts and limited service contracts as referenced in RCW 39.04.190. Subcategories can be viewed on the MRSC Rosters website. A list of currently subscribing local governments that have their Small Works Roster, Consultant Roster, and Vendor Roster hosted by MRSC Rosters can be found at https://www.mrscrosters.org/participating-agencies or by contacting the MRSC Rosters Program Coordinator at 206-625-1300 ext. 14. New local government agencies may join at any time. The list reflects current active agencies.  #06001/8907 Pub: June 1, 2023

SUMMARY OF ORDINANCE #835 THE CITY COUNCIL OF THE CITY OF WARDEN HAS ADOPTED AN ORDINANCE AMENDING WARDEN MUNICIPAL CODE CHAPTER 8.09 ENTITLED GARBAGE SERVICE CHARGES, “APPENDIX G”, Rates Effective July 1, 2023. Passed by the City Council of the City of Warden, Washington, this 9th day of May, 2023. Any person may obtain the full text of this ordinance by mail without charge upon request. #06003/9146 Pub: May 19, 2023 and June 1, 2023

NOTICE OF STATE ENVIRONMENTAL POLICY ACT (SEPA) DETERMINATION OF NON-SIGNIFICANCE The City of Royal City has issued a Determination of Non-Significance (DNS) under the SEPA rules (Washington Administrative Code Chapter 197-11) for the completion of the City’s Wastewater Facilities Plan (WWFP). The WWFP identifies potential improvements to the existing wastewater treatment facility that are necessary to meet projected sanitary sewer treatment needs over the next 20 years. In addition to completing the non-ground-disturbing planning document (WWFP), the City intends to install two groundwater monitoring wells. The proposed monitoring wells would be installed within city limits at the City’s existing wastewater treatment facility located in Section 6 of Township 16 North, Range 26 East. After reviewing the completed SEPA Checklist and additional supporting information filed with the Washington State Department of Ecology, the City has determined that this proposal will not have a probable significant adverse impact on the environment. The DNS and SEPA documents are available for public review at City Hall, 445 Camelia Street N.E., Royal City, Washington, 99357, Monday through Friday from 8:00 a.m. to 5:00 p.m. The public is invited to comment on this DNS by submitting written comments no later than June 9, 2023, to the attention of Shilo Christensen, Finance Director, at the above address above #06005/9368 Pub: May 25, 2023 & June 1, 2023

WASHINGTON STATE SUPERIOR COURT  COUNTY OF GRANT United States Department of Agriculture | (USDA), | No.  | Plaintiff, | SUMMONS (60 days) v. | | Eddie L. Rayoum, an individual and martial | community; Alice F. Rayoum, an individual | and martial community; and John and Jane | Does I through X; occupants of the subject | real property; and all other persons or parties | unknown claiming any right, title, interest, | lien or Estate in the property herein describe. |  | Defendants. | ____________________________________ | TO THE DEFENDANTS: A lawsuit has been started against you in the above entitled court by United States Department of Agriculture (“USDA”), hereinafter “Plaintiff”. Plaintiff’s claim is stated in the written complaint, a copy of which is available upon request and is on file with the court.  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after 28th day of March, 2023 and defend the above entitled action in the above entitled court, and answer the complaint of the plaintiff, and serve a copy of your answer upon the undersigned attorneys for plaintiff at their office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. The purpose of this suit is to foreclosure on your interest in the following described property:  The North 36 feet of Lot 19 and the South 27 feet of Lot 20, Block 11, Ephrata Heights First Addition to Ephrata, according to the plat thereof recorded in Volume 3 of Plats, page 4, records of Grant County, Washington. Which is located at:  140 H St. SE, Ephrata, WA 98823. In order to defend against this lawsuit, you must respond to the complaint by stating your defense in writing, and by serving a copy upon the person signing the summons within 60 days after the service of this summons, excluding the day of service, or a default judgment may be entered against you without notice. A default judgment is one where plaintiff is entitled to what he or she asks for because you have not responded. If you serve a notice of appearance on the undersigned person, you are entitled to notice before a default judgment may be entered. IMPORTANT NOTICE If judgment is taken against you, either by default or after hearing by the court, your property will be sold at public auction. You may prevent the sale by paying the amount of the judgment at any time prior to the sale. If your property is sold, you may have the right to redeem the property during the redemption period if applicable, by paying the amount for which the property was sold, plus interest and costs of the sale. If you wish to seek the advice of an attorney in this matter, you should do so promptly so that your written response, if any, may be served on time.  This summons is issued pursuant to rule 4 of the Superior Court Civil Rules of the State of Washington and RCW 4.28.100(7). Dated this 7th day of March, 2023. WONG FLEMING /s/ Wong Fleming_____________ Vanessa Moore, WSBA #52668 Attorney for Plaintiff #05001/6441 Pub: March 28, 2023, April 4, 11, 18, 25, 2023 & May 2, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 09, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider a petition to amend Section 6.08.650 “Special regulations to specific lakes in Grant County” of the Grant County Code, adding Warden Lake. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2483 386 7206) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05004/7607 Pub: April 23, 2023 & May 2, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:30 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Pelican Point Park and Recreation District # 2 of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by the password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05005/7609 Pub: May 2, 9, 16, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Airport Parks and Recreation District #1 Of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05006/7610 Pub: May 2, 9, 16, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD May 09, 2023 at  3:30p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to declare surplus Public Works county-owned property and order the sale thereof via public auction at www.publicsurplus.com to the highest bidder. If you would like to receive the list of miscellaneous surplus items, please contact the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2483 386 7206) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz Deputy Clerk of the Board Grant County Commissioners #05007/7616 Pub: April 25, 2023 & May 2, 2023

Advertisement For Bids Belsaas & Smith Construction, Inc. invites separate sealed Bids for: Bid Package 1 – HVAC Bid Package 2 – Fire Suppression Bid Package 3 – Electrical/Communication/Security Bid Package 4 – Plumbing (remaining bid packages to follow at a later date) For the construction of the: Columbia Basin Hospital ED Modernization 200 Nat Washington Way Ephrata, WA 98823 PROJECT DESCRIPTION: This project includes a remodel and addition to expand the emergency department and support spaces at Columbia Basin Hospital. The existing ED is to receive an addition to the south, followed by the remodel of existing interior spaces. The project is being delivered via Washington State’s GC/CM Program for Public District Hospitals and is subject to RCW 39.10, all applicable codes and standards including prevailing wage and project close-out requirements. Project phasing will be required to maintain patient services during construction.   Sealed bids must be received by Cheryl Bodi, Columbia Basin Hospital at 200 Nat Washington Way Ephrata, WA no later than Thursday, May 11th, 2023 at 1pm. Bids will be publicly opened immediately thereafter. All Bids shall remain valid for a period of 60 calendar days. A mandatory pre-bid walkthrough, for Bid Packages 1-4 only, will be held on Thursday, May 4th at 1pm. At Columbia Basin Hospital’s main entrance. Additional bid packages will be announced at a later date. Direct questions to Jodi Polak, Project Manager, Belsaas & Smith Construction,  jodip@belsmith.com, 509-925-9747. Bid Documents are available for free download to licensed contractors by contacting John McLean, Principal Architect: john@brdstudio.com.   A bid bond payable to Belsaas & Smith Construction, Inc. in the amount of 5% of the base bid amount shall accompany base bids exceeding $300,000.  All bids and qualifications will be received and evaluated. Grant County Public Hospital Dist. No. 3, Owner and Belsaas & Smith Construction, Inc., General Contractor/Construction Manager may reject any bid at its discretion and waive technicalities or irregularities. Belsaas & Smith Construction, Inc. may request clarification or confirmation of information submitted, and additional information from bidders to determine the ability of the Bidder to perform the work. After careful consideration of all bids and factors, the award will be offered to the bidder that best serves the interest of the Project Owner.  Belsaas & Smith Construction, Inc., General Contractor/Construction Manager intends to bid on Bid Package 10 – Demolition/Concrete/Carpentry/Metal and Wood Doors/Specialties/Landscape. #04050/8181 Pub: April 27, 2023 & May 2, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR THE COUNTY OF GRANT BANK UNITED N.A. , | | CASE NO.: 21-2-00818-13 Plaintiff, | JUDGMENT NO.: | vs. | SHERIFF’S NOTICE TO JUDGMENT | DEBTOR OF SALE OF REAL UNKNOWN HEIRS AND DEVISEES OF | PROPERTY DENNIS C. JOHNSON, DECEASED; | PATRICIA DIETZMAN, FORMER | PERSONAL REPRESENTATIVE FOR THE | ESTATE OF DENNIS CHARLES JOHNSON; | UNKNOWN SUCCESSOR PERSONAL | REPRESENTATIVE FOR THE ESTATE OF | DENNIS CHARLES JOHNSON; AQUA | FINANCE, INC.; DESERT AIRE OWNERS | ASSOCIATION; JOHN AND/OR JANE DOE, | UNKNOWN OCCUPANTS/CO-HABITANTS | OF THE SUBJECT PREMISES , | | Defendants | | _____________________________________ | Patricia Dietzman, former Personal Representative Unknown Heirs and Devisees of for the Estate of Dennis Charles Johnson Dennis C. Johnson, deceased 503 Desert Aire Drive SW 503 Desert Aire Drive SW Mattawa, WA 99349 Mattawa, WA 99349 Unknown Successor Peronal Representative Aqua Finance, Inc. for the Estate of Dennis Charles Johnson R/A: Corporation Service Company 503 Desert Aire Drive SW 300 Deschutes Way SW, Suite 208. MC-CSC1 Mattawa, WA 99349 Tumwater, WA 98501 John and/or Jane Doe, Unknown Occupants Desert Aire Owners Association Co-Habitants of the Subject Premises c/o Michael M Wyman 503 Desert Aire Drive SW 2219 W. Broadway Ave. Suite A Mattawa, WA 99349 Moses Lake, WA 98837 The Superior Court of Grant County has directed the undersigned Sheriff of Grant County to sell the property described below to satisfy a judgment in the above entitled action. The property to be sold is described as follows: LOT 14, DESERT AIRE NO. 8, PHASE II, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 13 OF PLATS, PAGES 71, 72 AND 73, RECORDS OF GRANT COUNTY, WASHINGTON APN TAX PARCEL NO.: 021687014 Commonly known as: 503 Desert Aire Drive SW, Mattawa, WA 99349 The sale of the described property is to take place at 10:30 am on the 19 th day of May 2023 at the main lobby of the Grant County Courthouse, Ephrata, Washington. The judgment debtor can avoid the sale by paying the judgment amount of $ 319,691.78 plus interest, costs and fees before the sale date. For the exact amount, contact the attorney at the address stated below. This property is subject to: A redemption period of 8 (Eight) months, which will expire at 4:30 pm on the 19 th day of January 2024. The judgment debtor or debtors or any of them may redeem the above described property at any time up to the end of the redemption period by paying the amount bid at the Sheriff’s sale plus additional costs, taxes, assessment, certain other amounts, fees and interest. If you are interested in redeeming the property, contact the attorney at the address stated below to determine the exact amount necessary to redeem. IMPORTANT NOTICE: If the judgment debtor or debtors do not redeem the property by 4:30 pm on the 19 th day of January 2024 , the end of the redemption period, the purchaser at the Sheriff’s sale will become the owner and may evict the occupant from the property unless the occupant is a tenant holding under an unexpired lease. If the property to be sold is occupied as a principal residence by the judgment debtor or debtors at the time of sale, he, she, they or any of them may have the right to retain possession during the redemption period, if any, without payment of any rent or occupancy fee. The judgment debtor may also have a right to retain possession during any redemption period if the property is used for farming or if the property is being sold under a mortgage that so provides. Dated this 15 th day of March 2023 , at Ephrata, WA 98823. JOSEPH M. KRIETE, Sheriff By: Sheena Ohl, Civil Specialist cc: Janeway Law Firm, LLC Attn: James A. Craft 1499 SE Tech Center Place, Suite 255 Vancouver, WA 98683 Phone: (360) 260-2253 Fax: (360) 260-2285 ksutherland@logs.com #05002/6703 Pub: March 30, 2023, April 6, 13, 20, 27, 2023 & May 4, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR THE COUNTY OF GRANT BANK UNITED N.A., | | CASE NO.: 21-2-00818-13 | JUDGMENT NO.: Plaintiff, | | SHERIFF’S PUBLIC NOTICE OF | SALE OF REAL PROPERTY vs. | | UNKNOWN HEIRS AND DEVISEES OF | DENNIS C. JOHNSON, DECEASED; | *** EIGHT MONTH PATRICIA DIETZMAN, FORMER | REDEMPTION*** PERSONAL REPRESENTATIVE FOR THE | ESTATE OF DENNIS CHARLES JOHNSON; | UNKNOWN SUCCESSOR PERSONAL | REPRESENTATIVE FOR THE ESTATE OF | DENNIS CHARLES JOHNSON; AQUA | FINANCE, INC.; DESERT AIRE OWNERS | ASSOCIATION; JOHN AND/OR JANE DOE, | UNKNOWN OCCUPANTS/CO-HABITANTS | OF THE SUBJECT PREMISES, | | Defendants | __________________________________________ | The Superior Court of Grant County has directed the undersigned Sheriff of Grant County to sell the property described to satisfy a judgment in the above entitled action: LOT 14, DESERT AIRE NO. 8, PHASE II, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 13 OF PLATS, PAGES 71, 72 AND 73, RECORDS OF GRANT COUNTY, WASHINGTON APN TAX PARCEL NO.: 021687014 Commonly known as: 503 Desert Aire Drive SW, Mattawa, WA 99349 The sale of the described property is to take place at 10:30 am on the 19th day of May 2023 at the main lobby of the Grant County Courthouse, Ephrata, Washington. The judgment debtor can avoid the sale by paying the judgment amount of $319,691.78 plus interest, costs and fees before the sale date. For the exact amount, contact the attorney at the address stated below. Dated this 15th day of March 2023 at Ephrata, WA 98823. JOSEPH M. KRIETE, Sheriff By: Sheena Ohl, Civil Specialist cc: Janeway Law Firm, LLC Attn: James A. Craft 1499 SE Tech Center Place, Suite 255 Vancouver, WA 98683 Phone: (360) 260-2253 Fax: (360) 260-2285 ksutherland@logs.com #04003/6709 Pub: March 30, 2023 & April 6, 13, 20, 2023

Grant County Mosquito Control District, No. 1 hereby gives public notice of the need for materials and work for construction that conforms to all applicable public works requirements including the requirement to pay prevailing wages. As allowed by code, the District hereby invites tenders of a construction bid to be based upon drawings and specifications that meet the requirements contained in the Contract Documents prepared by the District. Sealed bids will be received by the Grant County Mosquito Control District for a fixed stipulated lump sum General Contract for the construction of: GRANT COUNTY MOSQUITO CONTROL DISTRICT No. 1 FLIGHT OPERATIONS FACILITY MOSES LAKE, WASHINGTON This project will cover approx. 2 acres and will include a new 4,500 SF Hangar, a 130 SF Toilet Building, a Fuel ‘Island’, and related site work. The Hangar will be a pre-engineered metal building clad with insulated metal panels. The Pilot Toilet will be constructed with CMU. The Architect’s estimate for this project is $2,040,500. Grant County Mosquito Control District will receive sealed bids from qualified contractors ONLY until 2:00 p.m., April 20, 2023 at the District Office, 11905 Road 4, Lot #16, Moses Lake, Washington 98837. Bids received after 2:00 p.m. will not be accepted. Bids will be opened and publicly read aloud immediately after the specified closing time. Bidders and other interested parties are invited to be present at the opening.  Bid must be to perform work for a fixed stipulated lump sum that excludes Washington State Sales Tax. All bids must be accompanied by a bid bond in an amount not less than 5% of the total bid made payable to Grant County Mosquito Control District, No. 1. Questions are to be directed to the Architect of Record: Monson Architects, Inc. Attn: Ryan H. Monson (509) 952-5633 ryanm@monsonarchitects.com Bid documents may be examined at the following plan centers: Yakima Plan Center Yakima Tri-City Construction Council Kennewick Abadan Plan Center Spokane Spokane Regional Plan Center Spokane Builders Exchange of Washington Everett McGraw-Hill Construction / Dodge Plan Center Seattle Idaho AGC Northwest Plan Room Boise Bona fide licensed bidders may obtain project documents at “Monson Architects Plan Room”, www.monsonplanroom.com . Bidders may download digital documents at no cost. Hard copy sets to be used for bidding or construction may be purchased at Bidder’s /Contractor’s expense from the architect’s plan room by choosing the “Order” option or downloaded digital files may be forwarded to a printer of Bidder’s / Contractor’s choice. All Bidders are required to register as a plan holder on this plan room.  Any questions regarding this plan room, shall be directed to plan room administrator at (509) 747-2964 or planroom@abadanplancenter.com.  PRE-BID MEETING There will be a pre-bid meeting and site visitation on April 12, 2023 at 1:00 p.m. at the Project Site located at 8804 Turner Road NE, Moses Lake, Washington 98937. The meetings will include a question / answer period followed by a tour of the site. All General Contractors and subcontractors are highly encouraged to attend the pre-bid meetings.  The District will publicly announce the apparent low bidder during the bid opening; however, Grant County Mosquito Control District reserves the right to reject any or all bids, to waive any irregularity or to accept any bid deemed in the best interest of the District. Upon a thorough review of the bidder’s documents, the District will promptly award the contract to the responsible bidder with the lowest responsive bid.   The District retains the right to hold the bid bond of the lowest apparent bidder and the next two lowest bidders for (60) days after the bid opening, or until a contract has been executed, whichever is the lesser amount of time. All other bid bonds will be returned as soon as feasible after the bid opening. By order of the Board of Trustees, Grant County Mosquito Control District, No. 1 First Publication: March 30, 2023 Second Publicartion: April 6, 2023 #04012/7143 Pub: March 30, 31 2023 & April 6, 2022

Date: Wednesday, April 12, 2023    Address: 408 Intermodal Way Quincy, WA 98848      Time: 11:00 AM Local Time By virtue of default by We The People Trucking, L.L.C.  ( Individually and collectively “Client”), under a Negotiable Promissory Note and Security Agreement(s), Security Agreement(s) Promissory Note(s), Lease Agreement(s) and related documents dated February 23, 2021, payable to Commercial Credit Group Inc. (“CCG”), which obligation is secured by the property described below (the “Equipment”), CCG will sell at Public Auction, to the highest bidder, AS-IS, WHERE-IS, WITHOUT ANY REPRESENTATIONS OR WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR ANY WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE, all of its right, title and interest to the following Equipment: (1) 2015 Utility Reefer Trailer SN: 1UYVS2535FU280502 Terms: Successful bidder must pay 25% of purchase price at time of sale via cash, certified or acceptable bank check, with the balance payable in good funds on the next business day, unless: 1. The bidder has pre-qualified by presenting CCG with a written non-contingent, lending commitment from a source and in a form acceptable to CCG in its sole discretion, in which case we will entertain bids up to the amount of such written commitment; or 2. The bidder has obtained from CCG written credit approval in advance of the scheduled public sale. CCG reserves the right to bid at the sale. Contact Herb Orengo at (630) 718-4684 for additional information or to arrange an inspection of the Equipment. #04032/7376 Pub: April 5, 6, 2023

Notice is hereby given that a Short Subdivision application was received by Grant County on March 17 2023 from Charles Schwab (Designated Contact:  Doug Robins, 8420 Aspi Blvd #5, Moses Lake, WA 98837), was found to be technically complete on March 31, 2023, Project: A Short Subdivision of one (1) parcel totaling approximately 74.3 acres. The short subdivision will create two(2) lots. Lot 1 will be approximately 71.31 acres and is under irrigated agricultural production. Lot 2 will be 3.01 acres and contains a barn, garage and residence, Zoning is Agriculture. Location of Proposal: The site address of the subject property is 4513 Rd L SE Moses Lake, WA. The proposed division is located in the NW ¼ and the SW ¼ of Section 30 Township 18 North, Range 29 East, W.M., and Grant County, WA. Parcel #19-0907-000. Studies Required: None. Public Hearing: None. Consistency Statement: This proposal is subject to, and shall be consistent with, Grant County Code, International Building Code, and International Fire Code. Copies of application materials (File #P 23-0078) are available from Kent Ziemer, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509) 754-2011 ext. 2538, kziemer@grantcountywa.gov. Office Hours: 8 am - 5 pm, M-F. Comments must be submitted to Development Services no later than 5pm on April 21, 2023. Comments should be as specific as possible and may be mailed, e-mailed, or delivered via parcel services. Office Hours: 8 am -5 pm, -F. All persons, agencies, or tribes have the right to comment, receive notice, participate in hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the abovementioned proposal and materials. #04031/7378 Pub: April 6, 2023

2023 AQUATIC TREATMENTS REQUEST FOR PROPOSALS The Moses Lake Irrigation and Rehabilitation District (MLIRD) respectfully requests cost proposals to survey & treat portions of Moses Lake within the District. This effort would inventory aquatic plants by species and coverage and make recommendations for a prioritized treatment plan for species not conducive to recreation or water intake and/or detrimental to water quality. Contractor must have all applicable licenses for professional work of this nature in Washington State. The project would include the following: Survey work: • Must be consistent with WA State DOE Aquatic Plant Sampling Protocols; and  • Requires previous experience identifying aquatic plants in similar waters & climates. • Contractor submitted & approved work plan based on survey(s) results. Survey & Application personnel should be familiar with Moses Lake water bathymetry. Treatment work: • MLIRD reserves final determination of contractor proposal or recommendations. Contractor should plan an estimated 200 acres, which may include: Diquat; Aquathol; Procellacor; Alum. • Proposal should include chemical price per gallon and application cost per acre for each chemical. • Selected Contractor will be responsible for the generation of all mailing lists, mailed notices, posted signs & water testing, agency reporting & required notifications within ¼ mile radius of work. • All chemicals used must be approved for aquatic use in WA State and under federal law. • Proof of $3,000,000 insurance required w/RFP, request ‘Packet’ for more detail. • GPS equipment required to plot and track treatments • All personnel & equipment supplied by Contractor Deliverables: 20 paper copies of a final report and a digital version in formats to be determined. Report to include: • Lake maps based on GPS data showing inventory findings and work performed • Recommended prioritized treatment plan for undesirable species discovered in survey(s) • Native ArcGIS shape files of treatments recommended and performed • Detailed Final Report provided by contractor Evaluation Factors for Proposal: • Positive Aquatic Survey & Applicator experience in Washington State: 25 points possible • Neat, Comprehensive, Understandable proposal: 25 Points • Summaries of other Aquatic Survey work and the results thereof in similar condi tions: 25 points possible • References & Examples showing other Aquatic Survey work: 25 points possible • Cost: 25 points possible (firm with lowest cost proposal awarded 25 points) MLIRD reserves the right to reject any or all submittals for any reason or no reason, to waive insubstantial or immaterial informalities, and select the RFP that, in the selection team’s judgment, best serves the needs of MLIRD and the people we serve. MLIRD may, in its sole discretion, renew this contract/agreement in each of three subsequent years. All completed RFP documents should include proposed survey and treatment timeframes and must be received by MLIRD no later than Tuesday – April 25, 2023, at 3:00 PM PST at 932 E Wheeler RD, Moses Lake, WA 98837. Call for Packet. (509)765-8716 #04005/7015 Pub: April 5, 12, 19, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF BABY BOY DIAZ CASE NO. 22-7-00253-13 DOB: 11/25/2021 MINOR CHILD. NOTICE OF SUM-MONS BY PUBLICATION (TERMINATION) TO: Jessica Diaz, Valentin Diaz and any-one claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 11/10/2022. A Fact-Finding Hearing will be held 04/25/2023 at 9:00 a.m. This hearing will be held via WebEx in Superior Court of Washington, Grant County Juvenile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for instructions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be re-quired to observe social distancing and facial mask guidelines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE HEARING WILL DE-TERMINE IF YOUR PARENTAL RIGHTS TO YOUR CHILD ARE TERMINATED. IF YOU DO NOT AP-PEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE TERMINATING YOUR PARENTAL RIGHTS. To re-quest a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View information about your rights in this proceeding at www.atg.wa.gov/DPY.aspx Dated this 25th day of January 2023. /s Deputy Clerk #04023/7281 Pub: April 5, 12, 19, 2023__

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD May 02, 2023 at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider the following budget extension request: *Auditors Office in the amount of $90,521.00 Fund # (511.181) Interfund Communications. *Auditors Office in the amount of $761,151.00 Fund # (134.185) Lodging Tax Advisory Committee (LTAC).   *District Court in the amount of $2,114.00 to pay for retainage on a 2022 project. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2493 679 8146) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz Deputy Clerk of the Board Grant County Commissioners #04041/7884 Pub: April 19, 26, 2023

Vanessa R. Waldref United States Attorney Brian M. Donovan Assistant United States Attorney Post Office Box 1494 Spokane, WA 99210-1494 Telephone: (509) 353-2767 UNITED STATES DISTRICT COURT EASTERN DISTRICT OF WASHINGTON UNITED STATES OF AMERICA, | | NO. 2:22-cv-00036-MKD | | Plaintiff, | | vs. | | LEE M. HERRING and SHEILA M. | HERRING, husband and wife, dba L&S | NOTICE OF UNITED STATES ORCHARDS; STATE OF | MARSHALS’ SALE OF REAL WASHINGTON, DEPARTMENT OF | PROPERTY LABOR & INDUSTRIES; BROOK | LAKE ORCHARDS, a Washington | corporation; LOIS RALSTON; RICK | ARMSTRONG and CHRISTINE | ARMSTRONG, husband and wife; | and DAVE PONOZZO and RANDIE | PONOZZO, husband and wife, | | | | Defendants. | TO: Lee M. Herring, Sheila M. Herring, L&S Orchards, State of Washington Department of Labor & Industries Brook Lake Orchards, Lois Ralston, Rick Armstrong, Christine Armstrong, Dave Ponozzo, and Randie Ponozzo The District Court for the United States of America for the Eastern District of Washington by virtue of an Amended Order of Foreclosure Sale dated, October 24, 2022, on a judgment rendered in said Court on September 27, 2022, has directed the undersigned to sell the property described below to satisfy a judgment in the above-entitled action. The property to be sold is as follows: The sale of the above described real property is to take place as follows: A. Real Property SECTION 2 TOWNSHIP 22 RANGE 28, THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER AND THAT PORTION OF GOVERNMENT LOT 5 LYING SOUTHERLY OF THE RIGHTOF-WAY OF THE U.S.B.R. MAIN CANAL AS SHOWN ON THE FARM UNIT PLAT OF IRRIGATION BLOCK 70, EIGHTH REVISION, COLUMBIA BASIN PROJECT, GRANT COUNTY, WASHINGTON, ACCORDING TO THE PLAT THEREOF FILED AUGUST 21, 1961, ALL IN SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M. EXCEPT THAT PORTION OF GOVERNMENT LOT 5 AND THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2 SAID POINT BEARS NORTH 01°0940"" EAST, 5300.00 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0040"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 229.26 FEET TO THE TRUE POINT OF BEGINNING; THENCE NORTH 01°0940"" EAST, PARALLEL TO THE WEST BOUNDARY OF SAID SECTION 2,785.92 FEET TO AN INTERSECTION WITH THE SOUTHERLY RIGHT-OF-WAY BOUNDARY OF THE U.S.B.R. MAIN CANAL; THENCE FOLLOWING SAID SOUTHERLY RIGHT-OF-WAY BOUNDARY THROUGH THE FOLLOWING TWO (2) COURSES; NORTH 83°0300"" EAST, 498.35 FEET; THENCE EASTERLY FOLLOWING A TANGENTIAL CURVE TO THE LEFT HAVING A CENTRAL ANGLE OF 24°4713"" AND A RADIUS OF 753.00 FEET, 325.76 FEET TO AN INTERSECTION WITH THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5; THENCE SOUTH 01°0845"" WEST ALONG THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5 AND THE EASTERLY BOUNDARY OF SAID SOUTH WEST QUARTER OF THE NORTHWEST QUARTER, 546.74 FEET; THENCE SOUTH 59°5311"" WEST, 24.58 FEET; THENCE SOUTH 63°1733"" WEST, 876.97 FEET TO THE TRUE POINT OF BEGINNING. AND TOGETHER WITH THAT PORTION OF THE NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER AND GOVERNMENT LOT 4, SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M., DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R. BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2, SAID POINT BEARS NORTH 01°0940"" EAST, 5300.10 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0940"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 1106.23 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 59°5311"" EAST, 24.58 FEET TO AN INTERSECTION WITH THE WEST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2 AND THE TRUE POINT OF BEGINNING; THENCE NORTH 59°5311"" EAST, 342.62 FEET; THENCE NORTH 76°1831"" EAST, 192.02 FEET; THENCE SOUTH 01°5345"" WEST, 788.26 FEET TO AN INTERSECTION WITH THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 88°1038"" WEST ALONG THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER, 468.30 FEET TO AN INTERSECTION WITH THE EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 01°0845"" EAST ALONG SAID EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, 555.69 FEET TO THE TRUE POINT OF BEGINNING. SUBJECT TO EASEMENT SEE DEED. AND THE FOLLOWING DESCRIBED IRRIGATION SYSTEM INCLUDING BUT NOT LIMITED TO THE FOLLOWING, INCLUDING ANY REPLACEMENT OF OR ADDITIONS TO SUCH SYSTEMS: COMPLETE SPRINKLER SYSTEMS WITH PUMPS, MAINS, SUB-MAINS, RISERS, SPRINKLERS, PLUGS, VALVES, AND FITTINGS. SUBJECT TO ALL OUTSTANDING EASEMENTS, RIGHTSOF-WAY, MINERAL LEASES, MINERAL RESERVATIONS, AND MINERAL CONVEYANCES OF RECORD. IN ADDITION TO FIXTURES, INCLUDING BUT NOT LIMITED TO, ALL IRRIGATION EQUIPMENT, PUMPS, PIPES, MAINLINE, SPRINKLERS, STORAGE FACILITIES, STORAGE FACILITIES, TANKS, BINS, FENCES, WIND MACHINES, AND SIMILAR GOODS AND INFRASTRUCTURE WHICH ARE NOW OWNED OR ACQUIRED IN THE FUTURE. ALL ADDITIONS, RE PLACEMENTS, SUBSTITUTIONS AND ACCESSORIES TO FIXTURES. Assessor’s Parcel No. 171179000. Property Address: 23663 Road J NE, Stratford, Grant County, Washington, 98853 B. Personal Property Wind machines, Irrigation equipment including but not limited to irrigation pumping equipment, irrigation pumps, irrigation pipes, and other irrigation equipment [located at the aforementioned real property]. (hereinafter collectively referred to as the “Property”). Time: 10:30 A.M. Date: March 10, 2023 Place: Grant County Courthouse 35 C Street NW Ephrata, Washington Minimum Bid: $351,775.08 The judgement debtor(s) can avoid the sale by paying the judgment amount of $341,658.71, plus interest at the applicable and legal rate until paid in full, and for the costs of suite, including the filing fee allowed pursuant to 28 U.S.C. 2412(a)(2), and other proper relief. For the exact amount, contact the Marshal at the address stated below: Craig Thayer United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 Redemption period: x The Real Property is subject to a Redemption period of one year which will expire at 4:30 p.m. on March 10, 2024.  No Redemption rights on Personal Property. The judgment debtor or debtor(s) or any of them may redeem the real property and fixtures at any time up to the end of the redemption period by paying the amount bid at the Marshal’s sale, plus additional costs, taxes, assessments and fees. If you are interested in redeeming the property contact the undersigned United States Marshal for the exact amount necessary to redeem. IMPORTANT NOTICE: IF THE JUDGMENT DEBTOR OR DEBTORS DO NOT REDEEM THE PROPERTY BY 4:30 p.m. ON THE 10th DAY OF MARCH, 2024 THE END OF THE REDEMPTION PERIOD, THE PURCHASER AT THE MARSHAL’S SALE WILL BECOME THE OWNER AND MAY EVICT THE OCCUPANT FROM THE PROPERTY UNLESS THE OCCUPANT IS A TENANT HOLDING UNDER AN UNEXPIRED LEASE. IF THE PROPERTY TO BE SOLD IS OCCUPIED AS A PRINCIPAL RESIDENCE BY THE JUDGMENT DEBTOR OR DEBTORS AT THE TIME OF SALE, HE, SHE, THEY, OR ANY OF THEM MAY HAVE THE RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD, IF ANY, WITHOUT PAYMENT OR ANY RENT OR OCCPANCY FEE. THE JUDGMENT DEBTOR MAY ALSO HAVE A RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD IF THE PROPERTY IS USED FOR FARMING OR IF THE PROPERTY IS BEING SOLD UNDER A MORTGAGE THAT SO PROVIDES. The successful bidder for the Property shall be required to deposit at the time of the same with the Marshal a minimum of ten percent of the bid, with the deposit to be made by certified or cashier’s check or cash payable to the United States District Court for the Eastern District of Washington. Before being permitted to bid at the sale, bidders shall display to the Marshal, or his/her representative, proof that they are able to comply with this requirement. No bids will be received from any person(s) who have not presented proof that, if they are the successful bidder(s), they can make the deposit required by this order of sale. The balance of the purchase price for the Property is to be paid to the Marshal within twenty days after the bid is accepted, by a certified or cashier’s check payable to the United States District Court for the Eastern District of Washington. If the bidder fails to fulfill this requirement, the deposit shall be forfeited and shall be applied to cover the expenses of the sale, including commissions due under 28 U.S.C. § 1921(c), with any amount remaining to be applied to the Judgment of the Defendant at issue herein. The Property shall be again offered for sale under the terms and conditions of this order of sale, or, in the alternative, sold to the second highest bidder. The sale of the Property shall be subject to confirmation by the Court. The Marshal shall file a report of sale with the Court, together with a proposed order of confirmation of sale and proposed deed, within thirty days from the date of receipt of the balance of the purchase price. On confirmation of the sale, the Marshal shall execute and deliver a certificate of sale. Upon the expiration of the redemption period, absent a redemption, the deed shall be executed and delivered immediately to the successful bidder. On confirmation of the sale, all interests in, liens against, or claims to, the Property that are held or asserted by all parties to this action are discharged and extinguished. Any party to this suit may become a purchaser at such sale. The United States may bid as a credit against its judgment without tender of cash. The sale will be “as is” and without warranty of any kind. DATED this 26th day of January, 2023. _______________________________ CRAIG THAYER United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 #02018/5061 Pub: February 3, 10, 17, 24, 2023___________________________________________

The Board of Directors Annual meeting for Adams County Weed District #1 will be held at 5:00 p.m. Monday February 27, 2023. Election of one board member for a term of three years will be held. 2023 Noxious Weed list and policy will be reviewed and adopted for Adams County Weed District #1.The 2023 Washington State Noxious Weed list will be available for review. #02033/5283 PUB: February 8, 15, 22, 2023

Moses Lake Irrigation and Rehabilitation District Small Works Roster Notice is hereby given that the Moses Lake Irrigation and Rehabilitation District (MLIRD) is accepting applications for its Smal Works Roster for the year 2023. The Small Works Roster will be used to solicit and secure telephone and /or written quotations for maintenance and improvement projects. All vendors, contractors, suppliers, or other parties wanting to be included in the Small Works Roster much obtain an Application from the District. Applications may be obtained via telephone request at (509)765-8716, email request at mlird@mlird.org, or by written request sent to P.O. Box 98, Moses Lake, WA 98837. Dated this 6th day of February 2023 Moses Lake Irrigation and Rehabilitation District By: Beth Yonko      Interim Manager #02039/5356 Pub: February 10, 2023

GRANT COUNTY WATER CONSERVANCY BOARD NOTICE OF APPLICATION FOR CHANGE OF GROUNDWATER CERTIFICATE G3-20015C(A) Notice of Application for Change of Water Right to change the point of withdrawal, place of use, purpose of use, and period of use under Groundwater Water Right No. G3-20015C(A). TAKE NOTICE: That on January 26, 2023, the City of Moses Lake filed application number GRAN-23-01 with the Grant County Water Conservancy Board (GCWCB) to change the point of withdrawal, place of use, purpose of use, and period of use under groundwater water right G3-20015C(A). That said right, G3-20015C(A), under priority date March 7, 1972, authorizes the withdrawal of 500 gallons per minute and 219.9 acre-feet per year for seasonal irrigation of 50 acres and 1.0 acre-feet per year for continuous domestic supply, from a well located within the SE¼ NW¼ Section 15, T. 20 N., R. 28 E.W.M. The existing place of use can be described as a portion of the N½ of Section 15, T. 20 N., R. 28 E.W.M., Grant County.  The applicant proposes to change the point of withdrawal and place of use to include 30 groundwater wells within the City of Moses Lake Water Service Area; one well exists in the in the SW¼NE¼ of Section 29, T. 19 N., R. 28 E.W.M. and a second well exists in the NW¼NE¼ of Section 27 T. 20 N., R. 28 E.W.M. The remaining 28 wells are to be constructed in the SW¼SE¼ and NE¼SW¼ of Section 4, NW¼ of Section 13, SW¼ and SE¼SE¼ of Section 14, NE¼NW¼, NW¼SW¼, and SW¼SE¼ of Section 15, SE¼NW¼ of Section 16, SE¼NE¼ of Section 22, NE¼SE¼ and SE¼NW¼ of Section 23, SW¼SE¼ of Section 25, SW¼SW¼ of Section 26, SE¼ and NE¼NW¼ of Section 27, SE¼ of Section 28, NW¼SW¼, S½, and SE¼SW¼ of Section 29, NE¼SW¼ of Section 33, all within T. 19 N., R. 28 E.W.M.; the NW¼ and SW¼ of Section 12 T. 18 N., R. 28 E.W.M.; the NW¼ of Section 16 and NW¼NW¼ of Section 20 within T. 19 N., R. 29 E.W.M.; and the SE¼NE¼, NE¼SE¼, NE¼NW¼ of Section 32 all within T. 20 N., R. 28 E.W.M. The place of use can be described as the City of Moses Lake Water System Boundary. The Applicant also proposes to change the period of use and purpose of use to year-round municipal supply. There are no changes to the total authorized quantity of water. Any protests or objections to the approval of this application may be filed with the Department of Ecology and must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-dollar ($50) recording fee and filed with the Cashiering Section, State of Washington, Department of Ecology, P.O. Box 47611, Lacey, Washington 98509-7611 within thirty (30) days from (February 17, 2023).  Any interested party may submit comments, objections, and other information to the GCWCB regarding this application. The comments and information may be submitted in writing or verbally at any public meeting of the Board held to discuss or decide on the application. Additionally, the Board will consider written comments or information  provided within thirty (30) days from February 17, 2023 of this notice, said written comments or information to be provided to its office located 2145 Basin Street SW, Ephrata, WA 98823. #02040/5358 Pub: February 10, 17, 2023

PUBLIC NOTICE: Ryka Consulting is proposing to build a 150-foot Monopole Telecommunications Tower located in the vicinity of 1804 Rd 14 NE, Coulee City, Grant County, WA 99115 (lat/long: N 47-49-2.61 / W 119-21-41.63). Public comments regarding potential effects from this site on historic properties may be submitted within 30-days from the date of this publication to: Taylor Blackbourn, Terracon, 21905 64th Avenue West, Suite 100, Mountlake Terrace, WA 98043; 425-771-3304; taylor.blackbourn@terracon.com. #02041/5376 PUb: February10, 2023

NOTICE TO MATERIAL SUPPLIERS  Sealed bids plainly marked “Bid for Asphalt Materials - 2023” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, March 1, 2023 and will then and there in the Public Meeting Room be opened and publicly read. If you have any questions about this procedure please call the Public Works Office in advance of the bid opening.:  Rob Harris  Assistant County Engineer  509-906-6415  rgharris@grantcountywa.gov  This contract provides for furnishing and delivering asphalt materials in accordance with the plans and specifications.  Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823.  The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County.  The improvement for which bids will be received follows:  Asphalt Materials - 2023  This proposal provides for furnishing 4,000-6,000 tons of HFE-150 liquid asphalt, 500 - 700 tons of HFE-90 liquid asphalt and 6000 - 8,000 tons of Hot Mix Asphalt for the 2023 season to Grant County and other work in accordance with the specifications.  #02043/5423 Pub: February 10, 15, 17, 22, 24, 27, 2023

PUBLIC NOTICE – The May meeting of the Noxious Weed Control Board of Grant County will be held Tuesday, May 16, 2023, at 10:00 a.m. The meeting will be held in-person at the Bureau of Reclamation building, 32 C St NW, Room 304B, Ephrata, WA, and via Webex. Please call (509) 237-4567 ahead of the meeting time for remote attendance instructions. Meeting updates will be posted on our website at www.grantcountyweedboard.org. Signed: Ron Tebow, Chairman; Wes Sieg, Vice-Chairman; Summer Sahli, Director; Chuck Sandmann, Director #05020/8300 Pub: May 9, 12, 2023

ADVERTISEMENT FOR BIDS WATER MAIN IMPROVEMENTS  City of Royal City, Washington 445 Camelia Street NE/P.O. Box 1239 Royal City, Washington 99357 General Notice The City of Royal City, Washington (Owner) is requesting Bids for the construction of the following Project: Water Main Improvements. Bids for the construction of the Project will be received at the City of Royal City, City Hall located at 445 Camelia Street NE, Royal City, Washington, 99357 until 2:00 p.m. local time, May 31, 2023. At that time the Bids received will be publicly opened and read. The Project includes the following Work: Installation of approximately 380 linear feet of 6-inch diameter water main, 7,200 linear feet of 8-inch diameter water main, 3,600 linear feet of 12-inch diameter water main, gate valves, butterfly valves, water service pipe and connections, water meter relocation, fire hydrants, air release valve assembly, surface restoration, and other miscellaneous work required to complete the Project as shown on the Drawings and as specified. The Work may include one or more Additive Alternatives which include the installation of approximately 100 linear feet of 6-inch diameter water main, 2,430 linear feet of 8-inch diameter water main, gate valves, water service pipe and connections, water meter relocation, fire hydrants, surface restoration, and other miscellaneous work. This Project is being funded in part through USDA Rural Development and the Washington State Community Development Block Grant program with federal funds from the U.S. Department of Housing and Urban Development. Because the Project is being paid for by federal funds, all Work will be subject to all federal and state requirements relating to the use of such funds, including the Davis-Bacon Wage Rates or Washington State Prevailing Wage Rates for Public Works Projects, EEO, Washington State Contracting Laws, etc. All Work performed on this project will be subject to the higher of the state or federal wage rates. Bid security is required and shall be furnished in accordance with the Instruction to Bidders. The Work shall be substantially completed within 160 calendar days. Obtaining the Bidding Documents Bidding Documents are available at http://www.andersonperry.com under the Bid Docs link. The digital Bidding Documents may be downloaded for a non-refundable payment of $30.00 by inputting QuestCDN eBidDoc Number 8436707 on the website. Assistance with free QuestCDN membership registration, document downloading, and working with the digital Project information may be obtained at QuestCDN.com, at 952-233-1632, or via e-mail at info@questcdn.com. The Bidding Documents will be available for download on May 8, 2023. No paper sets will be provided for bidding purposes. Prospective Bidders are urged to register with the designated website as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. The designated website will be updated periodically with addenda and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through the designated website. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than the designated website. The Issuing Office for the Bidding Documents is: Anderson Perry & Associates, Inc. Bill Vixie, P.E. P.O. Box 1687/214 E. Birch Street, Walla Walla, Washington 99362 509-529-9260, bvixie@andersonperry.com Prospective Bidders may examine the Bidding Documents at the Issuing Office on Monday through Friday between the hours of 8:00 a.m. and 5:00 p.m. or at the location listed below. City of Royal City, 445 Camelia Street NE, Royal City, Washington  The Owner may reject any bid not in compliance with all prescribed requirements and may reject for good cause any and all bids upon finding that it is in the public interest to do so. The Owner is an equal opportunity and affirmative action employer. Small, minority and women-owned businesses are encouraged to submit bids. Small minority and women-owned businesses should indicate they are a minority on the Planholders List. Pre-bid Conference A pre-bid conference will not be held. Instructions to Bidders For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents. American Iron and Steel Section 746 of Title VII of the Consolidated Appropriations Act of 2017 (Division A - Agriculture, Rural Development, Food and Drug Administration, and Related Agencies Appropriations Act, 2017) and subsequent statutes mandating domestic preference applies an American Iron and Steel requirement to this project. All iron and steel products used in this project must be produced in the United States. The term “iron and steel products” means the following products made primarily of iron or steel: lined or unlined pipes and fittings, manhole covers and other municipal castings, hydrants, tanks, flanges, pipe clamps and restraints, valves, structural steel, reinforced precast concrete, and Construction Materials. The following waivers apply to this Contract: De Minimis, Minor Components, Pig iron and direct reduced iron. This Advertisement is issued by: Owner: City of Royal City, Washington By: Kent Andersen  Title: Mayor Published: Columbia Basin Herald, Fridays May 5, 2023, and May12, 2023 #05027/8529 Pub: May 5, 12, 2023

NOTICE TO SUPPLIERS Sealed bids plainly marked “Bid for Steel Canopy Body” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, May 30th, 2023 and will then and there in the Public Meeting Room be opened and publicly read.  This contract provides for furnishing and delivering a Steel Canopy Body in accordance with the plans and specifications. Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County. The improvement for which bids will be received are as follows: Bid Specifications for Steel Canopy Body General Specifications This spec is patterned after the Knapheide KC7132H2094 Steel Canopy Body.   - 133.25” L x 94”W x 90” H (40” H side compartments) - 20” side compartment depth - Curbside  Horizontal (RH) compartment extends to rear of body - 14 and 16 gauge galvanneal steel body shell – Keyed alike stainless steel paddle handles with rotary style latches - Master locking system installed on both sides of body - Transverse-style L V 1 compartment extends to the back of R V 1 - (2) adjustable divider shelves in R V 1 compartment - (2) adjustable divider shelves in each L V 2 and R V 2  compartment - (1) bolt t- in divider shelf in R H compartment - (1) adjustable divider shelf in each L R and RR compartment - Double-panel galvanneal doors on rear of canopy (20 gauge outer, 14 gauge inner): - 49.5”W x 63.1” H clear door opening dimensions - Solid panel; no glass/ glass guards - 71.1” interior clear height - (2) L E D interior dome lights - (2) full length shelves on each side of canopy  Interior - 6-year limited warranty - Electro- immersion epoxy primer process - Fully undercoated  (Acrylic) - LED stop, tail, turn, and back-up lights - Chassis-specific install kit (loose): - Includes chassis-specific wiring harness adapter - 94”W Galva-grip bumper (loose) with hitch recess and K nap Liner  coating - Canopy upper side doors with 3-point twist latches - Rear chute doors deleted - 94” wide knaplined Galva-grip step bumper Install Knapheide dual rear wheel KUV cc canopy body as follows: - S/T /T lights - Mud flaps - (1) fuel spout - (2) interior dome lights - Standard bumper Paint 132” K U V cc canopy body urethane: Ford paint code PQ 1 Exhaust extension to bring exhaust out flush  with the body 1 Class V receiver hitch installed as follows: - 24,000 lb. maximum trailer weight , 1,600 lb. maximum vertical load - 2” receiver tube with pin and clip - Includes pin with cotter - Powder coated black 1 7-way trailer socket , RV style with flat blades 1LED compartment light strips in all  compartments for an 8 compartment service body - High intensity LED light strips mounted on each side of the compartment - Wired to existing chassis upfitter switch 1 C T E H .D . Aluminum 7-drawer unit installed as follows: LV2 - 14” w x 32”h x 16”d - (4) -3”, (2) -5”, and (1) -7” removable drawers –  Aluminum construction - Patented motion latch drawer handles - 250 lb. capacity roller slides - Powder coated red with black handles - (6) divider kits - Rubber liners in all drawers 1  Install customer’s existing Miller Bobcat 250 welder in LV1/ transverse compartment - Plumb exhaust up through canopy top 1 110v GFI electric outlet on rear of body wired to customer supplied welder  (No inverter) Install (4) Whelen WHL31HAF LED beacon lights as follows: - Weld mounting plates to canopy - (2) at the front corners of canopy body - (2) at rear corners of the canopy - Install LED beacon light on mounting plates and wire to chassis upfitter switch 1 Install Ford Factory Backup Camera 1 Dominator Liner red, front of body 1 Speed Liner 1000 black, cargo area floor and tailgate Speed Liner 1000 black, cargo area sides Provide the cost to furnish and deliver (inclusive of shipping) F.O.B., the following items meeting the specifications: #05031/8826 Pub: May 12, 16, 19, 23, 26, 2023

CITY OF MOSES LAKE NOTICE TO CONSULTANTS FOR Project # GC2022-081 SR 17 / Yonezawa Blvd Intersection Improvement The City of Moses Lake solicits interest from consulting firms with expertise in Civil and Structural Engineering Design. This agreement will be for approximately 18 Months in duration with the option for the City of Moses Lake to extend it for additional time and money if necessary. It is anticipated that work will commence during the 3rd Quarter of 2023. Consultants will be considered for the following project. The City of Moses Lake reserves the right to amend terms of this “Request for Qualifications” (RFQ) to circulate various addenda, or to withdraw the RFQ at any time, regardless of how much time and effort consultants have spent on their responses. Project Description The work to be performed by the CONSULTANT consists of preparing preliminary engineering design for improvements to Yonezawa Blvd & SR 17 Intersection. The proposed improvements include constructing a multilane roundabout and extending Yonezawa Avenue East to accommodate four lanes of traffic, removal of exiting signal systems in order to accommodate the proposed improvements and coordination with multiple agencies in preparation for construction. This project has 13% DBE goal. The major features of the project are as follows: • Design of multilane roundabout to WSDOT Standard Specification and Design Manual. • Design new connection for 4th leg on the intersection for East Yonezawa Blvd Extension to accommodate up to four lanes of traffic that meets City Standards. • Environmental documentation and preparation of permit applications if necessary. • Topographic and boundary survey (the City has completed some of the survey work; the consultant will be provided with the existing survey to expand to project limits). • Geotechnical engineering as needed for roadway and storm drainage design. • Illumination System modification design and traffic signal removal. • Determination of R/W needs, limited access revisions, and R/W plan preparation. • Construction phasing, sequencing, property access plans, and site-specific traffic control plans. • New utility installation and existing utility relocation coordination as needed. • A copy of the Grant application and award letter are available by request. The City of Moses Lake reserves the right to retain the services of the successful firm(s) for any subsequent phases (R/W, CN) associated with this/these project(s). Evaluation/ Scoring Criteria Submittals will be evaluated and ranked based on the following criteria: FACTOR POINTS Qualification of Proposed Project Manager & Team 30 Understanding and approach to meet schedule 40 Familiarity with WSDOT/FHWA projects & standards. 10 Past Performance/References 10 Approach to meet the DBE goal (DBE Participation Plan) 10 MAXIMUM AVAILABLE POINTS 100 Submittal • Submittals should include the following information: Firm name, phone, and fax numbers; Name of Principal-in-Charge and Project Manager; and number of employ ees in each firm proposed to project. • Submittals must be limited to 10 double-sided pages (20 total faces), excluding a letter of interest & resumes. Submittals must include the following information: 1) Letter of Interest: The cover letter shall briefly summarize the firm’s qualifications and experience relevant to the scope. A principal or officer of the firm authorized to execute contracts or other similar documents on the firm's behalf must sign the letter. 2) Evidence of the firm’s ability and availability to perform the required services: a) Outline your firm’s experience on the Scope of Work. b) Describe your firm’s overall design approach, including organization and work tasks necessary to accomplish the objectives, products, and project schedule. c) If it is your firm’s practice to have any specific sub-categories of the Scope of Work performed by sub-consultants, please identify the sub-consultants you anticipate using, indicate their specific roles, and outline their experience on similar or related work. d) Describe your quality control process. 3) Qualifications/expertise of the key personnel on the team; with evidence of the availability of staffing to begin immediately upon award of Contract. a) Provide a list of key personnel, including sub-consultants indicating the specific role of each, and clearly identify the Project Manager. Project Manager’s qualifications are key to the City’s evaluation of the Consultant's ability to meet the City’s needs. b) Provide a professional resume for each named key personnel, indicating the extent of their experience on projects related to this type of work. 4) Past performance and record of successful completion of similar work. a) Describe any previous projects (firm and individual, indicate each) of similar nature and scope, and provide a specific description of specific responsibility on such projects. b) Note any information useful in demonstrating successful results on previous projects (within budget, constructed within contract time, etc.). 5) Attachments a) Resumes: include resumes of all key personnel that will work directly with or on this project. b) Provide a list of recent client references, ideally reflecting projects similar in nature. Please submit 1 digital copy (thumb drive) and 1 hard copy of your Statement of Qualifications to: City of Moses Lake, 321 S Balsam Street, Attn: Levi Bisnett no later than 4:00 p.m. on June 8, 2023. Submittals will not be accepted after that time and date. Any questions regarding this project should be directed to Levi Bisnett, at (509) 764-3775 or lbisnett@cityofml.com Additional Information for prospective consultants: Federal EEO Requirements Federally funded projects will be held to Federal EEO requirements. Americans with Disabilities Act (ADA) Information The City of Moses Lake in accordance with Section 504 of the Rehabilitation Act (Section 504) and the Americans with Disabilities Act (ADA), commits to nondiscrimination on the basis of disability, in all of its programs and activities. This material can be made available in an alternate format by emailing: City of Moses Lake, Levi Bisnett at lbisnett@cityofml.com or by calling collect (509)764-3775. Title VI Statement The City of Moses Lake, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award.” Dates of publication in the (Columbia Basin Herald): (May 12, 2023), and (May 19, 2023). #05033/8862 Pub: May 12, 19, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR GRANT COUNTY MIDDLE BAR C, LLC, a Washington limited | liability company,  | Plaintiff, | NO. 23-2-00152-13 vs. | FRANCES E. SHAW, an individual; | ENID TREFFINGER, an individual; and ALSO ALL | OTHER PERSONS OR PARTIES UNKNOWN | SUMMONS CLAIMING ANY RIGHT, TITLE, ESTATE, | LIEN, OR INTEREST IN THE REAL ESTATE | DESCRIBED IN THE COMPLAINT HEREIN, |                             Defendants. | The State of Washington to DEFENDANTS FRANCES E. SHAW, ENID TREVVINGER, and ALSO ALL OTHER PERSONS OR PARTIES UNKNOWN CLAIMING ANY RIGHT, TITLE, ESTATE, LIEN, OR INTEREST IN THE REAL ESTATE DESCRIBED IN THE COMPLAINT HEREIN:  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after the 14th day of March, 2023, and defend the above entitled action in the above titled court, and answer the complaint of the plaintiff MIDDLE BAR C, LLC, and serve a copy of your answer upon the undersigned attorneys for the Plaintiff Middle Bar C, LLC at its office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court.  This action arises from a complaint to quiet title in real property in Grant County, Washington.  Dated this 8th day of March, 2023. LUKINS & ANNIS, P.S. By /s/ Court A. Hall___________ TREVOR R. PINCOCK, WSBA #36818 COURT A. HALL, WSBA #54016 Attorneys for Plaintiff 717 W. Sprague Ave., Ste. 1600 Spokane, WA 99201 (509) 455-9555 #04001/6464 Pub: March 14, 21, 28, 2023 & April 4, 11, 18, 2023

Notice of Application, Proposed DNS, and Public Hearing: March 14, 2023 Notice is hereby given that a Conditional Use Permit Application and SEPA Checklist were received by Grant County on February 15, 2023 from NW GeoSolar (Designated Contact: Sieburg Designs, 605 Woodcrest St. Lewisburg TN, 37019) and were found to be Technically Complete on March 9, 2023. [Grant County expects to issue a Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used.] This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROJECT: A Conditional Use Permit and SEPA checklist proposing the construction of a two- story 14,000 square feet Assisted Living Facility. The facility will house 20 residents. The property will host a detached accessory dwelling unit for caretakers/facility managers. The facility will contain a garage and greenhouse. The site currently contains a 4,500 square foot office structure. Total building area is anticipated to be 26,000 square feet on a 2.86 acre parcel. STUDIES REQUIRED: None. LOCATION: 4306 Arnold Dr. in the Larson Community in Moses Lake. Being in the Northeast quarter of Section 32, Township 20 North, Range 28 East, Willamette Meridian, Grant County, WA. Parcel #17-1043-000. ZONING: Urban Residential 2 (UR2).  ADDITIONAL PERMITS: Building Permits, SEPA Environmental Checklist.  PUBLIC HEARING: Grant County Hearings Examiner tentatively scheduled for Wednesday, April 12, 2023 at 12:00 pm in the Commissioners Hearing Room at the Grant County Courthouse in Ephrata, WA. At this time, any person(s) may provide testimony for the hearing. Members of the public may also be present in the hearing room in limited numbers. Grant County is providing access to this scheduled hearing for the public via WebEx audio connection. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2482 325 5405), you will be joined to the meeting in a ‘muted’ status until the hearing allows for public testimony. If you have any questions about this procedure please call Development Services in advance of the hearing. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials (Files P23-0056 and P23-0057) are available from Kent Ziemer, (kziemer@gratncountywa.gov), Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538. Office hours: 8 am to 5 pm, M–F. Comments must be submitted to the Planning Department no later than 5 pm on March 28, 2023. Comments should be as specific as possible and may be mailed, electronic email or hand-delivered. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials #03029/6489 Pub: March 14, 2023______

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FRO THE COUNTY OF GRANT In the matter of the Estate of: ) ) NO. 23-4-00021-13 MARCELO PRUNEDA, ) ) PROBATE NOTICE TO CREDITORS Deceased. ) ____________________________ ) The Personal Representative named below has been appointed as Personal Representative of this estate. Any person having a claim against the decedent must, before the time claim would be barred by any other wise applicable statute of limitations, present the claim in the manner as provieded in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s Attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provieded under RCW 11.40.020(1)(c): or (2) four months after the date of first publication of the noitce. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 abd 11.40.060. This bar is efffective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: Date March 10, 2023 Personal Representative: Elida Martinez Street P.O.Box 14 City, State, Zip Warden, WA 98857 #03022/6317 Pub: March 10, 17, 24, 2022

ROYAL SCHOOL DISTRICT BOARD OF DIRECTORS  NOTICE OF WORK SESSION  Monday, March 27, 2023 – 6:30 pm  Royal Intermediate School Library  NOTICE IS HEREBY GIVEN that the Board of Directors (the “Board”) of Royal School  District will be holding a Work Session on Monday, March 27, 2023 at 6: 30pm at Royal  Intermediate School library, 6261 Rd. 12 SW, Royal City, WA 99357. The Work Session is  called for the purpose to discuss the 2024-2025 school year calendar.   Dated this 20th day of March 2023  Royal School District No 160  Grant County, WA  Roger W. Trail  Secretary to the Board of Directors #03036/6547 Pub: March 20, 24, 2023

IN THE SUPERIOR COURT OF WASHINGTON FOR SNOHOMISH COUNTY IN THE MATTER OF ESTATE ) NO. 23 4 00464 31 ) ) PROBATE NOTICE ) TO CREDITORS SHANE ANTHONY ARNOLD, ) ) Deceased, ) RCW. 11.40.030 ____________________________________) The personal representative named below has been appointed as personal representative of the estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1) (C); or (2) four months after the date of first publication of this notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and no-probate assets. Date of First Publication: March 17, 2023___ Personal Representative: /s/ Derek Arnold___ Derek Arnold Attorney for Personal Representative: /s/ Terry Simon____ Terry H. Simon, WSBA #15409 Address for Mailing or Service: 113. N Lewis Street Monroe, WA 98272 (360) 794-7101 #03042/6681 Pub: March 17, 24. 31, 2023

============ 2022 NOTICE OF CONSTRUCTION COMPLETION ============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Engineer’s Office has completed the following County Forces conducted road projects in 2022 with final true and complete costs as follows:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion Road 3-NE Phase 4 BST Surface after 22-01 County Forces $277,000 Contractor Preparations Total = $277,000 The maximum allowable construction work by County forces is $1,307,338. The 2022 County Forces completed work is well under the maximum allowed.   Dated this 16th day of March 2023 ========================== END OF NOTICE=========================== #03046/6752 Pub”March 22, 24, 27, 30, 2023

============ 2023 NOTICE OF COUNTY FORCES CONSTRUCTION============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Board of County Commissioners intends to have the following road(s) improved by County Forces (using county crews and equipment) in calendar year 2023:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion ADA Ramp / Sidewalk Upgrades ADA Ramp and/or Sidewalk County Forces $120,000 Miscellaneous Projects Safety/Drainage/Guardrail/ Bridge/Roads County Forces $250,000 B-SE Culverts Replace Culverts 18-10 County Forces $200,000 Road 23 NE Bridge Replacement 23 NE Bridge 171 Replacement 22-04 County Forces $100,000 Gravel to Oil Program (1.5 Miles) Portions of Road 8-NE and Road 12-NE County Forces $400,000 Total = $1,070,000 The maximum allowable new construction work by County forces is $1,307,338. The 2023 proposed work is well under the maximum allowed. All other new construction shall be contracted out for 2023. Dated this 16th day of March 2023 ========================== END OF NOTICE ========================== #03045/6756 Pub: March 22, 24, 27, 30, 2023

Columbia Northwest Engineering, PS, Kari Frost, 249 N Elder St Moses Lake, WA 98837-1731, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit.  The proposed project, Sand Hill Place, is located North of I90, West of Hansen Rd in Moses Lake in Grant county.  This project involves 47.27 acres of soil disturbance for Highway or Road, Residential, Utilities construction activities.  All discharges and runoff goes to ground water.  Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320.  Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696 #03047/6909 Pub:March 24, 31, 2023

NOTICE OF CONTRACT  COMPLETION NOTICE IS HEREBY GIVEN that Hilmes Construction Inc. has completed work on the PRS Railroad Spur.  NOTICE IS FURTHER GIVEN that claims against the retained percentage for this contract must be filed with the PORT OF ROYAL SLOPE on or before June 19, 2023. Dated this 22 day of May, 2023. -S- Bonnie Valentine, Port Executive Director #05042/9108  Pub: May 22, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD May 02, 2023 at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider the following budget extension request: *Auditors Office in the amount of $90,521.00 Fund # (511.181) Interfund Communications. *Auditors Office in the amount of $761,151.00 Fund # (134.185) Lodging Tax Advisory Committee (LTAC).   *District Court in the amount of $2,114.00 to pay for retainage on a 2022 project. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2493 679 8146) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz Deputy Clerk of the Board Grant County Commissioners #04041/7884 Pub: April 19, 26, 2023

CITY OF OTHELLO NOTICE OF PUBLIC HEARING NOTICE IS HEREBY GIVEN that the City Council has scheduled a public hearing to review and receive public input regarding the City’s Six Year Transportation Improvement Program for 2024-2029. The public hearing will be held during the regular City Council meeting on Monday, May 8, 2023 at 6:00 p.m., at Othello City Hall, 500 E. Main Street. All council meetings are open to the public and may be attended in person or virtually on Zoom. The link will be available on the city website othellowa.gov. The chambers are handicap accessible. Arrangements to reasonably accommodate special needs, including accessibility or an interpreter, will be made upon receiving 24-hour advance notice. For additional information, contact the city at (509)-488-5686. Tania Morelos City Clerk Published in the Columbia Basin Herald April 26th, 2023 #04046/7962 Pub: April 26, 2023

SUMMARY ORDINANCE 23-684 AN ORDINANCE OF THE CITY OF MATTAWA, WASHINGTON DESIGNATING A RESPONSIBLE INDIVIDUAL FOR THE MANAGEMENT OF CITY-OWNED PUBLIC TREES IN THE CITY OF MATTAWA AND ESTABLISHING A TREE ADVISORY BOARD For a complete copy of this ordinance, please contact Mattawa City Hall. To be published in the Columbia Basin Herald on April 26, 2023 #04049/8127 Pub: April 26, 2023

WASHINGTON STATE SUPERIOR COURT  COUNTY OF GRANT United States Department of Agriculture | (USDA), | No.  | Plaintiff, | SUMMONS (60 days) v. | | Eddie L. Rayoum, an individual and martial | community; Alice F. Rayoum, an individual | and martial community; and John and Jane | Does I through X; occupants of the subject | real property; and all other persons or parties | unknown claiming any right, title, interest, | lien or Estate in the property herein describe. |  | Defendants. | ____________________________________ | TO THE DEFENDANTS: A lawsuit has been started against you in the above entitled court by United States Department of Agriculture (“USDA”), hereinafter “Plaintiff”. Plaintiff’s claim is stated in the written complaint, a copy of which is available upon request and is on file with the court.  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after 28th day of March, 2023 and defend the above entitled action in the above entitled court, and answer the complaint of the plaintiff, and serve a copy of your answer upon the undersigned attorneys for plaintiff at their office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. The purpose of this suit is to foreclosure on your interest in the following described property:  The North 36 feet of Lot 19 and the South 27 feet of Lot 20, Block 11, Ephrata Heights First Addition to Ephrata, according to the plat thereof recorded in Volume 3 of Plats, page 4, records of Grant County, Washington. Which is located at:  140 H St. SE, Ephrata, WA 98823. In order to defend against this lawsuit, you must respond to the complaint by stating your defense in writing, and by serving a copy upon the person signing the summons within 60 days after the service of this summons, excluding the day of service, or a default judgment may be entered against you without notice. A default judgment is one where plaintiff is entitled to what he or she asks for because you have not responded. If you serve a notice of appearance on the undersigned person, you are entitled to notice before a default judgment may be entered. IMPORTANT NOTICE If judgment is taken against you, either by default or after hearing by the court, your property will be sold at public auction. You may prevent the sale by paying the amount of the judgment at any time prior to the sale. If your property is sold, you may have the right to redeem the property during the redemption period if applicable, by paying the amount for which the property was sold, plus interest and costs of the sale. If you wish to seek the advice of an attorney in this matter, you should do so promptly so that your written response, if any, may be served on time.  This summons is issued pursuant to rule 4 of the Superior Court Civil Rules of the State of Washington and RCW 4.28.100(7). Dated this 7th day of March, 2023. WONG FLEMING /s/ Wong Fleming_____________ Vanessa Moore, WSBA #52668 Attorney for Plaintiff #05001/6441 Pub: March 28, 2023, April 4, 11, 18, 25, 2023 & May 2, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR GRANT COUNTY MIDDLE BAR C, LLC, a Washington limited | liability company,  | Plaintiff, | NO. 23-2-00152-13 vs. | FRANCES E. SHAW, an individual; | ENID TREFFINGER, an individual; and ALSO ALL | OTHER PERSONS OR PARTIES UNKNOWN | SUMMONS CLAIMING ANY RIGHT, TITLE, ESTATE, | LIEN, OR INTEREST IN THE REAL ESTATE | DESCRIBED IN THE COMPLAINT HEREIN, |                             Defendants. | The State of Washington to DEFENDANTS FRANCES E. SHAW, ENID TREVVINGER, and ALSO ALL OTHER PERSONS OR PARTIES UNKNOWN CLAIMING ANY RIGHT, TITLE, ESTATE, LIEN, OR INTEREST IN THE REAL ESTATE DESCRIBED IN THE COMPLAINT HEREIN:  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after the 14th day of March, 2023, and defend the above entitled action in the above titled court, and answer the complaint of the plaintiff MIDDLE BAR C, LLC, and serve a copy of your answer upon the undersigned attorneys for the Plaintiff Middle Bar C, LLC at its office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court.  This action arises from a complaint to quiet title in real property in Grant County, Washington.  Dated this 8th day of March, 2023. LUKINS & ANNIS, P.S. By /s/ Court A. Hall___________ TREVOR R. PINCOCK, WSBA #36818 COURT A. HALL, WSBA #54016 Attorneys for Plaintiff 717 W. Sprague Ave., Ste. 1600 Spokane, WA 99201 (509) 455-9555 #04001/6464 Pub: March 14, 21, 28, 2023 & April 4, 11, 18, 2023

NOTICE IS HEREBY GIVEN that a petition dated April 5, 2023, was filed with the Board of Directors of the East Columbia Basin Irrigation District by Loeffelbein Family Trust, the holders of title to all the land hereinafter described, prayed that the following described land be included within the District: South Half of the Southeast Quarter of Section 16, Township 20N, Range 30E, Parcel Number 181356010 Grant County;  All persons interested in or that may be affected by such inclusion of the land described above are hereby notified to appear at the office of the Board at Othello, Adams County, Washington, May 3, 2023, this being the regular meeting of the Board next after the last day of publication of this Notice of Hearing, and show cause in writing, if any they have, why such land should not be included within the District as prayed for in the petition. #04017/7213 Pub: April 11, 18, 25, 2023

NOTICE IS HEREBY GIVEN that a petition dated April 5, 2023, was filed with the Board of Directors of the East Columbia Basin Irrigation District by Kevin J. Lyle, the holders of title to all the land hereinafter described, prayed that the following described land be included within the District: North Half of the North Half of Section 10, Township 15N, Range 31E.W.M., Parcel Number 2531100110001 Adams County;  All persons interested in or that may be affected by such inclusion of the land described above are hereby notified to appear at the office of the Board at Othello, Adams County, Washington, May 3, 2023, this being the regular meeting of the Board next after the last day of publication of this Notice of Hearing, and show cause in writing, if any they have, why such land should not be included within the District as prayed for in the petition. #04018/7218 Pub: April 11, 18, 25, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD April 18, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider an Ordinance relating to the amendment of “Title 15, Fire Protection Districts” and the adoption of “Chapter 15 of the Grant County Code, Fire Protection and Administration”. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2495 751 5694), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #04028/7313 Pub: April 4, 11, 2023_____

NOTICE TO CONTRACTORS  LIONS PARK BASKETBALL COURT PROJECT  Othello, Washington  Sealed bids will be received at the Othello City Hall, 500 East Main Street, Othello, Washington 99344 until May 1, 2:00 pm, for the above-named improvement. Said bids will be opened and publicly read at that time. All bids shall be received before said opening time in sealed envelopes with LIONS PARK BASKETBALL COURT PROJECT marked plainly thereon.  All bids shall be accompanied by a deposit in the form of a postal money order, cashier’s check, or bond in an amount equal to 5 percent of the maximum total amount of the bid. Should the successful bidder fail to enter into a contract or furnish a satisfactory contract bond within the time stated in the specifications, the deposit shall be forfeited to the City.  Plans and specifications may be obtained at no cost via electronic transmission from the City of Othello. Paper copies of the plans and specifications may also be obtained from the City at the above address for a non-refundable fee of $50.00. Plans and specifications can be requested by responding to this email, or by calling the Contact person listed below during normal business hours. Copies of plans and specifications are on file for review at various construction councils.  All bidders shall call 509-331-2711 prior to bid opening to sign up as a bidder on the project, whether or not they request a hard copy or obtain a digital copy of the Specifications. Bids received from bidders who are not signed in as a bidder on the project will be rejected for being non-responsive.  Contact person:  Shawn O’Brien  PROJECT DESCRIPTION: This project consists of constructing four (4) concrete  basketball courts with landscaping improvements and an additive for lighting.  Estimated Project Cost: Base Bid $400,000; with Additive $525,000  The City Council reserves the right to reject any or all bids if such action is in the best interest of the City.  #04035/7544 Pub: April 11, 2023

Vanessa R. Waldref United States Attorney Brian M. Donovan Assistant United States Attorney Post Office Box 1494 Spokane, WA 99210-1494 Telephone: (509) 353-2767 UNITED STATES DISTRICT COURT EASTERN DISTRICT OF WASHINGTON UNITED STATES OF AMERICA, | | NO. 2:22-cv-00036-MKD | | Plaintiff, | | vs. | | LEE M. HERRING and SHEILA M. | HERRING, husband and wife, dba L&S | NOTICE OF UNITED STATES ORCHARDS; STATE OF | MARSHALS’ SALE OF REAL WASHINGTON, DEPARTMENT OF | PROPERTY LABOR & INDUSTRIES; BROOK | LAKE ORCHARDS, a Washington | corporation; LOIS RALSTON; RICK | ARMSTRONG and CHRISTINE | ARMSTRONG, husband and wife; | and DAVE PONOZZO and RANDIE | PONOZZO, husband and wife, | | | | Defendants. | TO: Lee M. Herring, Sheila M. Herring, L&S Orchards, State of Washington Department of Labor & Industries Brook Lake Orchards, Lois Ralston, Rick Armstrong, Christine Armstrong, Dave Ponozzo, and Randie Ponozzo The District Court for the United States of America for the Eastern District of Washington by virtue of an Amended Order of Foreclosure Sale dated, October 24, 2022, on a judgment rendered in said Court on September 27, 2022, has directed the undersigned to sell the property described below to satisfy a judgment in the above-entitled action. The property to be sold is as follows: The sale of the above described real property is to take place as follows: A. Real Property SECTION 2 TOWNSHIP 22 RANGE 28, THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER AND THAT PORTION OF GOVERNMENT LOT 5 LYING SOUTHERLY OF THE RIGHTOF-WAY OF THE U.S.B.R. MAIN CANAL AS SHOWN ON THE FARM UNIT PLAT OF IRRIGATION BLOCK 70, EIGHTH REVISION, COLUMBIA BASIN PROJECT, GRANT COUNTY, WASHINGTON, ACCORDING TO THE PLAT THEREOF FILED AUGUST 21, 1961, ALL IN SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M. EXCEPT THAT PORTION OF GOVERNMENT LOT 5 AND THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2 SAID POINT BEARS NORTH 01°0940"" EAST, 5300.00 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0040"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 229.26 FEET TO THE TRUE POINT OF BEGINNING; THENCE NORTH 01°0940"" EAST, PARALLEL TO THE WEST BOUNDARY OF SAID SECTION 2,785.92 FEET TO AN INTERSECTION WITH THE SOUTHERLY RIGHT-OF-WAY BOUNDARY OF THE U.S.B.R. MAIN CANAL; THENCE FOLLOWING SAID SOUTHERLY RIGHT-OF-WAY BOUNDARY THROUGH THE FOLLOWING TWO (2) COURSES; NORTH 83°0300"" EAST, 498.35 FEET; THENCE EASTERLY FOLLOWING A TANGENTIAL CURVE TO THE LEFT HAVING A CENTRAL ANGLE OF 24°4713"" AND A RADIUS OF 753.00 FEET, 325.76 FEET TO AN INTERSECTION WITH THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5; THENCE SOUTH 01°0845"" WEST ALONG THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5 AND THE EASTERLY BOUNDARY OF SAID SOUTH WEST QUARTER OF THE NORTHWEST QUARTER, 546.74 FEET; THENCE SOUTH 59°5311"" WEST, 24.58 FEET; THENCE SOUTH 63°1733"" WEST, 876.97 FEET TO THE TRUE POINT OF BEGINNING. AND TOGETHER WITH THAT PORTION OF THE NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER AND GOVERNMENT LOT 4, SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M., DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R. BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2, SAID POINT BEARS NORTH 01°0940"" EAST, 5300.10 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0940"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 1106.23 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 59°5311"" EAST, 24.58 FEET TO AN INTERSECTION WITH THE WEST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2 AND THE TRUE POINT OF BEGINNING; THENCE NORTH 59°5311"" EAST, 342.62 FEET; THENCE NORTH 76°1831"" EAST, 192.02 FEET; THENCE SOUTH 01°5345"" WEST, 788.26 FEET TO AN INTERSECTION WITH THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 88°1038"" WEST ALONG THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER, 468.30 FEET TO AN INTERSECTION WITH THE EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 01°0845"" EAST ALONG SAID EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, 555.69 FEET TO THE TRUE POINT OF BEGINNING. SUBJECT TO EASEMENT SEE DEED. AND THE FOLLOWING DESCRIBED IRRIGATION SYSTEM INCLUDING BUT NOT LIMITED TO THE FOLLOWING, INCLUDING ANY REPLACEMENT OF OR ADDITIONS TO SUCH SYSTEMS: COMPLETE SPRINKLER SYSTEMS WITH PUMPS, MAINS, SUB-MAINS, RISERS, SPRINKLERS, PLUGS, VALVES, AND FITTINGS. SUBJECT TO ALL OUTSTANDING EASEMENTS, RIGHTSOF-WAY, MINERAL LEASES, MINERAL RESERVATIONS, AND MINERAL CONVEYANCES OF RECORD. IN ADDITION TO FIXTURES, INCLUDING BUT NOT LIMITED TO, ALL IRRIGATION EQUIPMENT, PUMPS, PIPES, MAINLINE, SPRINKLERS, STORAGE FACILITIES, STORAGE FACILITIES, TANKS, BINS, FENCES, WIND MACHINES, AND SIMILAR GOODS AND INFRASTRUCTURE WHICH ARE NOW OWNED OR ACQUIRED IN THE FUTURE. ALL ADDITIONS, RE PLACEMENTS, SUBSTITUTIONS AND ACCESSORIES TO FIXTURES. Assessor’s Parcel No. 171179000. Property Address: 23663 Road J NE, Stratford, Grant County, Washington, 98853 B. Personal Property Wind machines, Irrigation equipment including but not limited to irrigation pumping equipment, irrigation pumps, irrigation pipes, and other irrigation equipment [located at the aforementioned real property]. (hereinafter collectively referred to as the “Property”). Time: 10:30 A.M. Date: March 10, 2023 Place: Grant County Courthouse 35 C Street NW Ephrata, Washington Minimum Bid: $351,775.08 The judgement debtor(s) can avoid the sale by paying the judgment amount of $341,658.71, plus interest at the applicable and legal rate until paid in full, and for the costs of suite, including the filing fee allowed pursuant to 28 U.S.C. 2412(a)(2), and other proper relief. For the exact amount, contact the Marshal at the address stated below: Craig Thayer United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 Redemption period: x The Real Property is subject to a Redemption period of one year which will expire at 4:30 p.m. on March 10, 2024.  No Redemption rights on Personal Property. The judgment debtor or debtor(s) or any of them may redeem the real property and fixtures at any time up to the end of the redemption period by paying the amount bid at the Marshal’s sale, plus additional costs, taxes, assessments and fees. If you are interested in redeeming the property contact the undersigned United States Marshal for the exact amount necessary to redeem. IMPORTANT NOTICE: IF THE JUDGMENT DEBTOR OR DEBTORS DO NOT REDEEM THE PROPERTY BY 4:30 p.m. ON THE 10th DAY OF MARCH, 2024 THE END OF THE REDEMPTION PERIOD, THE PURCHASER AT THE MARSHAL’S SALE WILL BECOME THE OWNER AND MAY EVICT THE OCCUPANT FROM THE PROPERTY UNLESS THE OCCUPANT IS A TENANT HOLDING UNDER AN UNEXPIRED LEASE. IF THE PROPERTY TO BE SOLD IS OCCUPIED AS A PRINCIPAL RESIDENCE BY THE JUDGMENT DEBTOR OR DEBTORS AT THE TIME OF SALE, HE, SHE, THEY, OR ANY OF THEM MAY HAVE THE RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD, IF ANY, WITHOUT PAYMENT OR ANY RENT OR OCCPANCY FEE. THE JUDGMENT DEBTOR MAY ALSO HAVE A RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD IF THE PROPERTY IS USED FOR FARMING OR IF THE PROPERTY IS BEING SOLD UNDER A MORTGAGE THAT SO PROVIDES. The successful bidder for the Property shall be required to deposit at the time of the same with the Marshal a minimum of ten percent of the bid, with the deposit to be made by certified or cashier’s check or cash payable to the United States District Court for the Eastern District of Washington. Before being permitted to bid at the sale, bidders shall display to the Marshal, or his/her representative, proof that they are able to comply with this requirement. No bids will be received from any person(s) who have not presented proof that, if they are the successful bidder(s), they can make the deposit required by this order of sale. The balance of the purchase price for the Property is to be paid to the Marshal within twenty days after the bid is accepted, by a certified or cashier’s check payable to the United States District Court for the Eastern District of Washington. If the bidder fails to fulfill this requirement, the deposit shall be forfeited and shall be applied to cover the expenses of the sale, including commissions due under 28 U.S.C. § 1921(c), with any amount remaining to be applied to the Judgment of the Defendant at issue herein. The Property shall be again offered for sale under the terms and conditions of this order of sale, or, in the alternative, sold to the second highest bidder. The sale of the Property shall be subject to confirmation by the Court. The Marshal shall file a report of sale with the Court, together with a proposed order of confirmation of sale and proposed deed, within thirty days from the date of receipt of the balance of the purchase price. On confirmation of the sale, the Marshal shall execute and deliver a certificate of sale. Upon the expiration of the redemption period, absent a redemption, the deed shall be executed and delivered immediately to the successful bidder. On confirmation of the sale, all interests in, liens against, or claims to, the Property that are held or asserted by all parties to this action are discharged and extinguished. Any party to this suit may become a purchaser at such sale. The United States may bid as a credit against its judgment without tender of cash. The sale will be “as is” and without warranty of any kind. DATED this 26th day of January, 2023. _______________________________ CRAIG THAYER United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 #02018/5061 Pub: February 3, 10, 17, 24, 2023___________________________________________

GRANT COUNTY WATER CONSERVANCY BOARD NOTICE OF APPLICATION FOR CHANGE OF GROUNDWATER CERTIFICATE G3-20015C(A) Notice of Application for Change of Water Right to change the point of withdrawal, place of use, purpose of use, and period of use under Groundwater Water Right No. G3-20015C(A). TAKE NOTICE: That on January 26, 2023, the City of Moses Lake filed application number GRAN-23-01 with the Grant County Water Conservancy Board (GCWCB) to change the point of withdrawal, place of use, purpose of use, and period of use under groundwater water right G3-20015C(A). That said right, G3-20015C(A), under priority date March 7, 1972, authorizes the withdrawal of 500 gallons per minute and 219.9 acre-feet per year for seasonal irrigation of 50 acres and 1.0 acre-feet per year for continuous domestic supply, from a well located within the SE¼ NW¼ Section 15, T. 20 N., R. 28 E.W.M. The existing place of use can be described as a portion of the N½ of Section 15, T. 20 N., R. 28 E.W.M., Grant County.  The applicant proposes to change the point of withdrawal and place of use to include 30 groundwater wells within the City of Moses Lake Water Service Area; one well exists in the in the SW¼NE¼ of Section 29, T. 19 N., R. 28 E.W.M. and a second well exists in the NW¼NE¼ of Section 27 T. 20 N., R. 28 E.W.M. The remaining 28 wells are to be constructed in the SW¼SE¼ and NE¼SW¼ of Section 4, NW¼ of Section 13, SW¼ and SE¼SE¼ of Section 14, NE¼NW¼, NW¼SW¼, and SW¼SE¼ of Section 15, SE¼NW¼ of Section 16, SE¼NE¼ of Section 22, NE¼SE¼ and SE¼NW¼ of Section 23, SW¼SE¼ of Section 25, SW¼SW¼ of Section 26, SE¼ and NE¼NW¼ of Section 27, SE¼ of Section 28, NW¼SW¼, S½, and SE¼SW¼ of Section 29, NE¼SW¼ of Section 33, all within T. 19 N., R. 28 E.W.M.; the NW¼ and SW¼ of Section 12 T. 18 N., R. 28 E.W.M.; the NW¼ of Section 16 and NW¼NW¼ of Section 20 within T. 19 N., R. 29 E.W.M.; and the SE¼NE¼, NE¼SE¼, NE¼NW¼ of Section 32 all within T. 20 N., R. 28 E.W.M. The place of use can be described as the City of Moses Lake Water System Boundary. The Applicant also proposes to change the period of use and purpose of use to year-round municipal supply. There are no changes to the total authorized quantity of water. Any protests or objections to the approval of this application may be filed with the Department of Ecology and must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-dollar ($50) recording fee and filed with the Cashiering Section, State of Washington, Department of Ecology, P.O. Box 47611, Lacey, Washington 98509-7611 within thirty (30) days from (February 17, 2023).  Any interested party may submit comments, objections, and other information to the GCWCB regarding this application. The comments and information may be submitted in writing or verbally at any public meeting of the Board held to discuss or decide on the application. Additionally, the Board will consider written comments or information  provided within thirty (30) days from February 17, 2023 of this notice, said written comments or information to be provided to its office located 2145 Basin Street SW, Ephrata, WA 98823. #02040/5358 Pub: February 10, 17, 2023

NOTICE TO MATERIAL SUPPLIERS  Sealed bids plainly marked “Bid for Asphalt Materials - 2023” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, March 1, 2023 and will then and there in the Public Meeting Room be opened and publicly read. If you have any questions about this procedure please call the Public Works Office in advance of the bid opening.:  Rob Harris  Assistant County Engineer  509-906-6415  rgharris@grantcountywa.gov  This contract provides for furnishing and delivering asphalt materials in accordance with the plans and specifications.  Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823.  The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County.  The improvement for which bids will be received follows:  Asphalt Materials - 2023  This proposal provides for furnishing 4,000-6,000 tons of HFE-150 liquid asphalt, 500 - 700 tons of HFE-90 liquid asphalt and 6000 - 8,000 tons of Hot Mix Asphalt for the 2023 season to Grant County and other work in accordance with the specifications.  #02043/5423 Pub: February 10, 15, 17, 22, 24, 27, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF BABY BOY DIAZ CASE NO. 22-7-00253-13 DOB: 11/25/2021 MINOR CHILD. NOTICE OF SUM-MONS BY PUBLICATION (TERMI-NATION) TO: Jessica Diaz, Valentin Diaz Medina and anyone claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 11/10/2022. A Fact-Finding Hearing will be held 06/06/2023 at 9:00 a.m. This hear-ing will be held via WebEx in Superior Court of Washington, Grant County Juve-nile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for in-structions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be required to observe social distancing and facial mask guide-lines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE HEARING WILL DETERMINE IF YOUR PARENTAL RIGHTS TO YOUR CHILD ARE TERMINATED. IF YOU DO NOT APPEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE TERMINATING YOUR PARENTAL RIGHTS. To request a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View infor-mation about your rights in this proceed-ing at www.atg.wa.gov/DPY.aspx Dated this 25th day of January 2023. /s Deputy Clerk #05019/8299 Pub: May 1, 8, 15, 2023___

NOTICE OF SPECIAL BOARD OF TRUSTEES MEETING A special meeting of the NCW Libraries Board of Trustees is being called on May 11, 2023, from 8am - 5pm. The meeting will be held at the Community Foundation of North Central Washington, located at 9 S. Wenatchee Ave, Wenatchee. The purpose of the special meeting is to hold a board retreat and to conduct the monthly financial business of the board. Pursuant to RCW 42.30 the meeting is open to the public. Any member of the public interested in attending should email board clerk Sharon Mauch at smauch@ncwlibraries.org. The previously scheduled May 18, 2023 of the NCW Libraries Board of Trustees is cancelled. #05032/8851 Pub: May 15, 2023

The Moses Lake City Council adopted the following ordinance at their meeting held on May 9, 2023. The full text of this ordinance is available on the city’s website www.cityofml.com and can be mailed or emailed upon request by contacting the City Clerk’s Office at 509-764-3703 or cityclerk@cityofml.com. ORDINANCE NO. 3024 AN ORDINANCE OF THE CITY OF MOSES LAKE, WASHINGTON, APPROVING THE MITCHELL DEVELOPMENT II LLC DEVELOPMENT AGREEMENT REGARDING THE “THE REFUGE AT MAE VALLEY FIRST ADDITION” MAJOR SUBDIVISION The ordinance authorizes a development agreement to use a portion of the Well 31 property for a safe street design pursuant to condition stated during approval of the subdivision.   #05034/8877 Pub: May 15, 2023

City of Moses Lake Notice of Public Hearing Shoreline Substantial Development Permit The Moses Lake Planning Commission will hold a public hearing on June 8, 2023, at 6:00 pm to consider an application for a Shoreline Substantial Development Permit (SSDP). The applicant is requesting the SSDP to install a retaining wall within Moses Lake shoreline jurisdiction. The retaining wall will be on the southwest side of the property. Sand will be removed with a mini track hoe and the retaining wall will be 25’ from the shoreline. The retaining wall will be 80’ lineal feet, 6” wide and about 4’ to 6’ tall. There will be drain rock and drainpipe placed and then back filled with sand. The property is located at 509 Astro Loop in Moses Lake, WA. This is Lot 14, Block 3 of the Westlake Shores Phase III Plat. For more information or to review the application materials contact Amy Harris at 509-764-3747. Submit written comments by mail to City of Moses Lake Community Development Department, Attn: Amy Harris, P.O. Box 1579, Moses Lake, WA 98837. Written comments will be accepted until June 7, 2023, at 5:00 pm. Any member of the public may testify before the Planning Commission during the hearing. The hearing will take place in the Council Chambers of the Civic Center, 401 S. Balsam St, Moses Lake WA. Date of Notice: May 9, 2023 #05035/8904 Pub: May 15, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Grant Orchards Fence”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until 1:00 P.M., Tuesday, March 21, 2023 and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Grant Orchards Fence This contract provides for furnishing and installing approximately 2,000 linear feet of 6 (six) foot tall chain link fence and other work, on the property line of the Grant County Public Works Grant Orchard shop, located at 19956 Road A.8 NE, Grant County Parcel #141404000, in Grant County, WA, all in accordance with the attached Contract Plans, these Contract Provisions and the Standard Specifications. #03017/6178 Pub: March 6, 9, 13, 16, 20, 21, 2023

BEFORE THE HONORABLE BOARD OF COUNTY COMMISSIONERS OF GRANT COUNTY, WASHINGTON In the matter of the Application of  NOTICE OF HEARING  ON  Intermountain Infrastructure Group LLC APPLICATION FOR A COUNTY ROAD FRANCHISE for a franchise to construct, operate and maintain Fiber Telecomunications on certain County Road Rights-of-Way within the County of Grant, State of Washington, for the purpose of carrying water. NOTICE IS HEREBY GIVEN that Intermountain Infrastructure Group LLC, has filed with the Board of County Commissioners of Grant County, Washington, an application for a franchise for a period of fifty (50) years to construct, operate and maintain a fiber telecommunications facility across certain County roads in Grant County, Washington lying within the following described portion of the County, to-wit: Route 1  Location begins on the South side of Road 20 NE and the East side of the City of Soap Lake. Route continues on the South side of Road 20 NE to Stratford Road NE. Route continues North on the East side of Stratford Rd. NE until Road 22NE. Route continues East on the south side of Road 22 NE until HWY 28. Route continues East on the south side of Wilson Creek Loop T:22N R:27E S: 19,25,26,27,28,29,30 T22N: R:28E S:13,14,23,26,27,28,29,30 T:22N R:29E: S:2,3, 10,11,16,17,18, Route 2 Location begins on West side of Road R NE (Black Rock Road) and continues South until Road 19 NE. Rout continues East on South side of Road 19 NE until the Grant County/ Lincoln Line T:22N R:29E S: 13 T:22N R:30E S: 18,19,30,31,32,33,34,35,36 ------------------------------------------------------------------------------------------------------------------ Route 1  Location begins on South side of Road K NW and 11.5 NW (15 feet South of 11.5 NW Centerline) goes East to Road H NW. It will continues on the East side of Road H NW (15 Feet East of Road H NW Centerline) to Martin Rd. NW (15 feet South of Martin Rd. NW Centerline). It will continue on Martin Rd. NW to HWY 28.Within, T: 20N R: 25E S: 3,4,5, T: 21N R: 25E S:35,36 T: 21N R: 26E S: 29,31,32 Route 2 Location begins on East side of Dodson Rd NW and Road 14 NW and continues North until the City of Ephrata boundary. T: 21N R: 26 E S: 21 Route 3 Location begins on the East side of Road B NW and continues North to Road 20 NE. route turns east on the South side of Road 20 NE until the boundary of the city of Soap Lake. T: 21N R:26 S:2,3 T:22N R:26E S: 22,23,24,27,34, NOTICE IS FURTHER GIVEN that the Board of County Commissioners of Grant County, Washington, has fixed the hearing on said application for the franchise for the 28th day of March, 2023 at 3:15 p.m. in the Board of County Commissioners’ room in the Grant County Courthouse in Ephrata, Grant County, State of Washington, and any person may appear at this time and place to be heard for or against the granting or denying of said franchise or any part thereof. Webex virtual meeting is also available by calling 1-408-418-9388 using access code 2486 236 7798. DATED this 03 day of March 2023. Michele Jaderlund, Auditor of Grant County, Washington   By:_/s/Michele Jaderlund____________________ Auditor               #03020/6201 Pub: March 13, 20, 2023

City of Warden Notice of Application  Notice of SEPA Optional Determination of Nonsignificance NOTICE IS HEREBY GIVEN THAT the City of Warden has determined that the amendment to Lot 4 of the Port of Warden No. 5 Short Plat, Industrial Binding Site Plan is not likely to result in significance adverse environmental impacts and will be issuing an Optional Determination of Nonsignificance. Project Description: non-project action requesting an amendment to Lot 4 of the Port of Warden No. 5 Short Plat, Industrial Binding Site Plan. This proposal would create two(2) additional lots by amending Lot 10 and Lot 14 of the existing binding site plan. Project Location: Lots 10 and 14 of the existing binding site plan, parcel Nos. 06-1713-410 and 06-1713-414.  Township: A portion of the W ½ of section 16, Township 17 North, Range 30 East W.M.  City: Warden County: Grant Pursuant to WAC 197-11-355, The City of Warden is issuing an Optional Determination of Non significance process. The option enables the comment period for the environmental review and notice of application to be integrated. This may be the only opportunity to comment on the environmental impacts of the proposal. A copy of the threshold determination for this proposal may be obtained upon request to the City of Warden. This information is available to the public and may be reviewed at City of Warden City Hall or you may inquire regarding this determination by calling 509-859-2943, during normal business hours. Brandon Mauseth  Responsible Official #03023/6445 Pub: March 13, 2023

ADVERTISEMENT FOR BIDS Sealed bids will be received by the Board of Directors of Moses Lake School District No. 161 in the school district Board Room at the Central Washington Region Transportation Cooperative, 940 E. Yonezawa Blvd., Moses Lake, Washington for construction of the VANGUARD ACADEMY – RFID SYSTEM as follows: Prime bidders shall submit their Basic Bid proposals in a sealed envelope up until 3:00 p.m., Tuesday, March 28, 2023. Basic Bid proposals will be opened and publicly read immediately after submittal of proposals. Proposals received after the above times may not be considered. Optional Pre-Bid Conference: An optional pre-bid conference will be held at 3:00 p.m., Tuesday, March 14, 2023, commencing at the project site, 740 E. Yonezawa Blvd., Moses Lake, Washington. The meeting will convene outside the Vanguard Academy administration office. Drawings and Specifications will be available on or after Monday, March 6, 2023 at www.nacplans.com and may be examined at the following locations: NAC Architecture, 1203 West Riverside, Spokane, WA 99201; Abadan Regional Plan Center, 603 E Second Street, Spokane, WA 99202. Bidders may download digital files at no cost. Printed documents are available by choosing the “Order” option. Bona Fide Prime Contractors, licensed in the State of Washington may receive up to 2 full sets of “Refundable Documents” upon deposit of $100.00 per set. Make checks payable to NAC Architecture and mail to Abadan Reprographics, 603 East 2nd Avenue, Spokane, WA 99202. Deposit will not be returned if documents are mutilated or so marked that they are not reusable and/or if they are not returned to the Architect within ten (10) days after bids are received. Additional or partial sets may be purchased, at bidders’ expense, (non-refundable), from www.nacplans.com or a printer of the bidders’ choosing. Bidders wishing to be formally listed as a plan holder must log in and choose “Add me as a Plan Holder” at www.nacplans.com, where a current plan holder list is continually posted. Any questions regarding www.nacplans.com shall be directed to plan center services, 509-747-2964 or repro@abadanspokane.com. No bidder may withdraw its bid after hour set for opening thereof, unless award is delayed for a period exceeding 45 days. The Board of Directors of Moses Lake School District No. 161 reserves the right to reject any or all bids and to waive informalities. Individuals with disabilities who may need a modification to participate in a meeting should contact the Owner at (509) 766-2650, no later than three days before the bid opening and as soon as possible in advance, so that arrangements can be made. By order of: Board of Directors of Moses Lake School District No. 161. #03025/6461 Pub: March 13, 20 2023

Notice of Application, Proposed MDNS, and Public Hearing: March 13, 2023 Notice is hereby given that a Conditional Use Permit Application and SEPA Checklist were received by Grant County on January 18, 2019 from O’Sullivan Storage LLC (Designated Contact: CAD Homes LLC, PO Box 2330, Moses Lake, WA, 98837) and were found to be Technically Complete on March 9, 2023. Grant County expects to issue a Mitigated Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used.] This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROPOSED MITIGATION MEASURES: The landowners/applicants are responsible to determine if any other permits and/or licenses will   be required by other local, state, and federal agencies. The landowners/applicants shall acquire    all such permits and/or licenses as required. 2. Best Management Practices (BMPs) shall be utilized as necessary during development and implementation of this proposal in order to minimize temporary disturbances to the subject      area, to lessen the risk of erosion, and to stabilize the site during construction. Proper erosion    and sediment control practices must be used to prevent upland sediments from entering surface water. Dust and emissions to the air will be controlled by using water on-site for dust control as needed. 3. All development shall be installed in such a manner so as to prevent run-off from the site from entering adjoining properties. Surface water run-off must be contained and absorbed on-site. 4. The proposed development shall not inflict upon adjacent land(s) smoke, dust, glare, dirt, steam, vibration, noise, electrical interference, excessive hazards, odors, or pollution which exceeds applicable local, state, or federal standards. PROJECT: A Conditional Use Permit and SEPA checklist proposing the construction of six (6) mini-storage structures. Storage units will varying size and are anticipated to be approximately 22,200 Sq. Ft. of total building area on a 1.19 acre parcel. STUDIES REQUIRED: None. LOCATION: The subject parcel is located in the 6900 Block of Washington State Route 262 E Othello near the Potholes Resort Community the land is further described as being in the Northeast quarter of Section 18, Township 17 North, Range 28 East, Willamette Meridian, Grant County, WA. Parcel #17-0020-000. ZONING: Rural Community (RC).  ADDITIONAL PERMITS: Highway Access Permits, SEPA Environmental Checklist.  PUBLIC HEARING: Grant County Hearings Examiner tentatively scheduled for Wednesday, April 12, 2023 at 12:00 pm in the Commissioners Hearing Room at the Grant County Courthouse in Ephrata, WA. At this time, any person(s) may provide testimony for the hearing. Members of the public may also be present in the hearing room in limited numbers. Grant County is providing access to this scheduled hearing for the public via WebEx audio connection. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2482 325 5405), you will be joined to the meeting in a ‘muted’ status until the hearing allows for public testimony. If you have any questions about this procedure please call Development Services in advance of the hearing. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials (Files P23-0027 and P23-0028) are available from Kent Ziemer, (kziemer@gratncountywa.gov), Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538. Office hours: 8 am to 5 pm, M–F. Comments must be submitted to the Planning Department no later than 5 pm on March 27, 2023. Comments should be as specific as possible and may be mailed, electronic email or hand-delivered. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials #03024/6462 Pub: March 13, 2023______

Notice of Application and Public Hearing: March 13, 2023 Notice is hereby given that a Conditional Use Permit Application and SEPA Checklist were received by Grant County on February 14, 2023 from CPM Development Corp Attn: Jana McDonald and were found to be Technically Complete on March 9, 2023. Grant County expects to issue a Mitigated Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used.] This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROPOSED MITIGATION MEASURES: 1. The proposed development shall not inflict upon adjacent land(s) smoke, dust, glare, dirt, steam, vibration, noise, electrical interference, excessive hazards, or pollution which exceeds applicable local, state, or federal standards. 2. Existing vegetation will be removed from the site during mining operations. The site shall subsequently be replanted according to the approved Washington State Department of Natural Resources Reclamation Plan. 3. If any Native American Grave site(s) or archaeological/cultural resources (Indian Artifacts) are found all construction activity shall stop and the owner/developer shall immediately notify the Grant County Planning Department, the Colville Confederated Tribes and the Washington State Office of Archaeology and Historic Preservation. 5. Best management practices as specified by the Department of Ecology to mitigate fugitive dust and noise have been and will continue to be used for the duration of mining. PROJECT: A Conditional Use Permit and SEPA to allow the establishment of a surface mine and extraction operation for sand products. Approximately 250,000 cubic yards of material are estimated to be removed from this site, which will involve 40 acres on a vacant parcel. Currently there are no activities at the location. The site has also been assessed for cultural resources and an Inadvertent Discovery Plan is included in the application materials. A Wildlife Habitat Management Plan has a/so been developed in coordination with WDFW for Shrubsteppe and Mule Deer. STUDIES REQUIRED: None. LOCATION: The site address of the subject parcel would be in the 6300 block of Road 4 SW. The site is located approximately 9 miles north of Royal City.  The site is the northeast ¼ of Section 24, Township 18 N, Range 25 E, W.M., Grant County, WA Parcel #15-1670-000. ZONING: Rural Resource. PUBLIC HEARING: Grant County Hearings Examiner scheduled for Wednesday, April 12, 2023 at 12:00 pm in the Commissioner’s Hearing Room on the bottom floor of the Grant County Courthouse in Ephrata, WA. At this time, any person(s) may provide testimony for the hearing. Grant County is providing access to this scheduled hearing for the public via Webex audio connection only, members of the public may be present in the hearing room. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code, 2482 325 5405, you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure please call Development Services in advance of the hearing. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials (File #P23-0053 & P23-0054) are available from Kent Ziemer, (kziemer@gratncountywa.gov) Grant County Planning Department, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538. Office Lobby hours: 8 am – 5 pm, M-F. Comments must be submitted to the Planning Department no later than 5 pm on March 27, 2023. Comments should be as specific as possible and may be mailed, hand-delivered, or sent by email. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials.  #03026/6466 Pub: March 13, 2023

OFFICIAL NOTICE FOR NOMINATION OF MEMBERS TO THE WASHINGTON OILSEED COMMISSION Pursuant to chapter 15.65 RCW, notice is given that a call-in public meeting will be held from 10:00 a.m. – 11:00 a.m. on March 23, 2023 to nominate candidates for positions 1 and 3 on the Washington Oilseeds Commission. Nominations may be made by calling (360) 902-1887. Notice of this meeting has been mailed to all affected producers entitled to nominate a candidate. For more information regarding how to submit a nomination by mail or the nomination process/meeting, please contact Megan Finkenbinder at (360) 902-1887 or mfinkenbinder@agr.wa.gov.  Dated at Olympia, Washington this 13th day of March, 2023. Derek I. Sandison, Director Washington State Department of Agriculture #03027/6467 Pub: March 13. 2023

CITY OF WARDEN CITY COUNCIL NOTICE OF HEARING In The Matter of: APPEAL OF NONCONFORMING USE CONTINUATION DECISION 720 S. Pine Street Jonathan and Brittney Pittman To Appellant: Mr. Zachary W. Acres RIES LAW FIRMM, P.S. P.O. Box 2119 Moses Lake, WA 98837 Pursuant to Warden Municipal Code Section 17.69.010, the Appellant, Jonathan and Brittney Pittman, have filed an appeal of the October 26, 2022, decision of the City Planning Agency to continue the nonconforming use at 720 S. Pine St., Warden, WA, with conditions. The hearing before the City Council is scheduled to occur on Tuesday, May 23rd, 2023, at 7:00 p.m., at the Warden City Council Chambers, 201 South Ash Street, Warden, WA, 98857. The Appellant shall contact the City Administrator at least one week prior to the hearing if the Appellant needs an interpreter present at the hearing at (509) 349-2326 Ordered this 19th day of April, 2023. /s/Kristine Shuler______ Kristine Shuler, City Administrator #05022/8465 Pub: May 5, 2023

NOTICE OF PUBLIC HEARING - CITY OF MOSES LAKE CITY COUNCIL ** REVISED NOTICE ** 6:30 P.M. ON TUESDAY, MAY 23, 2023 MOSES LAKE COUNCIL CHAMBERS - MOSES LAKE CIVIC CENTER 401 S BALSAM ST, MOSES LAKE, WA 98837 The City Council of the City of Moses Lake invites all interested parties to attend a Public Hearing on May 23, 2023, at 6:30 p.m. to offer testimony on amending the following development regulations within the Moses Lake Municipal Code (MLMC): MLMC 16.02.020 Building Codes Adopted. Changing the threshold to obtain a grading permit from 5,000 cu yds to 500 cu yds. MLMC 16.02.045 Building Prior to Filing Final Plat. Establishing the conditions to obtain a building permit for a single-family structure on a preliminary plat. MLMC 16.02.050 State Building Code Amendments. Referencing the biannual state adopted building code amendments. MLMC 17.12.170 Recording Final Major Plat. Designating the City Manager to sign final major plats upon approval of the Hearing Examiner. MLMC 17.18.070 Binding Site Plan - Final Recording. To provide a one-year time frame for taking action on the approved permit. MLMC 20.07.010 Required Public Notice. Resolve code conflicts and increase public participation via neighborhood mailings. MLMC 20.07.020 Notice of Public Hearing. Minor edits to clarify existing provisions. MLMC 20.09.015 Neighborhood Meetings. Requirements to be repealed. MLMC 18.30.030 D. Land Uses In Commercial Zones Table. Amend the uses in Commercial Zones Table to permit Municipal Facilities, including emergency services buildings in the C-2 Commercial Zone with a Conditional Use Permit. MLMC 18.40.030 E. Table 1: Land Uses in Industrial zones. Amend the uses in the Industrial Uses Table to allow mini-storage facilities to be located in the Heavy Industrial zone as an outright use. Persons interested in receiving copies of the draft proposals, legal descriptions and/or the final decision (upon issuance) may review them during normal business hours at 321 S Balsam Street. For more information contact Nathan Pate, AICP, via email planning@cityofml.com or call 509-764-3752. Interested persons may provide testimony either in writing or by participating in the Public Hearing. The form to register to speak at the meeting will also be on the posted agenda, or you can contact the City Clerk’s Office to receive the form in advance. The speaker request form must be completed no later than 3 p.m. on the day of the meeting to speak remotely. Written comments can also be delivered to the City Council prior to the Public Hearing, via mail to the City of Moses Lake, Attn: City Clerk’s Office, PO Box 1579, Moses Lake, WA, 98837, or via email before 3 p.m. on the day of the meeting at cityclerk@cityofml.com. #05024/8500 Pub: May 5, 2023

Mobile home lien foreclosure public action Air stream spartan serial: 343551555 May 11th 2023 2022 W Broadway #24 Moses Lake, WA 98837 #05025/8506 Pub: May 5, 8, 2023

ADVERTISEMENT FOR BIDS WATER MAIN IMPROVEMENTS  City of Royal City, Washington 445 Camelia Street NE/P.O. Box 1239 Royal City, Washington 99357 General Notice The City of Royal City, Washington (Owner) is requesting Bids for the construction of the following Project: Water Main Improvements. Bids for the construction of the Project will be received at the City of Royal City, City Hall located at 445 Camelia Street NE, Royal City, Washington, 99357 until 2:00 p.m. local time, May 31, 2023. At that time the Bids received will be publicly opened and read. The Project includes the following Work: Installation of approximately 380 linear feet of 6-inch diameter water main, 7,200 linear feet of 8-inch diameter water main, 3,600 linear feet of 12-inch diameter water main, gate valves, butterfly valves, water service pipe and connections, water meter relocation, fire hydrants, air release valve assembly, surface restoration, and other miscellaneous work required to complete the Project as shown on the Drawings and as specified. The Work may include one or more Additive Alternatives which include the installation of approximately 100 linear feet of 6-inch diameter water main, 2,430 linear feet of 8-inch diameter water main, gate valves, water service pipe and connections, water meter relocation, fire hydrants, surface restoration, and other miscellaneous work. This Project is being funded in part through USDA Rural Development and the Washington State Community Development Block Grant program with federal funds from the U.S. Department of Housing and Urban Development. Because the Project is being paid for by federal funds, all Work will be subject to all federal and state requirements relating to the use of such funds, including the Davis-Bacon Wage Rates or Washington State Prevailing Wage Rates for Public Works Projects, EEO, Washington State Contracting Laws, etc. All Work performed on this project will be subject to the higher of the state or federal wage rates. Bid security is required and shall be furnished in accordance with the Instruction to Bidders. The Work shall be substantially completed within 160 calendar days. Obtaining the Bidding Documents Bidding Documents are available at http://www.andersonperry.com under the Bid Docs link. The digital Bidding Documents may be downloaded for a non-refundable payment of $30.00 by inputting QuestCDN eBidDoc Number 8436707 on the website. Assistance with free QuestCDN membership registration, document downloading, and working with the digital Project information may be obtained at QuestCDN.com, at 952-233-1632, or via e-mail at info@questcdn.com. The Bidding Documents will be available for download on May 8, 2023. No paper sets will be provided for bidding purposes. Prospective Bidders are urged to register with the designated website as a plan holder, even if Bidding Documents are obtained from a plan room or source other than the designated website in either electronic or paper format. The designated website will be updated periodically with addenda and other information relevant to submitting a Bid for the Project. All official notifications, addenda, and other Bidding Documents will be offered only through the designated website. Neither Owner nor Engineer will be responsible for Bidding Documents, including addenda, if any, obtained from sources other than the designated website. The Issuing Office for the Bidding Documents is: Anderson Perry & Associates, Inc. Bill Vixie, P.E. P.O. Box 1687/214 E. Birch Street, Walla Walla, Washington 99362 509-529-9260, bvixie@andersonperry.com Prospective Bidders may examine the Bidding Documents at the Issuing Office on Monday through Friday between the hours of 8:00 a.m. and 5:00 p.m. or at the location listed below. City of Royal City, 445 Camelia Street NE, Royal City, Washington  The Owner may reject any bid not in compliance with all prescribed requirements and may reject for good cause any and all bids upon finding that it is in the public interest to do so. The Owner is an equal opportunity and affirmative action employer. Small, minority and women-owned businesses are encouraged to submit bids. Small minority and women-owned businesses should indicate they are a minority on the Planholders List. Pre-bid Conference A pre-bid conference will not be held. Instructions to Bidders For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents. American Iron and Steel Section 746 of Title VII of the Consolidated Appropriations Act of 2017 (Division A - Agriculture, Rural Development, Food and Drug Administration, and Related Agencies Appropriations Act, 2017) and subsequent statutes mandating domestic preference applies an American Iron and Steel requirement to this project. All iron and steel products used in this project must be produced in the United States. The term “iron and steel products” means the following products made primarily of iron or steel: lined or unlined pipes and fittings, manhole covers and other municipal castings, hydrants, tanks, flanges, pipe clamps and restraints, valves, structural steel, reinforced precast concrete, and Construction Materials. The following waivers apply to this Contract: De Minimis, Minor Components, Pig iron and direct reduced iron. This Advertisement is issued by: Owner: City of Royal City, Washington By: Kent Andersen  Title: Mayor Published: Columbia Basin Herald, Fridays May 5, 2023, and May12, 2023 #05027/8529 Pub: May 5, 8, 2023

A board seat on the Columbia Basin Conservation District is available for appointment by the Washington State Conservation Commission. Conservation district board supervisors are public officials who serve without compensation and set policy and direction for the conservation district. An applicant must be a registered voter in Washington State and may be required to own land or operate a farm. Applicants for appointed positions do not have to live within the district to apply. For more information, please contact the Columbia Basin Conservation District or read the Guide to Appointment for Conservation District Applicants (https://assets.website-files.com/5ec2d4f7da309c68cdc0655a/5f36cfa9fb8e3e5d59ceaee9_CD-appointment-guide.pdf ) which can be found on the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). To apply, use this direct link (http://www.formstack.com/forms/?1918463-JfwJs6JKCL) or please visit the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). Applications and supporting materials must be received by the Conservation Commission no later than March 31, 2023. #03004/5884 Pub: February 24, 2023 & March 3, 10, 17, 2023.

Hilmes Construction, Inc., Stewart Hilmes, 1716 S Broadway Ave Othello, WA 99344, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Knolls Vista Major Subdivision, is located at Parcel Numbers 11-0625-001, 11-0621-000, 11-0625-002 in Moses Lake in Grant county. This project involves 6.65 acres of soil disturbance for Highway or Road, Residential, Utilities construction activities. All discharges and runoff goes to ground water. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696 #03005/5905 Pub: February 24, 2023 & March 3, 2023

SUPERIOR COURT OF WASHINGTON FOR LINCOLN COUNTY In the Matter of the Estate ) ) No. 23-4-00017-22      of ) ) PROBATE NOTICE TO WILLA J. EVERS, ) CREDITORS ) RCW 11.40.030           Deceased  ) ) _____________________ ) The Personal Representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent that arose before the decedent’s death must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorneys at the address stated below a copy of the claim and filing the original of the claim with the Clerk of this Court. The claim must be presented within the later of (1) thirty days after the Personal Representative served or mailed the Notice to the Creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of this notice. If the claim is not presented within this time frame, the claim will be forever barred, except as otherwise provided in RCW Section 11 and RCW 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: 03/03/2023 Personal Representative: CHARLES L. EVERS Attorney for P.R.: Norman D. Brock Address for Mailing or Service: Brock Law Firm, P.S. 111 S. Post St., Ste. 2280 Spokane, Washington 99201 /s/Charles L. Evers Charles L. Evers Personal Representative #03014/6146 Pub: March 3, 10, 17, 2023

SUPERIOR COURT OF WASHINGTON FOR LINCOLN COUNTY In the Matter of the Estate ) ) No. 234 00017 22      of ) ) NOTICE OF APPOINTMENT WILLA J. EVERS, ) AND PENDENCY OF ) PROBATE           Deceased  ) ) _______________________ ) Notice is hereby given that, on February 22, 2023, the undersigned was appointed Personal Representative of the above estate and that probate proceedings are pending. DATED this __16___ day of February , 2023. /s/ Charles L Evers Charles L. Evers Personal Representative #03015/6147 Pub: March 3, 2023

GRANT COUNTY WATER CONSERVANCY BOARD NOTICE OF APPLICATIONS FOR CHANGE OF GROUNDWATER SUPERCEDING CERTIFICATE G3-01508C(G)  Notice of Applications for Change of Water Right to change the point of withdrawal, place of use, period of use, and purpose of use under Groundwater Water Right No. G3-01508C(G). TAKE NOTICE: That on November 22, 2022, Dove Haven Homeowners Associations (HOA) No. 1 and No. 2 filed application numbers GRAN-22-04 and GRAN-22-05, respectively, with the Grant County Water Conservancy Board (GCWCB) to change the point of withdrawal, place of use, period of use, and purpose of use under Groundwater Water Right No. G3-01508C(G). That said right, G3-01508C(G), under priority date August 5, 1964, authorizes the withdrawal of 500 gallons per minute (gpm) and 240 acre-feet per year (AF/yr) for seasonal irrigation of 75 acres from one point of withdrawal well located within the SE¼ SE¼ of Section 8, T. 20 N., R. 28 E. on Grant County parcel 170921000. The existing place of use is the E½ SW¼, W½ SE¼, and SE¼ SE¼ of Section 8, T. 20 N., R. 28 E. on Grant County parcel 170921000. Under GRAN-22-04, Dove Haven HOA No. 1 is seeking to transfer 15.2 gpm and 7.3 AF/yr from G3-01508C(G) to Dove Haven Acres Lots 2 through 17 (parcels 120136766, 120136767, 120136768, 120136769, 120136770, 120136771, 120136772, 120136773, 120136774, 120136775, 120136776, 120136777, 120136778, 120136779, 120136780, and 120136781) in the W½ NE¼ of Section 2, T. 19 N., R. 28 E. The purpose and period of use of the portion proposed for transfer to Dove Haven HOA No. 1 will be changed from seasonal irrigation to continuous potable supply. The proposed point of withdrawal consists of two wells located on Grant County parcels 120136791 and 120136792 in the W½ NE¼ of Section 2, T. 19 N., R. 28 E.  Under GRAN-22-05, Dove Haven HOA No. 2 is seeking to transfer 5.7 gpm and 2.7 AF/yr from G3-01508C(G) to Dove Have Acres Lots 20 through 25 (parcels 120136784, 120136785, 120136786, 120136787, 120136788, and 120136789) in the SE¼ NE¼ of Section 2, T. 19 N., R. 28 E. The purpose and period of use of the portion proposed for transfer to Dove Haven HOA No. 2 will be changed from seasonal irrigation to continuous potable supply. The proposed PoW consists of one well located on Grant County parcel 120136790 in the SE¼ NE¼ of Section 2, T. 19 N., R. 28 E.  The portion of G3-01508C(G) to remain at the existing location following approval of these two change applications is in quantities of 479.1 gpm and 230.0 AF/yr for seasonal irrigation of 71.9 acres. There will be no changes to the place of use or point of withdrawal for the remaining portion of G3-01508C(G).  Any protests or objections to the approval of these applications may be filed with the Department of Ecology and must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-dollar ($50) recording fee and filed with the Cashiering Section, State of Washington, Department of Ecology, P.O. Box 47611, Lacey, Washington 98509-7611 within thirty (30) days from March 10, 2023.  Any interested party may submit comments, objections, and other information to the GCWCB regarding these applications. The comments and information may be submitted in writing or verbally at any public meeting of the GCWCB held to discuss or decide on these applications. Additionally, the GCWCB will consider written comments or information provided within thirty (30) days from March 10, 2023, said written comments or information to be provided to its office located 2145 Basin Street SW, Ephrata, WA 98823.   #03016/6164 Pub: March 3, 10, 2023

VENDOR ROSTER   Columbia Basin Hydropower is preparing a vendor roster for purchases costing less than $50,000 for materials, supplies, equipment and services to be used in maintaining its hydroelectric power projects. To be on the roster, submit business name and contact information to: info@cbhydropower.org. #03033/6524 Pub: March 23, 30, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF KING In the Receivership of: | | CASE NO: 23-2-02688-8 SEA | SOLSTICE GROUP, INC., and | NOTICE TO CREDITORS OF SOLSTICE HOLDINGS, INC. | RECEIVERSHIP | | [for publication] ____________________________________| PLEASE TAKE NOTICE that pursuant to the Order Appointing General Receiver entered by this Court on February 10, 2023, TurningPointe, LLC has been appointed General Receiver (“Receiver”) over all assets of Solstice Group, Inc., and Solstice Holdings, Inc., whose last known address is 640 S. Spokane St., Seattle, WA. Claims. All persons and businesses who believe they are owed money related to the Property on account of any goods, services or credit provided to the Property before February 10, 2023, must complete the Proof of Claim Form available through the receiver’s attorney. Creditors who fail to timely file a claim will not share in any distributions, should funds become available. The Proof of Claim Form must be returned to the Receiver’s counsel at the address listed below no later than 30 days from the date of this notice. If you are a state agency, you must file proof of claim with the receiver within 180 days after the date of this notice. RECEIVER: TurningPointe, LLC ATTORNEYS FOR RECEIVER: Dominique R. Scalia, WSBA No. 47313 DBS Law 155 NE 100th St., Suite 205 Seattle, Washington 98125 (206) 489-3802 #3038/6603 Pub: March 16, 23, 30, 2023

Fisher Construction Group, Inc., Chris Lang, 625 Fisher Ln Burlington, WA 98233-3431, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Simplot Moses Rainier HBF 23F012, is located at Northeast of Rd. O and Rd. 2 NE Intersection Parcel #180217000 & 180218000 in Moses Lake in Grant county. This project involves 91.6 acres of soil disturbance for Industrial construction activities. The receiving waterbody is Existing Wetland. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696 #05040/8969 Pub: May 18, 25, 2023

NOTICE OF STATE ENVIRONMENTAL POLICY ACT (SEPA) DETERMINATION OF NON-SIGNIFICANCE The City of Royal City has issued a Determination of Non-Significance (DNS) under the SEPA rules (Washington Administrative Code Chapter 197-11) for the completion of the City’s Wastewater Facilities Plan (WWFP). The WWFP identifies potential improvements to the existing wastewater treatment facility that are necessary to meet projected sanitary sewer treatment needs over the next 20 years. In addition to completing the non-ground-disturbing planning document (WWFP), the City intends to install two groundwater monitoring wells. The proposed monitoring wells would be installed within city limits at the City’s existing wastewater treatment facility located in Section 6 of Township 16 North, Range 26 East. After reviewing the completed SEPA Checklist and additional supporting information filed with the Washington State Department of Ecology, the City has determined that this proposal will not have a probable significant adverse impact on the environment. The DNS and SEPA documents are available for public review at City Hall, 445 Camelia Street N.E., Royal City, Washington, 99357, Monday through Friday from 8:00 a.m. to 5:00 p.m. The public is invited to comment on this DNS by submitting written comments no later than June 9, 2023, to the attention of Shilo Christensen, Finance Director, at the above address above #06005/9368 Pub: May 25, 2023 & June 1, 2023

NOTICE TO MATERIAL SUPPLIERS  Sealed bids plainly marked “Bid for Asphalt Materials - 2023” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, March 1, 2023 and will then and there in the Public Meeting Room be opened and publicly read. If you have any questions about this procedure please call the Public Works Office in advance of the bid opening.:  Rob Harris  Assistant County Engineer  509-906-6415  rgharris@grantcountywa.gov  This contract provides for furnishing and delivering asphalt materials in accordance with the plans and specifications.  Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823.  The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County.  The improvement for which bids will be received follows:  Asphalt Materials - 2023  This proposal provides for furnishing 4,000-6,000 tons of HFE-150 liquid asphalt, 500 - 700 tons of HFE-90 liquid asphalt and 6000 - 8,000 tons of Hot Mix Asphalt for the 2023 season to Grant County and other work in accordance with the specifications.  #02043/5423 Pub: February 10, 15, 17, 22, 24, 27, 2023

ADVERTISEMENT FOR BID OTHELLO HOSPITAL AMBULANCE FACILITY Sealed bids will be received by the Othello Community Hospital Board of Commissioners, at 315 N. 14th Ave., Othello, WA 99344, for the construction of the Othello Hospital Ambulance Facility project. Sealed Base Bids must be received by 3:00 p.m. local time on Tuesday, March 14, 2023, and must be marked “Sealed Base Bid – Othello Hospital Ambulance Facility.” Sealed Supplemental Bid Form A-Part-1 must be received by 4:00 p.m. local time on March 14, 2023, and must be marked “Sealed Supplemental Bid Form A – Part 2– Othello Hospital Ambulance Facility.” Bids received after this time will not be considered. Sealed Bids will be opened and publicly read at 4:00 p.m. local time on March 14, 2023. Sealed Supplemental Bid Form A-Part-2 must be received forty-eight hours after Base Bid is due. Project documents are available at www.architectswestplans.com. Bidders may download digital PDF files at no cost. Hardcopy sets are available at the bidders expense via Abadan Reprographics, 603 E. 2nd Ave., Spokane, WA 99202. Bidders are encouraged to register as a plan holder at www.architectswestplans.com, and select “Add me as a Plan Holder.”  Questions regarding the plan room contact Auron (509) 747-2964 or repro@abadanspokane.com. A complete set of contract documents will also be filed with the Plan Centers listed at www.architectswestplans.com. A non-mandatory Pre-Bid Conference has been scheduled for Tuesday, February 28, 2023, at 10:00 a.m. local time at the existing ambulance station located at 315 N. 14th Ave., Othello, WA 99344. No bidder may withdraw his bid after hour set for opening thereof, unless award is delayed for a period exceeding 30 days. The Othello Community Hospital reserves the right to reject any or all bids and to waive informalities or irregularities in any bid.   #02050/5652 Pub: February 20. 27. 2023

City of Moses Lake Parks, Recreation, and Cultural Services Advisory Board Opening The Moses Lake City Council has one vacancy on the Parks, Recreation, and Cultural Services Advisory Board. Qualified applicants must reside in the city, or in the city’s urban growth area outside the corporate limits of the city. The purpose of the Parks, Recreation and Cultural Services Advisory Board is to review and make recommendations to the Moses Lake City Council, City Manager, and Director to needs including: formulation of policy and plans for development, management and operation of the City parks and recreation program, promoting parks, recreation and cultural services programs to the community, setting standards for park maintenance, coordinating museum exhibits and activities, setting goals for short-term and long-term future of the City’s museum and park system, serving as citizens’ input concerning parks, recreation, and cultural services, generally, and monitoring and evaluating the park system and museum activities. The Parks, Recreation and Cultural Services Advisory Board is composed of seven members appointed by a majority vote of the City Council without regard to political affiliation. The current vacancy will be for an unexpired term scheduled to end or have reappointment December 31, 2024. Meetings are held the 2nd Wednesday of the month at 6:00 p.m. in the Council Chambers. Interested persons need to complete the online Boards and Commissions application by Tuesday, March 14, 2023. Contact the Parks Secretary Stefanie Dunn if you have questions regarding this position at sdunn@cityofml.com or 509-764-3805. #02054/5925 Pub: February 27, 2023

NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Grant County, Washington, will receive bids for the printing of County Legal Notices for the year beginning July 1, 2023, and ending June 30, 2024. All printing is to be published in nine-point solid matter and must be able to publish legal notices a minimum of 2 days per week. Legal notices must be published in single-column format, based on a six-column publication, justified, with hyphenation and no spaces between paragraphs. Legal notices will be submitted, by the County, in this format. Bids must be sealed and endorsed on the outside of the envelope with the words: “BID FOR COUNTY PRINTING” and must be filed with the Clerk of the Board of County Commissioners on or before April 03, 2023, at 10:30 a.m. Bid opening immediately follows. Bids shall contain a certified statement of paid circulation within Grant County so that due consideration of the widest publicity of notices may be made an element of the award of said printing. In accordance with RCW 36.72.075, the successful bidder may be required to post a bond in the amount of Two Thousand and No/100 Dollars ($2,000.00) for the correct and faithful performance of the contract and work to be done. The Board of County Commissioners reserves the right to reject any and all bids. DATED this 27th day of February 2023. Grant County, Washington Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioner’s Office #02055/5935 Pub: February 27, 2023____

PUBLIC NOTICE The East Columbia Basin Irrigation District will be making aquatic herbicide treatments beginning in May 2023 and continuing through the end of the 2023 irrigation season. These herbicide treatments will be made pursuant to a Department of Ecology NPDES General Permit for Aquatic Weed Control in Irrigation Systems (Permit No. WAG-991010). The District’s service area is located in Moses Lake, Warden and Othello areas of Grant and Adams Counties. The District operates the East Low Canal and its laterals plus some laterals on the Potholes East Canal. 49 locations on various canals, laterals, wasteways and drains within the District’s service areas will receive these treatments to control the growth of algae, moss and pondweeds. Frequency of treatments varies from as often as biweekly to as seldom as twice per irrigation season depending on location and circumstances. Permanent signs giving notice of aquatic herbicide treatments have been erected at public road crossing of treated waterways within one mile of the treatment sites. The herbicides being used for these treatments are copper sulfate, Captain Aquatic Herbicide (copper), Endothall and Magnicide H (acrolein) which are registered for such use under the Federal Insecticide, Fungicide and Rodenticide Act (FIFRA). Water remains suitable for irrigation use during aquatic herbicide treatments. Treated water is not suitable for drinking or swimming. Individuals desiring additional information about these treatments should contact the East District’s main office in Othello at (509) 488-9671 and ask to speak to the Secretary-Manager or Water Quality Supervisor. Inquiries may also be directed to the Department of Ecology Eastern Regional Office in Spokane, (509) 625-5194. East Columbia Basin Irrigation District, 55 North 8th Avenue, Po Box E, Othello, WA 99344. #04026/7315 Pub: April 7, 14, 21, 2023

APN:111432000 T.S. No. LO-52658-WA U.S. DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT NOTICE OF DEFAULT AND FORECLOSURE SALE. Recorded in accordance with 12 USCA 3764 (c) WHEREAS, on 6/20/2011, a certain Deed of Trust was executed by Thomas E. McCurdy and Nancy McCurdy, husband and wife as trustor in favor of One Reverse Mortgage, LLC as beneficiary, and FNTG-Chicago Title as trustee, and was recorded on 7/13/2011, as Instrument No. 1288475, in Book XX, Page XX, in the Office of the County Recorder of Grant County, Washington; and WHEREAS, the Deed of Trust was insured by the United States Secretary of Housing and Urban Development (the Secretary) pursuant to the National Housing Act for the purpose of providing single family housing; and WHEREAS, the beneficial interest in the Deed of Trust is now owned by the Secretary, pursuant to an Assignment of Deed of Trust dated 1/23/2019, recorded on 5/24/2019, as instrument number 1409554, book XX, page XX, in the Office of the County Recorder, Grant County, Washington; and WHEREAS, a default has been made in the covenants and conditions of the Deed of Trust in that the payment due on 5/18/2022, was not made due to an obligation of the borrower under this security instrument is not performed and remains wholly unpaid as of the date of this notice, and no payment has been made sufficient to restore the loan to currency; and WHEREAS, the entire amount delinquent as of 3/9/2023 is $190,734.26; and WHEREAS, by virtue of this default, the Secretary has declared the entire amount of the indebtedness secured by the Deed of Trust to be immediately due and payable;  NOW THEREFORE, pursuant to powers vested in me by the Single Family Mortgage Foreclosure Act of 1994, 12 U.S.C. 3751 et seq., by 24 CFR part 27, subpart B, and by the Secretary’s designation of Law Offices of Jason C Tatman APC as Foreclosure Commissioner, recorded on 10/19/2020 as instrument number 1435815, book XX, page XX notice is hereby given that on 4/14/2023 at 10:00 AM* local time, all real and personal property at or used in connection with the following described property will be sold at public auction to the highest bidder: *The foreclosure sale is being postponed to 5/12/2023. Legal Description: LOT 3, BLOCK 1, VANCE-EMERY SUBDIVISION, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 3 OF PLATS, PAGE 33, RECORDS OF GRANT COUNTY, WASHINGTON. Commonly known as: 613 S Pacific St, Moses Lake, WA 98837 The sale will be held at At the Police Justice County Building, 401 Balsam Street NKA 411 South Balsam Street, Moses Lake, WA. The Secretary of Housing and Urban Development will bid an estimate of $195,834.04. For Sales information visit www.SuperiorDefault.com or call 855-986-9342 There will be no proration of taxes, rents or other income or liabilities, except that the purchaser will pay, at or before closing, his prorata share of any real estate taxes that have been paid by the Secretary to the date of the foreclosure sale. When making their bids, all bidders except the Secretary must submit a deposit totaling $19,583.40 [10% of the Secretary’s bid] in the form of a certified check or cashier’s check made out to the Secretary of HUD. Each oral bid need not be accompanied by a deposit. If the successful bid is oral, a deposit of $19,583.40 must be presented before the bidding is closed. The deposit is nonrefundable. The remainder of the purchase price must be delivered within 30 days of the sale or at such other time as the Secretary may determine for good cause shown, time being of the essence. This amount, like the bid deposits, must be delivered in the form of a certified or cashier’s check. If the Secretary is the high bidder, he need not pay the bid amount in cash. The successful bidder will pay all conveyancing fees, all real estate and other taxes that are due on or after the delivery of the remainder of the payment and all other costs associated with the transfer of title. At the conclusion of the sale, the deposits of the unsuccessful bidders will be returned to them.  The Secretary may grant an extension of time within which to deliver the remainder of the payment. All extensions will be for 15-day increments for a fee of $500.00, paid in advance. The extension fee shall be in the form of a certified or cashier’s check made payable to the Secretary of HUD. If the high bidder closes the sale prior to the expiration of any extension period, the unused portion of the extension fee shall be applied toward the amount due. If the high bidder is unable to close the sale within the required period, or within any extensions of time granted by the Secretary, the high bidder may be required to forfeit the cash deposit or, at the election of the foreclosure commissioner after consultation with the HUD Field Office representative, will be liable to HUD for any costs incurred as a result of such failure. The commissioner may, at the direction of the HUD field office Representative, offer the Property to the second highest bidder for an amount equal to the highest price offered by that bidder. There is no right of redemption, or right of possession based upon a right of redemption, in the mortgagor or others subsequent to a foreclosure completed pursuant the Act. Therefore, the Foreclosure commissioner will issue a Deed to the purchaser(s) upon receipt of the entire purchase price in accordance with the terms of the sale as provided herein. HUD does not guarantee that the property will be vacant. The amount that must be paid if the Mortgage is to be reinstated prior to the scheduled sale is $195,834.04, as of 4/13/2023, plus all other amounts that would be due under the mortgage agreement if payments under the mortgage had not been accelerated, advertising costs and postage expenses incurred in giving notice, mileage by the most reasonable road distance for posting notices and for the Foreclosure Commissioner’s attendance at the sale, reasonable and customary costs incurred for title and lien record searches, the necessary out-of-pocket costs incurred by the Foreclosure Commissioner for recording documents, a commission for the Foreclosure Commissioner, and all other costs incurred in connection with the foreclosure prior to reinstatement.  Tender of payment by certified or cashier’s check or application for cancellation of the foreclosure sale shall be submitted to the address of the Foreclosure Commissioner provided below. Date: 4/10/2023 By: Rhonda Rorie rr@tatmanlegal.com Law Offices of Jason C Tatman, APC U.S. Dept. of HUD Foreclosure Commissioner 5677 Oberlin Dr., Ste 210 San Diego, CA 92121 (858) 201-3590 Fax (858) 348-4976 (TS# LO-52658-WA SDI-26481)  #05008/7722 Pub: April 21, 28, 2023 & May 5, 2023

Jenks Holdings, Duane Jenks, 10158 Kinder Rd NE Moses Lake, WA 98837, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, S Eastlake Dr Development, is located at 948 S Eastlake St in Moses Lake in Grant county. This project involves 2.25 acres of soil disturbance for Residential construction activities. The receiving waterbody is Moses Lake. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320.   Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696   #04040/7729 Pub: April 14, 21, 2023

SUPERIOR COURT OF WASHINGTON COUNTY OF ADAMS IN THE MATTER OF THE ESTATE OF | | | No.  22-4-00053-01 ADELINA GUTTIERREZ MENDEZ , | | | PROBATE NOTICE TO | CREDITORS   Deceased | ____________________________________|_______________________ PLEASE TAKE NOTICE The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication of this Notice: ___March 15, 2023___________________ Decedent’s Social Security Number (to be filled in and sent to Washington Dept. of Social & Health Services ONLY): _____________________________________ ____________________________________ ESMERALDA CANTU Address for Mailing of Service: Toni Meacham, Attorney at Law 1420 Scooteney Rd Connell, WA 99326 (509)488-3289 #03028/6486 Pub: March 15, 22, 29, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF SPOKANE In the Matter of the Estate | | No. 23-4-00522-32 of | | PROBATE NOTICE TO CREDITORS GORDON FAY ROBINSON, | | Deceased. | ____________________________ |_______________________________________ The Personal Representative named below has been appointed as the Personal Representative of this estate. Any person having a claim against the Decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to Personal Representative at the address stated below, a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the Personal Representative served or mailed the notice to the creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the Decedent’s probate and non-probate assets. Date of First Publication: March 15, 2023 Personal Representative: Gordon Scott Robinson Attorney for the Personal Representative: Steven Wee, Esq. Address for Mailing or Service: 708 N. Argonne Road, Suite 1B Spokane Valley, WA 99212 Steven Wee, WSBA # 30620 Attorney for the Personal Representative #03031/6499 Pub: March 15, 22, 29, 2023

IN AND FOR THE SUPERIOR COURT OF WASHINGTON IN AND FOR THE COUNTY OF FRANKLIN  In Re the Estate of:  ANTONIA GONZALES Deceased.  # No.23-4-500-40-11  NOTICE TO CREDITORS  The personal representative named below has been appointed and has qualified  as personal representative of this estate. Persons having claims against the decedents must, prior to the time such claims would be barred by any otherwise applicable statute of limitations, serve their claims in the manner as provided in RCW 11.40.070 by serving or mailing on the personal representative r the attorneys of record at the address stated below and file an executed copy of the claim with the Clerk of this Court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim will be forever barred, except as otherwise provided in RCW 11.40.051 and 11.40,060. This bar is effective as to claims against both the probate and nonprobate assets of the decedent.  DATE OF FIRST PUBLICATION: March 15, 2023 Edna Medina  Box 2009  Pasco, WA 99302  509-546-0804  Personal Representative  Paul Keister, attorney  Box 2009, Pasco, WA. 99302 509-546-0804 #03032/6509 Pub: March 15, 22, 29, 2023

VENDOR ROSTER   Columbia Basin Hydropower is preparing a vendor roster for purchases costing less than $50,000 for materials, supplies, equipment and services to be used in maintaining its hydroelectric power projects. To be on the roster, submit business name and contact information to: info@cbhydropower.org. #03033/6524 Pub: March 23, 30, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF KING In the Receivership of: | | CASE NO: 23-2-02688-8 SEA | SOLSTICE GROUP, INC., and | NOTICE TO CREDITORS OF SOLSTICE HOLDINGS, INC. | RECEIVERSHIP | | [for publication] ____________________________________| PLEASE TAKE NOTICE that pursuant to the Order Appointing General Receiver entered by this Court on February 10, 2023, TurningPointe, LLC has been appointed General Receiver (“Receiver”) over all assets of Solstice Group, Inc., and Solstice Holdings, Inc., whose last known address is 640 S. Spokane St., Seattle, WA. Claims. All persons and businesses who believe they are owed money related to the Property on account of any goods, services or credit provided to the Property before February 10, 2023, must complete the Proof of Claim Form available through the receiver’s attorney. Creditors who fail to timely file a claim will not share in any distributions, should funds become available. The Proof of Claim Form must be returned to the Receiver’s counsel at the address listed below no later than 30 days from the date of this notice. If you are a state agency, you must file proof of claim with the receiver within 180 days after the date of this notice. RECEIVER: TurningPointe, LLC ATTORNEYS FOR RECEIVER: Dominique R. Scalia, WSBA No. 47313 DBS Law 155 NE 100th St., Suite 205 Seattle, Washington 98125 (206) 489-3802 #3038/6603 Pub: March 16, 23, 30, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR THE COUNTY OF GRANT BANK UNITED N.A. , | | CASE NO.: 21-2-00818-13 Plaintiff, | JUDGMENT NO.: | vs. | SHERIFF’S NOTICE TO JUDGMENT | DEBTOR OF SALE OF REAL UNKNOWN HEIRS AND DEVISEES OF | PROPERTY DENNIS C. JOHNSON, DECEASED; | PATRICIA DIETZMAN, FORMER | PERSONAL REPRESENTATIVE FOR THE | ESTATE OF DENNIS CHARLES JOHNSON; | UNKNOWN SUCCESSOR PERSONAL | REPRESENTATIVE FOR THE ESTATE OF | DENNIS CHARLES JOHNSON; AQUA | FINANCE, INC.; DESERT AIRE OWNERS | ASSOCIATION; JOHN AND/OR JANE DOE, | UNKNOWN OCCUPANTS/CO-HABITANTS | OF THE SUBJECT PREMISES , | | Defendants | | _____________________________________ | Patricia Dietzman, former Personal Representative Unknown Heirs and Devisees of for the Estate of Dennis Charles Johnson Dennis C. Johnson, deceased 503 Desert Aire Drive SW 503 Desert Aire Drive SW Mattawa, WA 99349 Mattawa, WA 99349 Unknown Successor Peronal Representative Aqua Finance, Inc. for the Estate of Dennis Charles Johnson R/A: Corporation Service Company 503 Desert Aire Drive SW 300 Deschutes Way SW, Suite 208. MC-CSC1 Mattawa, WA 99349 Tumwater, WA 98501 John and/or Jane Doe, Unknown Occupants Desert Aire Owners Association Co-Habitants of the Subject Premises c/o Michael M Wyman 503 Desert Aire Drive SW 2219 W. Broadway Ave. Suite A Mattawa, WA 99349 Moses Lake, WA 98837 The Superior Court of Grant County has directed the undersigned Sheriff of Grant County to sell the property described below to satisfy a judgment in the above entitled action. The property to be sold is described as follows: LOT 14, DESERT AIRE NO. 8, PHASE II, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 13 OF PLATS, PAGES 71, 72 AND 73, RECORDS OF GRANT COUNTY, WASHINGTON APN TAX PARCEL NO.: 021687014 Commonly known as: 503 Desert Aire Drive SW, Mattawa, WA 99349 The sale of the described property is to take place at 10:30 am on the 19 th day of May 2023 at the main lobby of the Grant County Courthouse, Ephrata, Washington. The judgment debtor can avoid the sale by paying the judgment amount of $ 319,691.78 plus interest, costs and fees before the sale date. For the exact amount, contact the attorney at the address stated below. This property is subject to: A redemption period of 8 (Eight) months, which will expire at 4:30 pm on the 19 th day of January 2024. The judgment debtor or debtors or any of them may redeem the above described property at any time up to the end of the redemption period by paying the amount bid at the Sheriff’s sale plus additional costs, taxes, assessment, certain other amounts, fees and interest. If you are interested in redeeming the property, contact the attorney at the address stated below to determine the exact amount necessary to redeem. IMPORTANT NOTICE: If the judgment debtor or debtors do not redeem the property by 4:30 pm on the 19 th day of January 2024 , the end of the redemption period, the purchaser at the Sheriff’s sale will become the owner and may evict the occupant from the property unless the occupant is a tenant holding under an unexpired lease. If the property to be sold is occupied as a principal residence by the judgment debtor or debtors at the time of sale, he, she, they or any of them may have the right to retain possession during the redemption period, if any, without payment of any rent or occupancy fee. The judgment debtor may also have a right to retain possession during any redemption period if the property is used for farming or if the property is being sold under a mortgage that so provides. Dated this 15 th day of March 2023 , at Ephrata, WA 98823. JOSEPH M. KRIETE, Sheriff By: Sheena Ohl, Civil Specialist cc: Janeway Law Firm, LLC Attn: James A. Craft 1499 SE Tech Center Place, Suite 255 Vancouver, WA 98683 Phone: (360) 260-2253 Fax: (360) 260-2285 ksutherland@logs.com #05002/6703 Pub: March 30, 2023, April 6, 13, 20, 27, 2023 & May 4, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR THE COUNTY OF GRANT BANK UNITED N.A., | | CASE NO.: 21-2-00818-13 | JUDGMENT NO.: Plaintiff, | | SHERIFF’S PUBLIC NOTICE OF | SALE OF REAL PROPERTY vs. | | UNKNOWN HEIRS AND DEVISEES OF | DENNIS C. JOHNSON, DECEASED; | *** EIGHT MONTH PATRICIA DIETZMAN, FORMER | REDEMPTION*** PERSONAL REPRESENTATIVE FOR THE | ESTATE OF DENNIS CHARLES JOHNSON; | UNKNOWN SUCCESSOR PERSONAL | REPRESENTATIVE FOR THE ESTATE OF | DENNIS CHARLES JOHNSON; AQUA | FINANCE, INC.; DESERT AIRE OWNERS | ASSOCIATION; JOHN AND/OR JANE DOE, | UNKNOWN OCCUPANTS/CO-HABITANTS | OF THE SUBJECT PREMISES, | | Defendants | __________________________________________ | The Superior Court of Grant County has directed the undersigned Sheriff of Grant County to sell the property described to satisfy a judgment in the above entitled action: LOT 14, DESERT AIRE NO. 8, PHASE II, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 13 OF PLATS, PAGES 71, 72 AND 73, RECORDS OF GRANT COUNTY, WASHINGTON APN TAX PARCEL NO.: 021687014 Commonly known as: 503 Desert Aire Drive SW, Mattawa, WA 99349 The sale of the described property is to take place at 10:30 am on the 19th day of May 2023 at the main lobby of the Grant County Courthouse, Ephrata, Washington. The judgment debtor can avoid the sale by paying the judgment amount of $319,691.78 plus interest, costs and fees before the sale date. For the exact amount, contact the attorney at the address stated below. Dated this 15th day of March 2023 at Ephrata, WA 98823. JOSEPH M. KRIETE, Sheriff By: Sheena Ohl, Civil Specialist cc: Janeway Law Firm, LLC Attn: James A. Craft 1499 SE Tech Center Place, Suite 255 Vancouver, WA 98683 Phone: (360) 260-2253 Fax: (360) 260-2285 ksutherland@logs.com #04003/6709 Pub: March 30, 2023 & April 6, 13, 20, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR SPOKANE COUNTY  In Re the Estate of:  | NO. 23400445-32  | PAUL EUGENE MAYBEE  | PROBATE NOTICE TO CREDITORS | RCW 11.40.030  Deceased.  | ____________________________ | The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.  Date of first publication: March 22, 2023 Personal Representative: David Eugene Maybee  Attorney for Personal Representative: Andrew M. Ouimet  Address for Mailing or Service:  DATED this 16th day of  March 2023.  David Eugene Maybee, Personal Representative  ANDREW M. OUIMET, WSBA #46512  PROBATE NOTICE TO CREDITORS  RCW 11.40.030  #04004/6747 Pub: March 22, 29, 2023 & April 5, 2023

============ 2022 NOTICE OF CONSTRUCTION COMPLETION ============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Engineer’s Office has completed the following County Forces conducted road projects in 2022 with final true and complete costs as follows:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion Road 3-NE Phase 4 BST Surface after 22-01 County Forces $277,000 Contractor Preparations Total = $277,000 The maximum allowable construction work by County forces is $1,307,338. The 2022 County Forces completed work is well under the maximum allowed.   Dated this 16th day of March 2023 ========================== END OF NOTICE=========================== #03046/6752 Pub”March 22, 24, 27, 30, 2023

============ 2023 NOTICE OF COUNTY FORCES CONSTRUCTION============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Board of County Commissioners intends to have the following road(s) improved by County Forces (using county crews and equipment) in calendar year 2023:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion ADA Ramp / Sidewalk Upgrades ADA Ramp and/or Sidewalk County Forces $120,000 Miscellaneous Projects Safety/Drainage/Guardrail/ Bridge/Roads County Forces $250,000 B-SE Culverts Replace Culverts 18-10 County Forces $200,000 Road 23 NE Bridge Replacement 23 NE Bridge 171 Replacement 22-04 County Forces $100,000 Gravel to Oil Program (1.5 Miles) Portions of Road 8-NE and Road 12-NE County Forces $400,000 Total = $1,070,000 The maximum allowable new construction work by County forces is $1,307,338. The 2023 proposed work is well under the maximum allowed. All other new construction shall be contracted out for 2023. Dated this 16th day of March 2023 ========================== END OF NOTICE ========================== #03045/6756 Pub: March 22, 24, 27, 30, 2023

STATE ENVIRONMENTAL POLICY ACT Determination of NonSignificance Date of issuance: March 22, 2023 Lead agency: Port of Moses Lake Agency Contact: Milton Miller mmiller@portofmoseslake.com (509) 762-5363 Description of proposal: The Port of Moses Lake (Port) proposes to lease property to the Grant County Mosquito Control District #1 for the purpose of constructing a facility to house its flight operations. Phase 1 will include an approximately 4,500 square foot hangar, a 150 square foot pilot toilet, and a fuel tank. Improvements for the project include site, stormwater management improvements, and an apron to connect the hangar to the Grant County International Airport taxiway. Site improvements and construction for Phase 1 will begin as soon as permits and approvals have been received. Future site upgrades may include up to 3 additional hangars, a storage building, an administrative building, on-site parking, and a loading dock.  Location of proposal: The proposed Project will be located in Grant County, Washington, on Turner Road NE, Moses Lake, WA, in a portions of Section 28, Township 20 North, Range 28 East W.M. The Project will occur within parcel 17-1017-000; however, an address has not been assigned to the site yet. Project Proponent: Port of Moses Lake; Milton Miller, SEPA Responsible Official; 7810 Andrews N.E. Suite 200; Moses Lake, WA 98837 (509)762-5363 The Port of Moses Lake, as Lead Agency, has determined that this proposal will not have a probable significant adverse impact on the environment. An environmental impact statement (EIS) is not required under RCW 43.21C.030(2)(c). We have reviewed the SEPA Environmental Checklist, drawings, and project studies on file with the lead agency. This information is available to the public on request. This determination is based on the following findings and conclusions: • The proposed site footprint is located at the Grant County International Airport within the developed area covered by a prior Environmental Impact Statement and will be constructed adjacent to similar infrastructure.  • A Wildlife and Habitat Site Assessment was performed by Jacobs and concluded that the project will not impact any high-quality habitat or wildlife species.   • Statewide cultural resources database searches indicated no cultural or historic sites are documented within the project area. Though the site is disturbed, the Project will utilize an Inadvertent Discovery Plan and monitoring in the event anything is found during construction.  • A Subsurface Investigation Report documented there are no risks of environmental health hazards, exposure to toxic chemicals, or hazardous waste from this project. • All hazardous material storage, including fuel and pesticides, will be stored and man aged with full containment. • Best Management Practices and a Temporary Erosion and Sediment control Plan will be used to prevent erosion and provide site stabilization during construction, and stormwater management will comply with the Eastern Washington Stormwater Manu al by storing and infiltrating stormwater on site. This DNS is issued under WAC 197-11-340(2). The lead agency will not act on this proposal for 14 days from March 22, 2023. Written comments must be submitted no later than 5:00 PM on April 5, 2023, to the Port of Moses Lake c/o Director of Port Facilities, 7810 Andrews Street NE Suite 200, Moses Lake, WA 98837 or via email to mmiller@portofmoseslake.com.    #03044/6758 Pub: March 22, 29, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

Notice of Application Optional DNS Process The City of Mattawa has received a permit application for the following project: A proposal to short subdivision one (1) existing 15,750sf parcel into two (2) proposed lots. Lot 1 will be 9,449sf and Lot 2 will be 6,295sf. Date of Application: February 08, 2023 Date of Determination of Completeness: March 20, 2023 Date of Notice of Application: March 22, 2023 Comment Due Date: April 12, 2023 Agency Contact: Rachelle Bradley, Contract Planner, City of Mattawa                 rachelle.bradley@scjalliance.com                  509-932-4037 Agency File Number: SP-02-2023 (Rubalcava) Project Location: The project is located at 300 S. Broadway Ave, Parcel No. 030140001, Mattawa, Grant County, Washington. It is legally described as: LOTS 1, 2, 3, 4 AND 5, BLOCK 16, ORIGINAL PLAT OF MATTAWA, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 1 OF PLATS, PAGE 42, RECORDS OF GRANT COUNTY, WASHINGTON. TOGETHER WITH THAT CERTAIN 1979 MARLETTE MOBILE HOME, SIZE 14/70, SERIAL NO. 014270FDK90049. CONTAINS WHICH IS LOCATED ON SAID PREMISES. 15,737 SQUARE FEET, MORE OR LESS. Owner/Applicant: Eleuterio & Maria Rubalcava         300 S Broadway Ave         Mattawa, WA 99349   SEPA Environmental Review: The City of Mattawa has reviewed the proposed project for probable adverse environmental impacts and expects to issue a Determination of Nonsignificance (DNS). An Environmental Impact Statement (EIS) is not required under RCW 43.21.C.030.(2)(c). The decision was made after review of a completed environmental checklist and other information on file with the lead agency. This information is available to the public upon request. The optional DNS process in WAC 197-11-355 is being used. This may be your only opportunity to comment on the environmental impacts of the proposed project. Agencies, tribes, and the public are encouraged to review and comment on the proposed project and its probable environmental impacts. Comments must be submitted by the date noted above to City of Mattawa, Planning Department, 521 Government Rd Mattawa, WA 99349. Any information submitted to the City of Mattawa is subject to the public records disclosure law for the State of Washington (RCW Chapter 42.17) and all other applicable law that may require the release of the documents to the public. This project does not require a public hearing. A copy of the subsequent threshold determination and any other information concerning this action may be obtained by contacting the Mattawa Planning Department, 521 Government Rd Mattawa, WA 99349. Required Permits: City of Mattawa Development Permit/Land Use Application. Other forms, reports, or approvals as necessary. Required Studies: Unknown at this time. Existing Environmental Documents: SEPA Checklist.  Preliminary Development Regulations and Existing Environmental Documents: To evaluate the impacts of the proposed project, the following may be used for mitigation, consistency, and the development of findings and conclusions: Regulations of the City of Mattawa including the Mattawa Comprehensive Plan, MMC Title 16 Subdivisions, MMC Title 17 Zoning Code, and MMC Title 18 Environmental Protection; Regulations of the Washington State Department of Fish and Wildlife, Washington State Department of Ecology, and Washington State Department of Natural Resources; Regulations of the Grant County Health District; and SEPA Environmental Checklist; and Other required agency evaluations, approvals, permits, and mitigation as necessary. This project does not require a public hearing. A copy of the subsequent threshold det ermination and any other information concerning this action may be obtained by contacting the Mattawa Planning Department, 521 Government Rd Mattawa, WA 99349. Dated on this 22nd day of March 2023: _/s/Rachelle Bradley______________________________ Rachelle Bradley, Contract Planner, City of Mattawa Distribution List: Mattawa Building Department (NW Code Professionals) Mattawa Engineering Department (Gray & Osborne Engineering) Mattawa Public Works Department Grant County Fire District #8 Grant County Health District Grant County Development Services Grant County Public Utility District Port of Mattawa Grant County Assessor’s Office South Columbia Basin Irrigation District Burlington Northern Railroad Wahluke School District Washington State Department of Health Washington State Department of Fish and Wildlife Washington State Department of Archeology and Preservation Washington State Department of Transportation Confederated Tribes and Bands of the Yakama Nation Wanapum Tribe Confederated Tribes of the Colville Reservation Spokane Tribe of Indians #04008/7055 Pub: March 29, 2023 & April 3, 2023

City of Mattawa  Notice of Application Name of Applicant: Ackerman-Estvold Application Number: BSP-10-2022 Date of Application: 09/30/2022 Resubmitted: 03/08/2023 Date Letter of Completeness Issued: 03/22/2023 Public Comment Period: March 29, 2023 through April 12, 2023 Description of Proposed Project Action and Permits: The applicant is proposing a Binding Site Plan to construct a family dollar store and ancillary infrastructure within the undeveloped portion of the parcel located at 20 Government Road (Parcel # 030477151) in the Commercial zoning district within the City of Mattawa.  Other Permits Not Included, To the Extent Known: City of Mattawa Building Permit, Excavation Permit, Development Application, Water and Sewer Permit. Threshold Determination: The City of Mattawa has determined that this project is exempt from SEPA review per WAC 197-11-800. Environmental documentation is not included in this application.  Requested Approvals, Actions and/or Required Studies: A Binding Site Plan requires review by local offices, departments, and agencies, with a comment period of 14 calendar days prior to approval by the plat administrator. All taxes and assessments on the property included in the binding site plan must have been paid according to the provisions of RCW 58.08.030.  Notice of Public Comment Period: Pursuant to Mattawa Municipal Code Title 14 a public comment period is required on the proposed Binding Site Plan. There will be no Public Hearing, per MMC 14.09.040, the city may approve, approve with conditions, or deny the application after the date of application is accepted as complete, and upon completion of the public comment period. The public comment period ends April 12, 2023 at 5:00pm. Statement of Preliminary Determination: The development regulations that will be used for project review and to provide consistency with the type of land use for the proposed site are outlined in the MMC 14.07, Title 14 Development Code, Title 16 Subdivisions, and Title 17 Zoning. City Contact Person: To provide public comment or for further information about this project, please contact Jazmin Hernandez at 509-932-4037 or jahernandez@cityofmattawa-wa.gov or Rachelle Bradley, Planner (509)-835-3770 ext. 344 or rachelle.bradley@scjalliance.com  #04007/7057 Pub: March 29, 2023 & April 3, 2023

Fisher Construction Group, Inc., Chris Lang, 625 Fisher Ln Burlington, WA 98233-3431, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Simplot Moses Rainier HBF 23F012, is located at Northeast of Rd. O and Rd. 2 NE Intersection Parcel #180218000 in Moses Lake in Grant county. This project involves 91.6 acres of soil disturbance for Industrial construction activities. All discharges and runoff goes to ground water. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696   #04010/7072 Pub: March 29, 2023 & April 5, 2023

Grant County Mosquito Control District, No. 1 hereby gives public notice of the need for materials and work for construction that conforms to all applicable public works requirements including the requirement to pay prevailing wages. As allowed by code, the District hereby invites tenders of a construction bid to be based upon drawings and specifications that meet the requirements contained in the Contract Documents prepared by the District. Sealed bids will be received by the Grant County Mosquito Control District for a fixed stipulated lump sum General Contract for the construction of: GRANT COUNTY MOSQUITO CONTROL DISTRICT No. 1 FLIGHT OPERATIONS FACILITY MOSES LAKE, WASHINGTON This project will cover approx. 2 acres and will include a new 4,500 SF Hangar, a 130 SF Toilet Building, a Fuel ‘Island’, and related site work. The Hangar will be a pre-engineered metal building clad with insulated metal panels. The Pilot Toilet will be constructed with CMU. The Architect’s estimate for this project is $2,040,500. Grant County Mosquito Control District will receive sealed bids from qualified contractors ONLY until 2:00 p.m., April 20, 2023 at the District Office, 11905 Road 4, Lot #16, Moses Lake, Washington 98837. Bids received after 2:00 p.m. will not be accepted. Bids will be opened and publicly read aloud immediately after the specified closing time. Bidders and other interested parties are invited to be present at the opening.  Bid must be to perform work for a fixed stipulated lump sum that excludes Washington State Sales Tax. All bids must be accompanied by a bid bond in an amount not less than 5% of the total bid made payable to Grant County Mosquito Control District, No. 1. Questions are to be directed to the Architect of Record: Monson Architects, Inc. Attn: Ryan H. Monson (509) 952-5633 ryanm@monsonarchitects.com Bid documents may be examined at the following plan centers: Yakima Plan Center Yakima Tri-City Construction Council Kennewick Abadan Plan Center Spokane Spokane Regional Plan Center Spokane Builders Exchange of Washington Everett McGraw-Hill Construction / Dodge Plan Center Seattle Idaho AGC Northwest Plan Room Boise Bona fide licensed bidders may obtain project documents at “Monson Architects Plan Room”, www.monsonplanroom.com . Bidders may download digital documents at no cost. Hard copy sets to be used for bidding or construction may be purchased at Bidder’s /Contractor’s expense from the architect’s plan room by choosing the “Order” option or downloaded digital files may be forwarded to a printer of Bidder’s / Contractor’s choice. All Bidders are required to register as a plan holder on this plan room.  Any questions regarding this plan room, shall be directed to plan room administrator at (509) 747-2964 or planroom@abadanplancenter.com.  PRE-BID MEETING There will be a pre-bid meeting and site visitation on April 12, 2023 at 1:00 p.m. at the Project Site located at 8804 Turner Road NE, Moses Lake, Washington 98937. The meetings will include a question / answer period followed by a tour of the site. All General Contractors and subcontractors are highly encouraged to attend the pre-bid meetings.  The District will publicly announce the apparent low bidder during the bid opening; however, Grant County Mosquito Control District reserves the right to reject any or all bids, to waive any irregularity or to accept any bid deemed in the best interest of the District. Upon a thorough review of the bidder’s documents, the District will promptly award the contract to the responsible bidder with the lowest responsive bid.   The District retains the right to hold the bid bond of the lowest apparent bidder and the next two lowest bidders for (60) days after the bid opening, or until a contract has been executed, whichever is the lesser amount of time. All other bid bonds will be returned as soon as feasible after the bid opening. By order of the Board of Trustees, Grant County Mosquito Control District, No. 1 First Publication: March 30, 2023 Second Publicartion: April 6, 2023 #04012/7143 Pub: March 30, 31 2023 & April 6, 2022

NOTICE IS HEREBY GIVEN in accordance with RCW 47.48.020 that previously proposed Spring 2023 construction work on the ROAD-W SE Canal Bridge has been postponed. There will be no construction work while the canal is running water. Thereafter, the bridge shall be closed for bridge extension work from 10.18.2023 to 01.21.2024, with a planned reopening on or before 1.22.2024. The work will extend the existing bridge by 30’ per the original 1950 plans. This requires the construction of a 3rd pier, new abutment on the extended side, and a 4th span of wood beams. This construction schedule may change again, should Federal funds become available for a “full replacement” of the bridge. This notice is given in accordance with Resolution 23-006 Adopting a Six Year Transportation Improvement plan for 2023-2028, which includes this bridge work. More information regarding this project and detour planning can be found on the Grant County Public Works website. #03052/7181 Pub: March 30, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Grant Orchards Fence”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until 1:00 P.M., Tuesday, March 21, 2023 and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Grant Orchards Fence This contract provides for furnishing and installing approximately 2,000 linear feet of 6 (six) foot tall chain link fence and other work, on the property line of the Grant County Public Works Grant Orchard shop, located at 19956 Road A.8 NE, Grant County Parcel #141404000, in Grant County, WA, all in accordance with the attached Contract Plans, these Contract Provisions and the Standard Specifications. #03017/6178 Pub: March 6, 9, 13, 16, 20, 21, 2023

BEFORE THE HONORABLE BOARD OF COUNTY COMMISSIONERS OF GRANT COUNTY, WASHINGTON In the matter of the Application of  NOTICE OF HEARING  ON  Intermountain Infrastructure Group LLC APPLICATION FOR A COUNTY ROAD FRANCHISE for a franchise to construct, operate and maintain Fiber Telecomunications on certain County Road Rights-of-Way within the County of Grant, State of Washington, for the purpose of carrying water. NOTICE IS HEREBY GIVEN that Intermountain Infrastructure Group LLC, has filed with the Board of County Commissioners of Grant County, Washington, an application for a franchise for a period of fifty (50) years to construct, operate and maintain a fiber telecommunications facility across certain County roads in Grant County, Washington lying within the following described portion of the County, to-wit: Route 1  Location begins on the South side of Road 20 NE and the East side of the City of Soap Lake. Route continues on the South side of Road 20 NE to Stratford Road NE. Route continues North on the East side of Stratford Rd. NE until Road 22NE. Route continues East on the south side of Road 22 NE until HWY 28. Route continues East on the south side of Wilson Creek Loop T:22N R:27E S: 19,25,26,27,28,29,30 T22N: R:28E S:13,14,23,26,27,28,29,30 T:22N R:29E: S:2,3, 10,11,16,17,18, Route 2 Location begins on West side of Road R NE (Black Rock Road) and continues South until Road 19 NE. Rout continues East on South side of Road 19 NE until the Grant County/ Lincoln Line T:22N R:29E S: 13 T:22N R:30E S: 18,19,30,31,32,33,34,35,36 ------------------------------------------------------------------------------------------------------------------ Route 1  Location begins on South side of Road K NW and 11.5 NW (15 feet South of 11.5 NW Centerline) goes East to Road H NW. It will continues on the East side of Road H NW (15 Feet East of Road H NW Centerline) to Martin Rd. NW (15 feet South of Martin Rd. NW Centerline). It will continue on Martin Rd. NW to HWY 28.Within, T: 20N R: 25E S: 3,4,5, T: 21N R: 25E S:35,36 T: 21N R: 26E S: 29,31,32 Route 2 Location begins on East side of Dodson Rd NW and Road 14 NW and continues North until the City of Ephrata boundary. T: 21N R: 26 E S: 21 Route 3 Location begins on the East side of Road B NW and continues North to Road 20 NE. route turns east on the South side of Road 20 NE until the boundary of the city of Soap Lake. T: 21N R:26 S:2,3 T:22N R:26E S: 22,23,24,27,34, NOTICE IS FURTHER GIVEN that the Board of County Commissioners of Grant County, Washington, has fixed the hearing on said application for the franchise for the 28th day of March, 2023 at 3:15 p.m. in the Board of County Commissioners’ room in the Grant County Courthouse in Ephrata, Grant County, State of Washington, and any person may appear at this time and place to be heard for or against the granting or denying of said franchise or any part thereof. Webex virtual meeting is also available by calling 1-408-418-9388 using access code 2486 236 7798. DATED this 03 day of March 2023. Michele Jaderlund, Auditor of Grant County, Washington   By:_/s/Michele Jaderlund____________________ Auditor               #03020/6201 Pub: March 13, 20, 2023

ADVERTISEMENT FOR BIDS Sealed bids will be received by the Board of Directors of Moses Lake School District No. 161 in the school district Board Room at the Central Washington Region Transportation Cooperative, 940 E. Yonezawa Blvd., Moses Lake, Washington for construction of the VANGUARD ACADEMY – RFID SYSTEM as follows: Prime bidders shall submit their Basic Bid proposals in a sealed envelope up until 3:00 p.m., Tuesday, March 28, 2023. Basic Bid proposals will be opened and publicly read immediately after submittal of proposals. Proposals received after the above times may not be considered. Optional Pre-Bid Conference: An optional pre-bid conference will be held at 3:00 p.m., Tuesday, March 14, 2023, commencing at the project site, 740 E. Yonezawa Blvd., Moses Lake, Washington. The meeting will convene outside the Vanguard Academy administration office. Drawings and Specifications will be available on or after Monday, March 6, 2023 at www.nacplans.com and may be examined at the following locations: NAC Architecture, 1203 West Riverside, Spokane, WA 99201; Abadan Regional Plan Center, 603 E Second Street, Spokane, WA 99202. Bidders may download digital files at no cost. Printed documents are available by choosing the “Order” option. Bona Fide Prime Contractors, licensed in the State of Washington may receive up to 2 full sets of “Refundable Documents” upon deposit of $100.00 per set. Make checks payable to NAC Architecture and mail to Abadan Reprographics, 603 East 2nd Avenue, Spokane, WA 99202. Deposit will not be returned if documents are mutilated or so marked that they are not reusable and/or if they are not returned to the Architect within ten (10) days after bids are received. Additional or partial sets may be purchased, at bidders’ expense, (non-refundable), from www.nacplans.com or a printer of the bidders’ choosing. Bidders wishing to be formally listed as a plan holder must log in and choose “Add me as a Plan Holder” at www.nacplans.com, where a current plan holder list is continually posted. Any questions regarding www.nacplans.com shall be directed to plan center services, 509-747-2964 or repro@abadanspokane.com. No bidder may withdraw its bid after hour set for opening thereof, unless award is delayed for a period exceeding 45 days. The Board of Directors of Moses Lake School District No. 161 reserves the right to reject any or all bids and to waive informalities. Individuals with disabilities who may need a modification to participate in a meeting should contact the Owner at (509) 766-2650, no later than three days before the bid opening and as soon as possible in advance, so that arrangements can be made. By order of: Board of Directors of Moses Lake School District No. 161. #03025/6461 Pub: March 13, 20 2023

ROYAL SCHOOL DISTRICT BOARD OF DIRECTORS  NOTICE OF WORK SESSION  Monday, March 27, 2023 – 6:30 pm  Royal Intermediate School Library  NOTICE IS HEREBY GIVEN that the Board of Directors (the “Board”) of Royal School  District will be holding a Work Session on Monday, March 27, 2023 at 6: 30pm at Royal  Intermediate School library, 6261 Rd. 12 SW, Royal City, WA 99357. The Work Session is  called for the purpose to discuss the 2024-2025 school year calendar.   Dated this 20th day of March 2023  Royal School District No 160  Grant County, WA  Roger W. Trail  Secretary to the Board of Directors #03036/6547 Pub: March 20, 24, 2023

APN:111432000 T.S. No. LO-52658-WA U.S. DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT NOTICE OF DEFAULT AND FORECLOSURE SALE. Recorded in accordance with 12 USCA 3764 (c) WHEREAS, on 6/20/2011, a certain Deed of Trust was executed by Thomas E. McCurdy and Nancy McCurdy, husband and wife as trustor in favor of One Reverse Mortgage, LLC as beneficiary, and FNTG-Chicago Title as trustee, and was recorded on 7/13/2011, as Instrument No. 1288475, in Book XX, Page XX, in the Office of the County Recorder of Grant County, Washington; and WHEREAS, the Deed of Trust was insured by the United States Secretary of Housing and Urban Development (the Secretary) pursuant to the National Housing Act for the purpose of providing single family housing; and WHEREAS, the beneficial interest in the Deed of Trust is now owned by the Secretary, pursuant to an Assignment of Deed of Trust dated 1/23/2019, recorded on 5/24/2019, as instrument number 1409554, book XX, page XX, in the Office of the County Recorder, Grant County, Washington; and WHEREAS, a default has been made in the covenants and conditions of the Deed of Trust in that the payment due on 5/18/2022, was not made due to an obligation of the borrower under this security instrument is not performed and remains wholly unpaid as of the date of this notice, and no payment has been made sufficient to restore the loan to currency; and WHEREAS, the entire amount delinquent as of3/9/2023 is $190,734.26; and WHEREAS, by virtue of this default, the Secretary has declared the entire amount of the indebtedness secured by the Deed of Trust to be immediately due and payable;  NOW THEREFORE, pursuant to powers vested in me by the Single Family Mortgage Foreclosure Act of 1994, 12 U.S.C. 3751 et seq., by 24 CFR part 27, subpart B, and by the Secretary’s designation of Law Offices of Jason C Tatman APC as Foreclosure Commissioner, recorded on 10/19/2020 as instrument number 1435815, book XX, page XX notice is hereby given that on 4/14/2023 at 10:00 AM local time, all real and personal property at or used in connection with the following described property will be sold at public auction to the highest bidder: Legal Description: LOT 3, BLOCK 1, VANCE-EMERY SUBDIVISION, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 3 OF PLATS, PAGE 33, RECORDS OF GRANT COUNTY, WASHINGTON. Commonly known as: 613 S Pacific St, Moses Lake, WA 98837 The sale will be held at At the Police Justice County Building, 401 Balsam Street NKA 411 South Balsam Street, Moses Lake, WA. The Secretary of Housing and Urban Development will bid an estimate of$195,834.04. For Sales information visit www.SuperiorDefault.com or call 855-986-9342 There will be no proration of taxes, rents or other income or liabilities, except that the purchaser will pay, at or before closing, his prorata share of any real estate taxes that have been paid by the Secretary to the date of the foreclosure sale.  When making their bids, all bidders except the Secretary must submit a deposit totaling $19,583.40 [ 10% of the Secretary’s bid] in the form of a certified check or cashier’s check made out to the Secretary of HUD. Each oral bid need not be accompanied by a deposit. If the successful bid is oral, a deposit of $19,583.40 must be presented before the bidding is closed. The deposit is nonrefundable. The remainder of the purchase price must be delivered within 30 days of the sale or at such other time as the Secretary may determine for good cause shown, time being of the essence. This amount, like the bid deposits, must be delivered in the form of a certified or cashier’s check. If the Secretary is the high bidder, he need not pay the bid amount in cash. The successful bidder will pay all conveyancing fees, all real estate and other taxes that are due on or after the delivery of the remainder of the payment and all other costs associated with the transfer of title. At the conclusion of the sale, the deposits of the unsuccessful bidders will be returned to them. The Secretary may grant an extension of time within which to deliver the remainder of the payment. All extensions will be for 15-day increments for a fee of $500.00, paid in advance. The extension fee shall be in the form of a certified or cashier’s check made payable to the Secretary of HUD. If the high bidder closes the sale prior to the expiration of any extension period, the unused portion of the extension fee shall be applied toward the amount due. If the high bidder is unable to close the sale within the required period, or within any extensions of time granted by the Secretary, the high bidder may be required to forfeit the cash deposit or, at the election of the foreclosure commissioner after consultation with the HUD Field Office representative, will be liable to HUD for any costs incurred as a result of such failure. The commissioner may, at the direction of the HUD field office Representative, offer the Property to the second highest bidder for an amount equal to the highest price offered by that bidder. There is no right of redemption, or right of possession based upon a right of redemption, in the mortgagor or others subsequent to a foreclosure completed pursuant the Act. Therefore, the Foreclosure commissioner will issue a Deed to the purchaser(s) upon receipt of the entire purchase price in accordance with the terms of the sale as provided herein. HUD does not guarantee that the property will be vacant. The amount that must be paid if the Mortgage is to be reinstated prior to the scheduled sale is $195,834.04, as of 4/13/2023, plus all other amounts that would be due under the mortgage agreement if payments under the mortgage had not been accelerated, advertising costs and postage expenses incurred in giving notice, mileage by the most reasonable road distance for posting notices and for the Foreclosure Commissioner’s attendance at the sale, reasonable and customary costs incurred for title and lien record searches, the necessary out-of-pocket costs incurred by the Foreclosure Commissioner for recording documents, a commission for the Foreclosure Commissioner, and all other costs incurred in connection with the foreclosure prior to reinstatement.  Tender of payment by certified or cashier’s check or application for cancellation of the foreclosure sale shall be submitted to the address of the Foreclosure Commissioner provided below. Date: 3/13/23 By: Rhonda Rorie  rr@tatmanlegal.com Law Offices of Jason C Tatman, APC U.S. Dept. of HUD Foreclosure Commissioner 5677 Oberlin Dr., Ste 210 San Diego, CA 92121 (858) 201-3590 Fax (858) 348-4976 (TS# LO-52658-WA SDI-26228)  #04002/6666 Pub:March 20, 27, 2023 & April 3, 2023

NOTICE OF PUBLIC AUCTION Date: Friday, March 24, 2023 Address: 408 Intermodal Way Quincy, WA 98848    Time: 11:30 AM Local Time By virtue of default by LDH Xpress Inc  ( Individually and collectively “Client”), under a Negotiable Promissory Note and Security Agreement(s), Security Agreement(s) Promissory Note(s), Lease Agreement(s) and related documents dated May 3, 2022, payable to Commercial Credit Group Inc. (“CCG”), which obligation is secured by the property described below (the “Equipment”), CCG will sell at Public Auction, to the highest bidder, AS-IS, WHERE-IS, WITHOUT ANY REPRESENTATIONS OR WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR ANY WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE, all of its right, title and interest to the following Equipment: (1) 2023 Utility VS2RA Reefer Trailer SN 1UYVS2532P2662810 Terms: Successful bidder must pay 25% of purchase price at time of sale via cash, certified or acceptable bank check, with the balance payable in good funds on the next business day, unless: 1. The bidder has pre-qualified by presenting CCG with a written non-contingent, lending commitment from a source and in a form acceptable to CCG in its sole discretion, in which case we will entertain bids up to the amount of such written commitment; or 2. The bidder has obtained from CCG written credit approval in advance of the scheduled public sale. CCG reserves the right to bid at the sale. Contact Herb Orengo at (630) 718-4684 for additional information or to arrange an inspection of the Equipment. #03041/6680 Pub: March 17, 20, 2023

NOTICE TO SUPPLIERS Sealed bids plainly marked “Bid for Steel Canopy Body” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, May 30th, 2023 and will then and there in the Public Meeting Room be opened and publicly read.  This contract provides for furnishing and delivering a Steel Canopy Body in accordance with the plans and specifications. Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County. The improvement for which bids will be received are as follows: Bid Specifications for Steel Canopy Body General Specifications This spec is patterned after the Knapheide KC7132H2094 Steel Canopy Body.   - 133.25” L x 94”W x 90” H (40” H side compartments) - 20” side compartment depth - Curbside  Horizontal (RH) compartment extends to rear of body - 14 and 16 gauge galvanneal steel body shell – Keyed alike stainless steel paddle handles with rotary style latches - Master locking system installed on both sides of body - Transverse-style L V 1 compartment extends to the back of R V 1 - (2) adjustable divider shelves in R V 1 compartment - (2) adjustable divider shelves in each L V 2 and R V 2  compartment - (1) bolt t- in divider shelf in R H compartment - (1) adjustable divider shelf in each L R and RR compartment - Double-panel galvanneal doors on rear of canopy (20 gauge outer, 14 gauge inner): - 49.5”W x 63.1” H clear door opening dimensions - Solid panel; no glass/ glass guards - 71.1” interior clear height - (2) L E D interior dome lights - (2) full length shelves on each side of canopy  Interior - 6-year limited warranty - Electro- immersion epoxy primer process - Fully undercoated  (Acrylic) - LED stop, tail, turn, and back-up lights - Chassis-specific install kit (loose): - Includes chassis-specific wiring harness adapter - 94”W Galva-grip bumper (loose) with hitch recess and K nap Liner  coating - Canopy upper side doors with 3-point twist latches - Rear chute doors deleted - 94” wide knaplined Galva-grip step bumper Install Knapheide dual rear wheel KUV cc canopy body as follows: - S/T /T lights - Mud flaps - (1) fuel spout - (2) interior dome lights - Standard bumper Paint 132” K U V cc canopy body urethane: Ford paint code PQ 1 Exhaust extension to bring exhaust out flush  with the body 1 Class V receiver hitch installed as follows: - 24,000 lb. maximum trailer weight , 1,600 lb. maximum vertical load - 2” receiver tube with pin and clip - Includes pin with cotter - Powder coated black 1 7-way trailer socket , RV style with flat blades 1LED compartment light strips in all  compartments for an 8 compartment service body - High intensity LED light strips mounted on each side of the compartment - Wired to existing chassis upfitter switch 1 C T E H .D . Aluminum 7-drawer unit installed as follows: LV2 - 14” w x 32”h x 16”d - (4) -3”, (2) -5”, and (1) -7” removable drawers –  Aluminum construction - Patented motion latch drawer handles - 250 lb. capacity roller slides - Powder coated red with black handles - (6) divider kits - Rubber liners in all drawers 1  Install customer’s existing Miller Bobcat 250 welder in LV1/ transverse compartment - Plumb exhaust up through canopy top 1 110v GFI electric outlet on rear of body wired to customer supplied welder  (No inverter) Install (4) Whelen WHL31HAF LED beacon lights as follows: - Weld mounting plates to canopy - (2) at the front corners of canopy body - (2) at rear corners of the canopy - Install LED beacon light on mounting plates and wire to chassis upfitter switch 1 Install Ford Factory Backup Camera 1 Dominator Liner red, front of body 1 Speed Liner 1000 black, cargo area floor and tailgate Speed Liner 1000 black, cargo area sides Provide the cost to furnish and deliver (inclusive of shipping) F.O.B., the following items meeting the specifications: #05031/8826 Pub: May 12, 16, 19, 23, 26, 2023

NOTICE TO VENDORS The Quincy-Columbia Basin Irrigation District purchases materials, equipment and supplies estimated to cost between $10,000 and $50,000 as set forth in RCW 39.04.190. Quotations are solicited through District communications to vendors having requested to be listed to receive such notifications. To be included on District vendor lists contact: Purchasing Agent Quincy-Columbia Basin Irrigation District 1720 S Central Ave, PO Box 188 Quincy, WA 98848 (509) 787-3591 (509) 787-3906 FAX #05044/9122 Pub: May 19, 26, 2023

FILED 2023 MAY 12 02:55 PM KING COUNTY SUPERIOR COURT CLERK E-FILED CASE #: 23-4-03475-6 SEA SUPERIOR COURT OF THE STATE OF WASHINGTON FOR KING COUNTY   ESTATE OF: | NO. 23-4-03475-6 SEA  | FRED TOSHIO GOTO, | NOTICE TO CREDITORS RCW | ______________________Deceased._____ | 11.40.030   The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.   ANDREW GOTO, Personal Representative Attorney for Personal Representative: WSBA No. 18847 Lawrence F. Brown, Jr. Attorney at Law First filing date: May 12, 2023 P. 0. Box 940 Fall City WA 98024 First publication date: May 19, 2023   #06002/9126 Pub: May 19, 26, 2023 & June 2, 2023 First filing date: May 12, 2023   First publication date:  BROWN & STERLING, P.S. P.O. Box 940 4318 Preston-Fall Cily Rd SE Fall Cily. WA 98024 425-222-6374

STATE OF WASHINGTON DEPARTMENT OF ECOLOGY NOTICE OF APPLICATION FOR CHANGE/TRANSFER OF WATER RIGHT UNDER ONE (1) GROUND WATER CERTIFICATE TAKE NOTICE: That Marlin HB Trust of Marlin, WA, has made an application for change/transfer of water right in order to add points of withdrawal and change a portion of the place of use as granted under Ground Water Certificate No. G3-01558. That Ground Water Certificate No. G3-01558 authorizes the withdrawal of 1400 gallons per minute, 1520-acre feet per year, from April 1 to October 31, each year, for the irrigation of 570 acres. That authorized point of withdrawal is from a well located within the SW¼SW¼SE¼ of Section 18, T. 23 N., R. 32 E.W.M., Lincoln County, WA. That the authorized place of use is within the SE¼ of Section 13, T. 23 N., R. 31 E.W.M.,  E½, SW¼, and S½NW¼ of Section 18, T. 23 N., R. 32 E.W.M., Lincoln County, WA. That they propose to add three well located within Well 1 and 3) SW¼NW¼ of Section 35 and Well 2) S½NE¼ of Section 26 all within T. 22 N., R. 30 E.W.M., Grant County, WA. That they propose to change a portion of the place of use to 70 acres under pivot in the SE¼ and the SW¼ of Section 28 and 50 acres under wiper pivot in the SE¼ of Section 29 both within T. 22 N., R. 30 E.W.M., Grant County, WA. The remaining 450 acres will be retained at the original place of use located in Lincoln County, WA.  Protests or objections to approval of this application must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-($50.00) dollar recording fee and filed with the Department of Ecology, at the address shown below, within thirty (30) days from June 2, 2023. STATE OF WASHINGTON DEPARTMENT OF ECOLOGY WATER RESOURCES PROGRAM - ERO PO BOX 47611 OLYMPIA, WA 98504-761 NOTICE #06004/9356 Pub: May 26, 2023 & June 2, 2023

Vanessa R. Waldref United States Attorney Brian M. Donovan Assistant United States Attorney Post Office Box 1494 Spokane, WA 99210-1494 Telephone: (509) 353-2767 UNITED STATES DISTRICT COURT EASTERN DISTRICT OF WASHINGTON UNITED STATES OF AMERICA, | | NO. 2:22-cv-00036-MKD | | Plaintiff, | | vs. | | LEE M. HERRING and SHEILA M. | HERRING, husband and wife, dba L&S | NOTICE OF UNITED STATES ORCHARDS; STATE OF | MARSHALS’ SALE OF REAL WASHINGTON, DEPARTMENT OF | PROPERTY LABOR & INDUSTRIES; BROOK | LAKE ORCHARDS, a Washington | corporation; LOIS RALSTON; RICK | ARMSTRONG and CHRISTINE | ARMSTRONG, husband and wife; | and DAVE PONOZZO and RANDIE | PONOZZO, husband and wife, | | | | Defendants. | TO: Lee M. Herring, Sheila M. Herring, L&S Orchards, State of Washington Department of Labor & Industries Brook Lake Orchards, Lois Ralston, Rick Armstrong, Christine Armstrong, Dave Ponozzo, and Randie Ponozzo The District Court for the United States of America for the Eastern District of Washington by virtue of an Amended Order of Foreclosure Sale dated, October 24, 2022, on a judgment rendered in said Court on September 27, 2022, has directed the undersigned to sell the property described below to satisfy a judgment in the above-entitled action. The property to be sold is as follows: The sale of the above described real property is to take place as follows: A. Real Property SECTION 2 TOWNSHIP 22 RANGE 28, THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER AND THAT PORTION OF GOVERNMENT LOT 5 LYING SOUTHERLY OF THE RIGHTOF-WAY OF THE U.S.B.R. MAIN CANAL AS SHOWN ON THE FARM UNIT PLAT OF IRRIGATION BLOCK 70, EIGHTH REVISION, COLUMBIA BASIN PROJECT, GRANT COUNTY, WASHINGTON, ACCORDING TO THE PLAT THEREOF FILED AUGUST 21, 1961, ALL IN SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M. EXCEPT THAT PORTION OF GOVERNMENT LOT 5 AND THE SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2 SAID POINT BEARS NORTH 01°0940"" EAST, 5300.00 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0040"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 229.26 FEET TO THE TRUE POINT OF BEGINNING; THENCE NORTH 01°0940"" EAST, PARALLEL TO THE WEST BOUNDARY OF SAID SECTION 2,785.92 FEET TO AN INTERSECTION WITH THE SOUTHERLY RIGHT-OF-WAY BOUNDARY OF THE U.S.B.R. MAIN CANAL; THENCE FOLLOWING SAID SOUTHERLY RIGHT-OF-WAY BOUNDARY THROUGH THE FOLLOWING TWO (2) COURSES; NORTH 83°0300"" EAST, 498.35 FEET; THENCE EASTERLY FOLLOWING A TANGENTIAL CURVE TO THE LEFT HAVING A CENTRAL ANGLE OF 24°4713"" AND A RADIUS OF 753.00 FEET, 325.76 FEET TO AN INTERSECTION WITH THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5; THENCE SOUTH 01°0845"" WEST ALONG THE EASTERLY BOUNDARY OF SAID GOVERNMENT LOT 5 AND THE EASTERLY BOUNDARY OF SAID SOUTH WEST QUARTER OF THE NORTHWEST QUARTER, 546.74 FEET; THENCE SOUTH 59°5311"" WEST, 24.58 FEET; THENCE SOUTH 63°1733"" WEST, 876.97 FEET TO THE TRUE POINT OF BEGINNING. AND TOGETHER WITH THAT PORTION OF THE NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER AND GOVERNMENT LOT 4, SECTION 2, TOWNSHIP 22 NORTH, RANGE 28 E.W.M., DESCRIBED AS FOLLOWS: BEGINNING AT A U.S.B.R. BRASS CAP MONUMENT MARKING THE NORTHWEST CORNER OF SAID SECTION 2, SAID POINT BEARS NORTH 01°0940"" EAST, 5300.10 FEET FROM A U.S.B.R. BRASS CAP MONUMENT MARKING THE SOUTHWEST CORNER OF SAID SECTION 2; THENCE SOUTH 01°0940"" WEST, FOLLOWING THE WEST BOUNDARY OF SAID SECTION 2, 2054.68 FEET TO A P.K NAIL; THENCE NORTH 73°0025"" EAST, 340.79 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 63°1733"" EAST, 1106.23 FEET TO A HALF-INCH REBAR WITH SURVEYOR'S CAP; THENCE NORTH 59°5311"" EAST, 24.58 FEET TO AN INTERSECTION WITH THE WEST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2 AND THE TRUE POINT OF BEGINNING; THENCE NORTH 59°5311"" EAST, 342.62 FEET; THENCE NORTH 76°1831"" EAST, 192.02 FEET; THENCE SOUTH 01°5345"" WEST, 788.26 FEET TO AN INTERSECTION WITH THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 88°1038"" WEST ALONG THE SOUTHERLY BOUNDARY OF SAID NORTH HALF OF THE SOUTHEAST QUARTER OF THE NORTHWEST QUARTER, 468.30 FEET TO AN INTERSECTION WITH THE EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER; THENCE NORTH 01°0845"" EAST ALONG SAID EAST BOUNDARY OF SAID SOUTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, 555.69 FEET TO THE TRUE POINT OF BEGINNING. SUBJECT TO EASEMENT SEE DEED. AND THE FOLLOWING DESCRIBED IRRIGATION SYSTEM INCLUDING BUT NOT LIMITED TO THE FOLLOWING, INCLUDING ANY REPLACEMENT OF OR ADDITIONS TO SUCH SYSTEMS: COMPLETE SPRINKLER SYSTEMS WITH PUMPS, MAINS, SUB-MAINS, RISERS, SPRINKLERS, PLUGS, VALVES, AND FITTINGS. SUBJECT TO ALL OUTSTANDING EASEMENTS, RIGHTSOF-WAY, MINERAL LEASES, MINERAL RESERVATIONS, AND MINERAL CONVEYANCES OF RECORD. IN ADDITION TO FIXTURES, INCLUDING BUT NOT LIMITED TO, ALL IRRIGATION EQUIPMENT, PUMPS, PIPES, MAINLINE, SPRINKLERS, STORAGE FACILITIES, STORAGE FACILITIES, TANKS, BINS, FENCES, WIND MACHINES, AND SIMILAR GOODS AND INFRASTRUCTURE WHICH ARE NOW OWNED OR ACQUIRED IN THE FUTURE. ALL ADDITIONS, RE PLACEMENTS, SUBSTITUTIONS AND ACCESSORIES TO FIXTURES. Assessor’s Parcel No. 171179000. Property Address: 23663 Road J NE, Stratford, Grant County, Washington, 98853 B. Personal Property Wind machines, Irrigation equipment including but not limited to irrigation pumping equipment, irrigation pumps, irrigation pipes, and other irrigation equipment [located at the aforementioned real property]. (hereinafter collectively referred to as the “Property”). Time: 10:30 A.M. Date: March 10, 2023 Place: Grant County Courthouse 35 C Street NW Ephrata, Washington Minimum Bid: $351,775.08 The judgement debtor(s) can avoid the sale by paying the judgment amount of $341,658.71, plus interest at the applicable and legal rate until paid in full, and for the costs of suite, including the filing fee allowed pursuant to 28 U.S.C. 2412(a)(2), and other proper relief. For the exact amount, contact the Marshal at the address stated below: Craig Thayer United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 Redemption period: x The Real Property is subject to a Redemption period of one year which will expire at 4:30 p.m. on March 10, 2024.  No Redemption rights on Personal Property. The judgment debtor or debtor(s) or any of them may redeem the real property and fixtures at any time up to the end of the redemption period by paying the amount bid at the Marshal’s sale, plus additional costs, taxes, assessments and fees. If you are interested in redeeming the property contact the undersigned United States Marshal for the exact amount necessary to redeem. IMPORTANT NOTICE: IF THE JUDGMENT DEBTOR OR DEBTORS DO NOT REDEEM THE PROPERTY BY 4:30 p.m. ON THE 10th DAY OF MARCH, 2024 THE END OF THE REDEMPTION PERIOD, THE PURCHASER AT THE MARSHAL’S SALE WILL BECOME THE OWNER AND MAY EVICT THE OCCUPANT FROM THE PROPERTY UNLESS THE OCCUPANT IS A TENANT HOLDING UNDER AN UNEXPIRED LEASE. IF THE PROPERTY TO BE SOLD IS OCCUPIED AS A PRINCIPAL RESIDENCE BY THE JUDGMENT DEBTOR OR DEBTORS AT THE TIME OF SALE, HE, SHE, THEY, OR ANY OF THEM MAY HAVE THE RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD, IF ANY, WITHOUT PAYMENT OR ANY RENT OR OCCPANCY FEE. THE JUDGMENT DEBTOR MAY ALSO HAVE A RIGHT TO RETAIN POSSESSION DURING ANY REDEMPTION PERIOD IF THE PROPERTY IS USED FOR FARMING OR IF THE PROPERTY IS BEING SOLD UNDER A MORTGAGE THAT SO PROVIDES. The successful bidder for the Property shall be required to deposit at the time of the same with the Marshal a minimum of ten percent of the bid, with the deposit to be made by certified or cashier’s check or cash payable to the United States District Court for the Eastern District of Washington. Before being permitted to bid at the sale, bidders shall display to the Marshal, or his/her representative, proof that they are able to comply with this requirement. No bids will be received from any person(s) who have not presented proof that, if they are the successful bidder(s), they can make the deposit required by this order of sale. The balance of the purchase price for the Property is to be paid to the Marshal within twenty days after the bid is accepted, by a certified or cashier’s check payable to the United States District Court for the Eastern District of Washington. If the bidder fails to fulfill this requirement, the deposit shall be forfeited and shall be applied to cover the expenses of the sale, including commissions due under 28 U.S.C. § 1921(c), with any amount remaining to be applied to the Judgment of the Defendant at issue herein. The Property shall be again offered for sale under the terms and conditions of this order of sale, or, in the alternative, sold to the second highest bidder. The sale of the Property shall be subject to confirmation by the Court. The Marshal shall file a report of sale with the Court, together with a proposed order of confirmation of sale and proposed deed, within thirty days from the date of receipt of the balance of the purchase price. On confirmation of the sale, the Marshal shall execute and deliver a certificate of sale. Upon the expiration of the redemption period, absent a redemption, the deed shall be executed and delivered immediately to the successful bidder. On confirmation of the sale, all interests in, liens against, or claims to, the Property that are held or asserted by all parties to this action are discharged and extinguished. Any party to this suit may become a purchaser at such sale. The United States may bid as a credit against its judgment without tender of cash. The sale will be “as is” and without warranty of any kind. DATED this 26th day of January, 2023. _______________________________ CRAIG THAYER United States Marshal Eastern District of Washington Post Office Box 1463 West 920 Riverside Avenue Spokane, Washington 99210-1463 #02018/5061 Pub: February 3, 10, 17, 24, 2023___________________________________________

NOTICE TO MATERIAL SUPPLIERS  Sealed bids plainly marked “Bid for Asphalt Materials - 2023” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, March 1, 2023 and will then and there in the Public Meeting Room be opened and publicly read. If you have any questions about this procedure please call the Public Works Office in advance of the bid opening.:  Rob Harris  Assistant County Engineer  509-906-6415  rgharris@grantcountywa.gov  This contract provides for furnishing and delivering asphalt materials in accordance with the plans and specifications.  Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823.  The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County.  The improvement for which bids will be received follows:  Asphalt Materials - 2023  This proposal provides for furnishing 4,000-6,000 tons of HFE-150 liquid asphalt, 500 - 700 tons of HFE-90 liquid asphalt and 6000 - 8,000 tons of Hot Mix Asphalt for the 2023 season to Grant County and other work in accordance with the specifications.  #02043/5423 Pub: February 10, 15, 17, 22, 24, 27, 2023

A board seat on the Columbia Basin Conservation District is available for appointment by the Washington State Conservation Commission. Conservation district board supervisors are public officials who serve without compensation and set policy and direction for the conservation district. An applicant must be a registered voter in Washington State and may be required to own land or operate a farm. Applicants for appointed positions do not have to live within the district to apply. For more information, please contact the Columbia Basin Conservation District or read the Guide to Appointment for Conservation District Applicants (https://assets.website-files.com/5ec2d4f7da309c68cdc0655a/5f36cfa9fb8e3e5d59ceaee9_CD-appointment-guide.pdf ) which can be found on the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). To apply, use this direct link (http://www.formstack.com/forms/?1918463-JfwJs6JKCL) or please visit the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). Applications and supporting materials must be received by the Conservation Commission no later than March 31, 2023. #03004/5884 Pub: February 24, 2023 & March 3, 10, 17, 2023.

Hilmes Construction, Inc., Stewart Hilmes, 1716 S Broadway Ave Othello, WA 99344, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Knolls Vista Major Subdivision, is located at Parcel Numbers 11-0625-001, 11-0621-000, 11-0625-002 in Moses Lake in Grant county. This project involves 6.65 acres of soil disturbance for Highway or Road, Residential, Utilities construction activities. All discharges and runoff goes to ground water. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696 #03005/5905 Pub: February 24, 2023 & March 3, 2023

2023 AQUATIC TREATMENTS REQUEST FOR PROPOSALS The Moses Lake Irrigation and Rehabilitation District (MLIRD) respectfully requests cost proposals to survey & treat portions of Moses Lake within the District. This effort would inventory aquatic plants by species and coverage and make recommendations for a prioritized treatment plan for species not conducive to recreation or water intake and/or detrimental to water quality. Contractor must have all applicable licenses for professional work of this nature in Washington State. The project would include the following: Survey work: • Must be consistent with WA State DOE Aquatic Plant Sampling Protocols; and  • Requires previous experience identifying aquatic plants in similar waters & climates. • Contractor submitted & approved work plan based on survey(s) results. Survey & Application personnel should be familiar with Moses Lake water bathymetry. Treatment work: • MLIRD reserves final determination of contractor proposal or recommendations. Contractor should plan an estimated 200 acres, which may include: Diquat; Aquathol; Procellacor; Alum. • Proposal should include chemical price per gallon and application cost per acre for each chemical. • Selected Contractor will be responsible for the generation of all mailing lists, mailed notices, posted signs & water testing, agency reporting & required notifications within ¼ mile radius of work. • All chemicals used must be approved for aquatic use in WA State and under federal law. • Proof of $3,000,000 insurance required w/RFP, request ‘Packet’ for more detail. • GPS equipment required to plot and track treatments • All personnel & equipment supplied by Contractor Deliverables: 20 paper copies of a final report and a digital version in formats to be determined. Report to include: • Lake maps based on GPS data showing inventory findings and work performed • Recommended prioritized treatment plan for undesirable species discovered in survey(s) • Native ArcGIS shape files of treatments recommended and performed • Detailed Final Report provided by contractor Evaluation Factors for Proposal: • Positive Aquatic Survey & Applicator experience in Washington State: 25 points possible • Neat, Comprehensive, Understandable proposal: 25 Points • Summaries of other Aquatic Survey work and the results thereof in similar condi tions: 25 points possible • References & Examples showing other Aquatic Survey work: 25 points possible • Cost: 25 points possible (firm with lowest cost proposal awarded 25 points) MLIRD reserves the right to reject any or all submittals for any reason or no reason, to waive insubstantial or immaterial informalities, and select the RFP that, in the selection team’s judgment, best serves the needs of MLIRD and the people we serve. MLIRD may, in its sole discretion, renew this contract/agreement in each of three subsequent years. All completed RFP documents should include proposed survey and treatment timeframes and must be received by MLIRD no later than Tuesday – April 25, 2023, at 3:00 PM PST at 932 E Wheeler RD, Moses Lake, WA 98837. Call for Packet. (509)765-8716 #04005/7015 Pub: April 5, 12, 19, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR KING COUNTY IN PROBATE Estate of  ) NO. 23-4-02167-1 SEA ) ROY V. KOVAL, ) PROBATE NOTICE TO CREDITORS ) Deceased. ) (RCW 11.40.020; 11.40.030) ) The Personal Representative named below has been appointed and has qualified as Personal Representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative, or the Personal Representative’s attorney at the address stated below, a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of:(1) Thirty days after the Personal Representative served or mailed the notice to the creditors as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate assets and nonprobate assets. Date of First Publication: March 29, 2023  /s/Kathy L. Koval Kathy L. Koval, Personal Representative Court of Probate Proceedings:   King County Superior Court Cause No. 23-4-02167-1 SEA Attorneys for Personal Representative:  OGDEN MURPHY WALLACE PLLC By:  /s/Teresa Byers     Teresa Byers, WSBA #34388 Address for Mailing or Service: Teresa Byers OGDEN MURPHY WALLACE PLLC 901 Fifth Avenue Suite 3500 Seattle, WA 98164 206.447.7000 #04006/7022 Pub: March 29, 2023 & April 5, 12, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF BABY BOY DIAZ CASE NO. 22-7-00253-13 DOB: 11/25/2021 MINOR CHILD. NOTICE OF SUM-MONS BY PUBLICATION (TERMINATION) TO: Jessica Diaz, Valentin Diaz and any-one claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 11/10/2022. A Fact-Finding Hearing will be held 04/25/2023 at 9:00 a.m. This hearing will be held via WebEx in Superior Court of Washington, Grant County Juvenile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for instructions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be re-quired to observe social distancing and facial mask guidelines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE HEARING WILL DE-TERMINE IF YOUR PARENTAL RIGHTS TO YOUR CHILD ARE TERMINATED. IF YOU DO NOT AP-PEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE TERMINATING YOUR PARENTAL RIGHTS. To re-quest a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View information about your rights in this proceeding at www.atg.wa.gov/DPY.aspx Dated this 25th day of January 2023. /s Deputy Clerk #04023/7281 Pub: April 5, 12, 19, 2023__

PUBLIC NOTICE The Solid Waste Advisory Committee Meeting is Wednesday, April 19, 2023, at 1 PM, in the Public Works conference room located at 210 W. Alder, Ritzville, WA 99169. Please Call 509-659-3276 if you are unable to attend.   #04030/7379 Pub: April 5, 12, 2023

Notice of Application - Date of Notice: April 12, 2023- Notice is hereby given that a Utility Easement Extinguishment application was received by Grant County on March 30, 2023, from Grant County PUD (Contact: Chris Clarke, PO Box 878, Ephrata, WA, 98823), was found to be technically complete on April 6, 2023. PROJECT: Extinguishment of the existing east and northeast ten feet (10.00’) of Lot 4, Red Rock Coulee Short Plat, according to the Short Plat filed thereof in Book 28 of Short Plats, pages 70 through 71, records of Grant County, Washington as filed under Grant County Auditor’s Office under the Grant County Auditors File Number 1364509. LOCATION: The subject property is located at 13698 SW Rd E, Royal City, WA. The property is Lot 4, Red Rock Coulee Short Plat, according to the Short Plat filed thereof in Book 28 of Short Plats, pages 70 through 71, records of Grant County, WA. (Parcel # 31-3815-000). PRESENT ZONING: Urban Light Industrial (ULI). STUDIES REQUIRED: None. PUBLIC HEARING: None. CONSISTENCY STATEMENT: This proposal is subject to, and shall be consistent with, the Grant County Code, International Building Code, and International Fire Code. Copies of application materials (File #P 23-0101) are available from Aman Walia, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509) 754-2011 ext. 2536, awalia@grantcountywa.gov. Office Hours: 8 am – 5 pm, M-F. Comments must be submitted to Development Services no later than 5 pm on May 12, 2023. Comments should be as specific as possible and may be mailed, e-mailed, or hand-delivered. All persons, agencies, or tribes have the right to comment, receive notice, participate in hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above-mentioned proposal and materials.  #04036/7572 Pub: April 12, 2023_______

PUBLIC NOTICE IS HEREBY GIVEN MOSES LAKE CITY COUNCIL HAS EXTENDED THE DEADLINE FOR COMPREHENSIVE PLAN AMENDMENT REQUESTS TO APRIL 28, 2023:  Pursuant to MLMC 19.55.070 public notice is hereby given that the City of Moses Lake is accepting applications for 2023 Comprehensive Plan Amendments until April 28, 2023 at 5:00PM. Anyone who would like to apply for a comprehensive plan amendment(text, map, and zoning) will be required to complete the comprehensive plan amendment application and a State Environment Policy Act (SEPA) checklist. Both forms mentioned can be picked up at Civic Center Annex building located at 321 S. Balsam St. or the City of Moses Lake’s website (www.cityofml.com). Applications must be submitted before the due date to be considered and the fees must be paid at the time of submittal. If you have any questions or would like more information, please contact Vivian Ramsey (Planning Manager) at 509-764-3749 or Vramsey@cityofml.com  #04037/7594 Pub: April 12, 2023

Notice of Application & Proposed Mitigated Determination of Non-Significance - Date of Notice: April 12, 2023, Notice is hereby given that a JARPA (Shoreline Substantial Development Permit) Application and SEPA Checklist were received by Grant County on October 19, 2022 from Manmit Saini, DBA Wild West Camp LLC , 14716 NE 76th St. Redmond, WA 98052 (Designated Contact: Jay Dirske- Grette and Assoc., 151 South Worthen St. Suite 101, Wenatchee, WA 98801) and was found to be technically complete on April 6, 2023. Grant County expects to issue a Mitigated Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used. This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROPOSED MITIGATION MEASURES: 1. Limit the size of the project to the minimum amount necessary. 2. Project requires mitigation at a rate of 1:1 and 2:1 for all new developments to ensure a no net loss of shoreline ecological function (approximately 600 sq. ft. of plantings). 3. Construction shall be done during the water level is low enough to allow work with minimal disturbance of lands below the Ordinary High Water Mark. 4. Best management practices for control of erosion and sedimentation shall be implemented for the project. PROJECT: Shoreline Restoration of non-permitted work performed below the Ordinary High Water Mark (OHWM) and within the shoreline buffer at an existing camping and recreational resort. The applicant is looking to maintain 13 tent platforms that were established within the shoreline buffer as well as the planting of 60 native trees of various species.  ADDITIONAL PERMITS REQUIRED: WDFW HPA. LOCATION: The project is located on the south end of Blue Lake, adjacent to Hwy 17 N, in the Sun Lake State Park area. Known as the Wildwest Camp at 31199 N Hwy 17 N Coulee City WA 99115. In SECTION 29 AND THE SOUTHEAST ¼ OF SECTION 30, ALL IN TOWNSHIP 24 NORTH, RANGE 27 Parcel #16-2195-000. SHORELINE ENVIRONMENT: Shoreline Recreation. PRESENT ZONING: Shoreline Development 3. STUDIES REQUIRED Fish and Wildlife Habitat Management and Mitigation Plan. PUBLIC HEARING: None. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials  (Files #P 22-0391 and #P 22-0392) are available from Kent Ziemer, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538, kziemer@grantcountywa.gov. Office hours: 8 am –5pm, M–F. Comments must be submitted to the Planning Department no later than 5 pm on May 12, 2023. Comments should be as specific as possible and may be mailed, hand delivered or submitted via email. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials. #04038/7597 Pub: April 12, 2023

SUMMARY ORDINANCE 23-683 AN ORDINANCE AMENDING SECTIONS 5.04.070 TITLED “LICENSE-FEES”, 6.04.040 TITLED “LICENSE FEE AND TAG,” 6.10.030 TITLED “CHICKEN LICENSE PROCEDURE,” AND 6.04.150 TITLED “IMPOUNDMENT PROCEDURE – DISPOSITION” OF THE MATTAWA MUNICIPAL CODE RELATED TO FEES For a complete copy of this ordinance, please contact Mattawa City Hall. #04039/7621 Pub: April 12, 2023

Notice of Application & Proposed Mitigated Determination of Non-Significance - Date of Notice: February 14, 2023, Notice is hereby given that a JARPA (Shoreline Substantial Development Permit) Application and SEPA Checklist were received by Grant County on October 4, 2022 from Marilyn Gaylord(Designated Contact: Jason Gaylord, 8301, 212th St. SW Suite A, Edmonds, WA 98026). The application was found to be technically complete on February 3, 2023. [Grant County expects to issue a Mitigated Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used]. This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared.  A copy of the subsequent threshold determination may be obtained upon request. PROPOSED MITIGATION MEASURES: 1. Limit the size of the project to the minimum amount necessary. 2. Project requires mitigation at a rate of 1:1 for all new developments to ensure a no net loss of shoreline ecological function (approximately 7400 sq. ft. of planting mitigation on site and off-site). 3. Construction shall be done during the time of year that allows for establishment of plantings (when the water level is low enough to allow work with minimal disturbance of lands below the Ordinary High Water Mark). 4. Best management practices for control of erosion and sedimentation shall be implemented for the project. PROJECT: Site restoration and mitigation on a single-family parcel for previously completed unpermitted site work including grading, vegetation removal, placement or rocks and soil in the shoreline area. This location will be looking to complete a performance surety bond to secure for future off-site mitigation to assist in serving as the 1:1 and 2:1 mitigation.  ADDITIONAL PERMITS REQUIRED: WDFW HPA. LOCATION: The project is located at 5008 Panorama Dr. NE, Moses Lake. The parcel is in Section 36, Township 20 North, Range 27 East, WM, Grant County, WA. Parcel #12-1972-000. SHORELINE ENVIRONMENT: Shoreline Residential. PRESENT ZONING: Rural Residential 1. STUDIES REQUIRED none. PUBLIC HEARING: None. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials (Files #P 22-0371 and #P 22-0372) are available from Kent Ziemer, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538, kziemer@grantcountywa.gov. Office hours: 8 am -5pm, M-F. Comments must be submitted to the Planning Department no later than 5 pm on March 14, 2023. Comments should be as specific as possible and may be mailed, hand delivered or submitted via email. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. The optional DNS process in WAC 197-11-355 is being used. This may be the only opportunity to comment on the environmental impacts of the proposed project.  #02044/5434 Pub: February 14, 2023 ______________________

NOTICE IS HEREBY GIVEN in accordance with RCW 47.48.020 that the ROAD-W SE Canal Bridge crossing shall be closed for canal widening work from 2.20.2023 to 3.31.2023. Thereafter, a temporary single lane bridge shall provide local access for vehicles less than 31 Tons and 12’3” wide, through the end of the irrigation water season, from 4.01.2023 to 10.17.2023. Thereafter, the bridge shall be closed for bridge widening work from 10.18.2023 to 01.21.2024, with a planned reopening on or before 1.22.2024. The work will widen the existing bridge by 30’. This requires the construction of a 3rd pier, new abutment on the widened side, and a 4th span of wood beams. This notice is given in accordance with Resolution 23-006 Adopting a Six Year Transportation Improvement plan for 2023-2028, which includes this bridge work. There will be an on-site bridge widening workshop provided by Grant County Public Works Staff at 1PM on 2.15.2023. More information regarding this project and detour planning can be found on the Grant County Public Works website. #02045//5473 Pub# February 13, 14, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:30 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Pelican Point Park and Recreation District # 2 of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by the password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05005/7609 Pub: May 2, 9, 16, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Airport Parks and Recreation District #1 Of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05006/7610 Pub: May 2, 9, 16, 2023

BEFORE THE HONORABLE BOARD OF COUNTY COMMISSIONERS OF GRANT COUNTY, WASHINGTON In the matter of the Application of  NOTICE OF HEARING ON APPLICATION FOR A COUNTY Public Utility District No. 2 of  ROAD FRANCHISE Grant County, WA  for a franchise to enter upon, construct,  operate and maintain certain facilities upon  County Roads within the County of Grant,  State of Washington NOTICE IS HEREBY GIVEN that the Public Utility District No. 2 of Grant County has filed with the Board of County Commissioners of Grant County, Washington, an application for a franchise for a period of fifty (50) years set, erect, install, place, lay, construct, operate and maintain and install overhead and/or underground electrical distribution line(s) and construct, reconstruct, operate, patrol, maintain and remove communication, fiber optic, telecommunication, telephonic, television, telecomputing or any other communication or cable facilities along certain County roads in Grant County, Washington lying within the following described portion of the County, to-wit: All Sections, Townships, Ranges, County Roads, Right of Ways and undeveloped Right of Ways in the jurisdiction of Grant County, WA NOTICE IS FURTHER GIVEN that the Board of County Commissioners of Grant County, Washington, has fixed the hearing on said application for the franchise for the 30th day of May, 2023 at the hour of 3:15 o’clock pm in the Board of County Commissioners’ room in the Grant County Courthouse in Ephrata, Grant County, State of Washington, and any person may appear at this time and place to be heard for or against the granting or denying of said franchise or any part thereof. Webex virtual meeting is also available by calling 1-408-418-9388 and entering access code 2486 727 7823 (password 26220629). DATED this 21st day of April, 2023. Michele Jaderlund, Auditor of Grant County, Washington s/sMichele Jaderlund____________ Auditor   #05012/8113 Pub: May 16, 23, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD May 30, 2023 at  3:30 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider the following budget extension request: *Grants Administration Fund 190.001 to receive Washington State Department of Commerce Grants in the amount of $4,611,876.00 for pass through funding for the ERAP 2.0 (Contract 21-4619C-108 $3,905,000) and CHG (Contract 22-46108-10 $706,876.00) grants. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2486 727 7823) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz Deputy Clerk of the Board Grant County Commissioners #05011/8114 Pub: May 16, 23, 2023

NOTICE TO SUPPLIERS Sealed bids plainly marked “Bid for Steel Canopy Body” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, May 30th, 2023 and will then and there in the Public Meeting Room be opened and publicly read.  This contract provides for furnishing and delivering a Steel Canopy Body in accordance with the plans and specifications. Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County. The improvement for which bids will be received are as follows: Bid Specifications for Steel Canopy Body General Specifications This spec is patterned after the Knapheide KC7132H2094 Steel Canopy Body.   - 133.25” L x 94”W x 90” H (40” H side compartments) - 20” side compartment depth - Curbside  Horizontal (RH) compartment extends to rear of body - 14 and 16 gauge galvanneal steel body shell – Keyed alike stainless steel paddle handles with rotary style latches - Master locking system installed on both sides of body - Transverse-style L V 1 compartment extends to the back of R V 1 - (2) adjustable divider shelves in R V 1 compartment - (2) adjustable divider shelves in each L V 2 and R V 2  compartment - (1) bolt t- in divider shelf in R H compartment - (1) adjustable divider shelf in each L R and RR compartment - Double-panel galvanneal doors on rear of canopy (20 gauge outer, 14 gauge inner): - 49.5”W x 63.1” H clear door opening dimensions - Solid panel; no glass/ glass guards - 71.1” interior clear height - (2) L E D interior dome lights - (2) full length shelves on each side of canopy  Interior - 6-year limited warranty - Electro- immersion epoxy primer process - Fully undercoated  (Acrylic) - LED stop, tail, turn, and back-up lights - Chassis-specific install kit (loose): - Includes chassis-specific wiring harness adapter - 94”W Galva-grip bumper (loose) with hitch recess and K nap Liner  coating - Canopy upper side doors with 3-point twist latches - Rear chute doors deleted - 94” wide knaplined Galva-grip step bumper Install Knapheide dual rear wheel KUV cc canopy body as follows: - S/T /T lights - Mud flaps - (1) fuel spout - (2) interior dome lights - Standard bumper Paint 132” K U V cc canopy body urethane: Ford paint code PQ 1 Exhaust extension to bring exhaust out flush  with the body 1 Class V receiver hitch installed as follows: - 24,000 lb. maximum trailer weight , 1,600 lb. maximum vertical load - 2” receiver tube with pin and clip - Includes pin with cotter - Powder coated black 1 7-way trailer socket , RV style with flat blades 1LED compartment light strips in all  compartments for an 8 compartment service body - High intensity LED light strips mounted on each side of the compartment - Wired to existing chassis upfitter switch 1 C T E H .D . Aluminum 7-drawer unit installed as follows: LV2 - 14” w x 32”h x 16”d - (4) -3”, (2) -5”, and (1) -7” removable drawers –  Aluminum construction - Patented motion latch drawer handles - 250 lb. capacity roller slides - Powder coated red with black handles - (6) divider kits - Rubber liners in all drawers 1  Install customer’s existing Miller Bobcat 250 welder in LV1/ transverse compartment - Plumb exhaust up through canopy top 1 110v GFI electric outlet on rear of body wired to customer supplied welder  (No inverter) Install (4) Whelen WHL31HAF LED beacon lights as follows: - Weld mounting plates to canopy - (2) at the front corners of canopy body - (2) at rear corners of the canopy - Install LED beacon light on mounting plates and wire to chassis upfitter switch 1 Install Ford Factory Backup Camera 1 Dominator Liner red, front of body 1 Speed Liner 1000 black, cargo area floor and tailgate Speed Liner 1000 black, cargo area sides Provide the cost to furnish and deliver (inclusive of shipping) F.O.B., the following items meeting the specifications: #05031/8826 Pub: May 12, 16, 19, 23, 26, 2023

A board seat on the Columbia Basin Conservation District is available for appointment by the Washington State Conservation Commission. Conservation district board supervisors are public officials who serve without compensation and set policy and direction for the conservation district. An applicant must be a registered voter in Washington State and may be required to own land or operate a farm. Applicants for appointed positions do not have to live within the district to apply. For more information, please contact the Columbia Basin Conservation District or read the Guide to Appointment for Conservation District Applicants (https://assets.website-files.com/5ec2d4f7da309c68cdc0655a/5f36cfa9fb8e3e5d59ceaee9_CD-appointment-guide.pdf ) which can be found on the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). To apply, use this direct link (http://www.formstack.com/forms/?1918463-JfwJs6JKCL) or please visit the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). Applications and supporting materials must be received by the Conservation Commission no later than March 31, 2023. #03004/5884 Pub: February 24, 2023 & March 3, 10, 17, 2023.

SUPERIOR COURT OF WASHINGTON FOR LINCOLN COUNTY In the Matter of the Estate ) ) No. 23-4-00017-22      of ) ) PROBATE NOTICE TO WILLA J. EVERS, ) CREDITORS ) RCW 11.40.030           Deceased  ) ) _____________________ ) The Personal Representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent that arose before the decedent’s death must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorneys at the address stated below a copy of the claim and filing the original of the claim with the Clerk of this Court. The claim must be presented within the later of (1) thirty days after the Personal Representative served or mailed the Notice to the Creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of this notice. If the claim is not presented within this time frame, the claim will be forever barred, except as otherwise provided in RCW Section 11 and RCW 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: 03/03/2023 Personal Representative: CHARLES L. EVERS Attorney for P.R.: Norman D. Brock Address for Mailing or Service: Brock Law Firm, P.S. 111 S. Post St., Ste. 2280 Spokane, Washington 99201 /s/Charles L. Evers Charles L. Evers Personal Representative #03014/6146 Pub: March 3, 10, 17, 2023

GRANT COUNTY WATER CONSERVANCY BOARD NOTICE OF APPLICATIONS FOR CHANGE OF GROUNDWATER SUPERCEDING CERTIFICATE G3-01508C(G)  Notice of Applications for Change of Water Right to change the point of withdrawal, place of use, period of use, and purpose of use under Groundwater Water Right No. G3-01508C(G). TAKE NOTICE: That on November 22, 2022, Dove Haven Homeowners Associations (HOA) No. 1 and No. 2 filed application numbers GRAN-22-04 and GRAN-22-05, respectively, with the Grant County Water Conservancy Board (GCWCB) to change the point of withdrawal, place of use, period of use, and purpose of use under Groundwater Water Right No. G3-01508C(G). That said right, G3-01508C(G), under priority date August 5, 1964, authorizes the withdrawal of 500 gallons per minute (gpm) and 240 acre-feet per year (AF/yr) for seasonal irrigation of 75 acres from one point of withdrawal well located within the SE¼ SE¼ of Section 8, T. 20 N., R. 28 E. on Grant County parcel 170921000. The existing place of use is the E½ SW¼, W½ SE¼, and SE¼ SE¼ of Section 8, T. 20 N., R. 28 E. on Grant County parcel 170921000. Under GRAN-22-04, Dove Haven HOA No. 1 is seeking to transfer 15.2 gpm and 7.3 AF/yr from G3-01508C(G) to Dove Haven Acres Lots 2 through 17 (parcels 120136766, 120136767, 120136768, 120136769, 120136770, 120136771, 120136772, 120136773, 120136774, 120136775, 120136776, 120136777, 120136778, 120136779, 120136780, and 120136781) in the W½ NE¼ of Section 2, T. 19 N., R. 28 E. The purpose and period of use of the portion proposed for transfer to Dove Haven HOA No. 1 will be changed from seasonal irrigation to continuous potable supply. The proposed point of withdrawal consists of two wells located on Grant County parcels 120136791 and 120136792 in the W½ NE¼ of Section 2, T. 19 N., R. 28 E.  Under GRAN-22-05, Dove Haven HOA No. 2 is seeking to transfer 5.7 gpm and 2.7 AF/yr from G3-01508C(G) to Dove Have Acres Lots 20 through 25 (parcels 120136784, 120136785, 120136786, 120136787, 120136788, and 120136789) in the SE¼ NE¼ of Section 2, T. 19 N., R. 28 E. The purpose and period of use of the portion proposed for transfer to Dove Haven HOA No. 2 will be changed from seasonal irrigation to continuous potable supply. The proposed PoW consists of one well located on Grant County parcel 120136790 in the SE¼ NE¼ of Section 2, T. 19 N., R. 28 E.  The portion of G3-01508C(G) to remain at the existing location following approval of these two change applications is in quantities of 479.1 gpm and 230.0 AF/yr for seasonal irrigation of 71.9 acres. There will be no changes to the place of use or point of withdrawal for the remaining portion of G3-01508C(G).  Any protests or objections to the approval of these applications may be filed with the Department of Ecology and must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-dollar ($50) recording fee and filed with the Cashiering Section, State of Washington, Department of Ecology, P.O. Box 47611, Lacey, Washington 98509-7611 within thirty (30) days from March 10, 2023.  Any interested party may submit comments, objections, and other information to the GCWCB regarding these applications. The comments and information may be submitted in writing or verbally at any public meeting of the GCWCB held to discuss or decide on these applications. Additionally, the GCWCB will consider written comments or information provided within thirty (30) days from March 10, 2023, said written comments or information to be provided to its office located 2145 Basin Street SW, Ephrata, WA 98823.   #03016/6164 Pub: March 3, 10, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FRO THE COUNTY OF GRANT In the matter of the Estate of: ) ) NO. 23-4-00021-13 MARCELO PRUNEDA, ) ) PROBATE NOTICE TO CREDITORS Deceased. ) ____________________________ ) The Personal Representative named below has been appointed as Personal Representative of this estate. Any person having a claim against the decedent must, before the time claim would be barred by any other wise applicable statute of limitations, present the claim in the manner as provieded in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s Attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provieded under RCW 11.40.020(1)(c): or (2) four months after the date of first publication of the noitce. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 abd 11.40.060. This bar is efffective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: Date March 10, 2023 Personal Representative: Elida Martinez Street P.O.Box 14 City, State, Zip Warden, WA 98857 #03022/6317 Pub: March 10, 17, 24, 2022

NOTICE TO SUPPLIERS Sealed bids plainly marked “Bid for Steel Canopy Body” will be received by Grant County at the Grant County Public Works Office located in Ephrata, WA. 124 Enterprise Street, Ephrata, WA 98823, until 9:00 A.M., Tuesday, May 30th, 2023 and will then and there in the Public Meeting Room be opened and publicly read.  This contract provides for furnishing and delivering a Steel Canopy Body in accordance with the plans and specifications. Plans, specifications and bid documents may be obtained from the Public Works Department at no charge. Informational copies of the maps, plans, and specifications are on file for inspection at the Public Works Department of Grant County, 124 Enterprise St. SE, Ephrata, WA 98823. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this proposal, if made, may be made in whole or in part as determined to be in the best interest of Grant County. The improvement for which bids will be received are as follows: Bid Specifications for Steel Canopy Body General Specifications This spec is patterned after the Knapheide KC7132H2094 Steel Canopy Body.   - 133.25” L x 94”W x 90” H (40” H side compartments) - 20” side compartment depth - Curbside  Horizontal (RH) compartment extends to rear of body - 14 and 16 gauge galvanneal steel body shell – Keyed alike stainless steel paddle handles with rotary style latches - Master locking system installed on both sides of body - Transverse-style L V 1 compartment extends to the back of R V 1 - (2) adjustable divider shelves in R V 1 compartment - (2) adjustable divider shelves in each L V 2 and R V 2  compartment - (1) bolt t- in divider shelf in R H compartment - (1) adjustable divider shelf in each L R and RR compartment - Double-panel galvanneal doors on rear of canopy (20 gauge outer, 14 gauge inner): - 49.5”W x 63.1” H clear door opening dimensions - Solid panel; no glass/ glass guards - 71.1” interior clear height - (2) L E D interior dome lights - (2) full length shelves on each side of canopy  Interior - 6-year limited warranty - Electro- immersion epoxy primer process - Fully undercoated  (Acrylic) - LED stop, tail, turn, and back-up lights - Chassis-specific install kit (loose): - Includes chassis-specific wiring harness adapter - 94”W Galva-grip bumper (loose) with hitch recess and K nap Liner  coating - Canopy upper side doors with 3-point twist latches - Rear chute doors deleted - 94” wide knaplined Galva-grip step bumper Install Knapheide dual rear wheel KUV cc canopy body as follows: - S/T /T lights - Mud flaps - (1) fuel spout - (2) interior dome lights - Standard bumper Paint 132” K U V cc canopy body urethane: Ford paint code PQ 1 Exhaust extension to bring exhaust out flush  with the body 1 Class V receiver hitch installed as follows: - 24,000 lb. maximum trailer weight , 1,600 lb. maximum vertical load - 2” receiver tube with pin and clip - Includes pin with cotter - Powder coated black 1 7-way trailer socket , RV style with flat blades 1LED compartment light strips in all  compartments for an 8 compartment service body - High intensity LED light strips mounted on each side of the compartment - Wired to existing chassis upfitter switch 1 C T E H .D . Aluminum 7-drawer unit installed as follows: LV2 - 14” w x 32”h x 16”d - (4) -3”, (2) -5”, and (1) -7” removable drawers –  Aluminum construction - Patented motion latch drawer handles - 250 lb. capacity roller slides - Powder coated red with black handles - (6) divider kits - Rubber liners in all drawers 1  Install customer’s existing Miller Bobcat 250 welder in LV1/ transverse compartment - Plumb exhaust up through canopy top 1 110v GFI electric outlet on rear of body wired to customer supplied welder  (No inverter) Install (4) Whelen WHL31HAF LED beacon lights as follows: - Weld mounting plates to canopy - (2) at the front corners of canopy body - (2) at rear corners of the canopy - Install LED beacon light on mounting plates and wire to chassis upfitter switch 1 Install Ford Factory Backup Camera 1 Dominator Liner red, front of body 1 Speed Liner 1000 black, cargo area floor and tailgate Speed Liner 1000 black, cargo area sides Provide the cost to furnish and deliver (inclusive of shipping) F.O.B., the following items meeting the specifications: #05031/8826 Pub: May 12, 16, 19, 23, 26, 2023

CITY OF MOSES LAKE NOTICE TO CONSULTANTS FOR Project # GC2022-081 SR 17 / Yonezawa Blvd Intersection Improvement The City of Moses Lake solicits interest from consulting firms with expertise in Civil and Structural Engineering Design. This agreement will be for approximately 18 Months in duration with the option for the City of Moses Lake to extend it for additional time and money if necessary. It is anticipated that work will commence during the 3rd Quarter of 2023. Consultants will be considered for the following project. The City of Moses Lake reserves the right to amend terms of this “Request for Qualifications” (RFQ) to circulate various addenda, or to withdraw the RFQ at any time, regardless of how much time and effort consultants have spent on their responses. Project Description The work to be performed by the CONSULTANT consists of preparing preliminary engineering design for improvements to Yonezawa Blvd & SR 17 Intersection. The proposed improvements include constructing a multilane roundabout and extending Yonezawa Avenue East to accommodate four lanes of traffic, removal of exiting signal systems in order to accommodate the proposed improvements and coordination with multiple agencies in preparation for construction. This project has 13% DBE goal. The major features of the project are as follows: • Design of multilane roundabout to WSDOT Standard Specification and Design Manual. • Design new connection for 4th leg on the intersection for East Yonezawa Blvd Extension to accommodate up to four lanes of traffic that meets City Standards. • Environmental documentation and preparation of permit applications if necessary. • Topographic and boundary survey (the City has completed some of the survey work; the consultant will be provided with the existing survey to expand to project limits). • Geotechnical engineering as needed for roadway and storm drainage design. • Illumination System modification design and traffic signal removal. • Determination of R/W needs, limited access revisions, and R/W plan preparation. • Construction phasing, sequencing, property access plans, and site-specific traffic control plans. • New utility installation and existing utility relocation coordination as needed. • A copy of the Grant application and award letter are available by request. The City of Moses Lake reserves the right to retain the services of the successful firm(s) for any subsequent phases (R/W, CN) associated with this/these project(s). Evaluation/ Scoring Criteria Submittals will be evaluated and ranked based on the following criteria: FACTOR POINTS Qualification of Proposed Project Manager & Team 30 Understanding and approach to meet schedule 40 Familiarity with WSDOT/FHWA projects & standards. 10 Past Performance/References 10 Approach to meet the DBE goal (DBE Participation Plan) 10 MAXIMUM AVAILABLE POINTS 100 Submittal • Submittals should include the following information: Firm name, phone, and fax numbers; Name of Principal-in-Charge and Project Manager; and number of employ ees in each firm proposed to project. • Submittals must be limited to 10 double-sided pages (20 total faces), excluding a letter of interest & resumes. Submittals must include the following information: 1) Letter of Interest: The cover letter shall briefly summarize the firm’s qualifications and experience relevant to the scope. A principal or officer of the firm authorized to execute contracts or other similar documents on the firm's behalf must sign the letter. 2) Evidence of the firm’s ability and availability to perform the required services: a) Outline your firm’s experience on the Scope of Work. b) Describe your firm’s overall design approach, including organization and work tasks necessary to accomplish the objectives, products, and project schedule. c) If it is your firm’s practice to have any specific sub-categories of the Scope of Work performed by sub-consultants, please identify the sub-consultants you anticipate using, indicate their specific roles, and outline their experience on similar or related work. d) Describe your quality control process. 3) Qualifications/expertise of the key personnel on the team; with evidence of the availability of staffing to begin immediately upon award of Contract. a) Provide a list of key personnel, including sub-consultants indicating the specific role of each, and clearly identify the Project Manager. Project Manager’s qualifications are key to the City’s evaluation of the Consultant's ability to meet the City’s needs. b) Provide a professional resume for each named key personnel, indicating the extent of their experience on projects related to this type of work. 4) Past performance and record of successful completion of similar work. a) Describe any previous projects (firm and individual, indicate each) of similar nature and scope, and provide a specific description of specific responsibility on such projects. b) Note any information useful in demonstrating successful results on previous projects (within budget, constructed within contract time, etc.). 5) Attachments a) Resumes: include resumes of all key personnel that will work directly with or on this project. b) Provide a list of recent client references, ideally reflecting projects similar in nature. Please submit 1 digital copy (thumb drive) and 1 hard copy of your Statement of Qualifications to: City of Moses Lake, 321 S Balsam Street, Attn: Levi Bisnett no later than 4:00 p.m. on June 8, 2023. Submittals will not be accepted after that time and date. Any questions regarding this project should be directed to Levi Bisnett, at (509) 764-3775 or lbisnett@cityofml.com Additional Information for prospective consultants: Federal EEO Requirements Federally funded projects will be held to Federal EEO requirements. Americans with Disabilities Act (ADA) Information The City of Moses Lake in accordance with Section 504 of the Rehabilitation Act (Section 504) and the Americans with Disabilities Act (ADA), commits to nondiscrimination on the basis of disability, in all of its programs and activities. This material can be made available in an alternate format by emailing: City of Moses Lake, Levi Bisnett at lbisnett@cityofml.com or by calling collect (509)764-3775. Title VI Statement The City of Moses Lake, in accordance with the provisions of Title VI of the Civil Rights Act of 1964 (78 Stat. 252, 42 U.S.C. 2000d to 2000d-4) and the Regulations, hereby notifies all bidders that it will affirmatively ensure that in any contract entered into pursuant to this advertisement, disadvantaged business enterprises will be afforded full and fair opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award.” Dates of publication in the (Columbia Basin Herald): (May 12, 2023), and (May 19, 2023). #05033/8862 Pub: May 12, 19, 2023

LEGAL NOTICE The Grant County Board of Health will hold a public hearing at the Grant County Health District conference room at 1038 W Ivy Ave, Moses Lake and via Zoom https://us02web.zoom.us/j/83754805362?pwd=NkRuczVJMS96WTF3TGFqSWVQTGY2QT09 on Wednesday, June 14, 2023 at 6:00 p.m. The purpose of the hearing will be to adopt Ordinance 23-02 (GCHD Fee Schedule). Anyone wishing to comment regarding this matter should appear at the meeting.  #05043/9110 Pub: May 19, 2023

NOTICE TO VENDORS The Quincy-Columbia Basin Irrigation District purchases materials, equipment and supplies estimated to cost between $10,000 and $50,000 as set forth in RCW 39.04.190. Quotations are solicited through District communications to vendors having requested to be listed to receive such notifications. To be included on District vendor lists contact: Purchasing Agent Quincy-Columbia Basin Irrigation District 1720 S Central Ave, PO Box 188 Quincy, WA 98848 (509) 787-3591 (509) 787-3906 FAX #05044/9122 Pub: May 19, 26, 2023

FILED 2023 MAY 12 02:55 PM KING COUNTY SUPERIOR COURT CLERK E-FILED CASE #: 23-4-03475-6 SEA SUPERIOR COURT OF THE STATE OF WASHINGTON FOR KING COUNTY   ESTATE OF: | NO. 23-4-03475-6 SEA  | FRED TOSHIO GOTO, | NOTICE TO CREDITORS RCW | ______________________Deceased._____ | 11.40.030   The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.   ANDREW GOTO, Personal Representative Attorney for Personal Representative: WSBA No. 18847 Lawrence F. Brown, Jr. Attorney at Law First filing date: May 12, 2023 P. 0. Box 940 Fall City WA 98024 First publication date: May 19, 2023   #06002/9126 Pub: May 19, 26, 2023 & June 2, 2023 First filing date: May 12, 2023   First publication date:  BROWN & STERLING, P.S. P.O. Box 940 4318 Preston-Fall Cily Rd SE Fall Cily. WA 98024 425-222-6374

SUMMARY OF ORDINANCE #835 THE CITY COUNCIL OF THE CITY OF WARDEN HAS ADOPTED AN ORDINANCE AMENDING WARDEN MUNICIPAL CODE CHAPTER 8.09 ENTITLED GARBAGE SERVICE CHARGES, “APPENDIX G”, Rates Effective July 1, 2023. Passed by the City Council of the City of Warden, Washington, this 9th day of May, 2023. Any person may obtain the full text of this ordinance by mail without charge upon request. #06003/9146 Pub: May 19, 2023 and June 1, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:30 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Pelican Point Park and Recreation District # 2 of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by the password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05005/7609 Pub: May 2, 9, 16, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 23, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider dissolving Airport Parks and Recreation District #1 Of Grant County (pursuant to RCW 36.96). This district has been inactive for a five-year period. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2490 798 7672) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05006/7610 Pub: May 2, 9, 16, 2023

PUBLIC NOTICE – The May meeting of the Noxious Weed Control Board of Grant County will be held Tuesday, May 16, 2023, at 10:00 a.m. The meeting will be held in-person at the Bureau of Reclamation building, 32 C St NW, Room 304B, Ephrata, WA, and via Webex. Please call (509) 237-4567 ahead of the meeting time for remote attendance instructions. Meeting updates will be posted on our website at www.grantcountyweedboard.org. Signed: Ron Tebow, Chairman; Wes Sieg, Vice-Chairman; Summer Sahli, Director; Chuck Sandmann, Director #05020/8300 Pub: May 9, 12, 2023

WASHINGTON STATE SUPERIOR COURT  COUNTY OF GRANT United States Department of Agriculture | (USDA), | No.  | Plaintiff, | SUMMONS (60 days) v. | | Eddie L. Rayoum, an individual and martial | community; Alice F. Rayoum, an individual | and martial community; and John and Jane | Does I through X; occupants of the subject | real property; and all other persons or parties | unknown claiming any right, title, interest, | lien or Estate in the property herein describe. |  | Defendants. | ____________________________________ | TO THE DEFENDANTS: A lawsuit has been started against you in the above entitled court by United States Department of Agriculture (“USDA”), hereinafter “Plaintiff”. Plaintiff’s claim is stated in the written complaint, a copy of which is available upon request and is on file with the court.  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after 28th day of March, 2023 and defend the above entitled action in the above entitled court, and answer the complaint of the plaintiff, and serve a copy of your answer upon the undersigned attorneys for plaintiff at their office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. The purpose of this suit is to foreclosure on your interest in the following described property:  The North 36 feet of Lot 19 and the South 27 feet of Lot 20, Block 11, Ephrata Heights First Addition to Ephrata, according to the plat thereof recorded in Volume 3 of Plats, page 4, records of Grant County, Washington. Which is located at:  140 H St. SE, Ephrata, WA 98823. In order to defend against this lawsuit, you must respond to the complaint by stating your defense in writing, and by serving a copy upon the person signing the summons within 60 days after the service of this summons, excluding the day of service, or a default judgment may be entered against you without notice. A default judgment is one where plaintiff is entitled to what he or she asks for because you have not responded. If you serve a notice of appearance on the undersigned person, you are entitled to notice before a default judgment may be entered. IMPORTANT NOTICE If judgment is taken against you, either by default or after hearing by the court, your property will be sold at public auction. You may prevent the sale by paying the amount of the judgment at any time prior to the sale. If your property is sold, you may have the right to redeem the property during the redemption period if applicable, by paying the amount for which the property was sold, plus interest and costs of the sale. If you wish to seek the advice of an attorney in this matter, you should do so promptly so that your written response, if any, may be served on time.  This summons is issued pursuant to rule 4 of the Superior Court Civil Rules of the State of Washington and RCW 4.28.100(7). Dated this 7th day of March, 2023. WONG FLEMING /s/ Wong Fleming_____________ Vanessa Moore, WSBA #52668 Attorney for Plaintiff #05001/6441 Pub: March 28, 2023, April 4, 11, 18, 25, 2023 & May 2, 2023

SUPERIOR COURT OF WASHINGTON IN AND FOR GRANT COUNTY MIDDLE BAR C, LLC, a Washington limited | liability company,  | Plaintiff, | NO. 23-2-00152-13 vs. | FRANCES E. SHAW, an individual; | ENID TREFFINGER, an individual; and ALSO ALL | OTHER PERSONS OR PARTIES UNKNOWN | SUMMONS CLAIMING ANY RIGHT, TITLE, ESTATE, | LIEN, OR INTEREST IN THE REAL ESTATE | DESCRIBED IN THE COMPLAINT HEREIN, |                             Defendants. | The State of Washington to DEFENDANTS FRANCES E. SHAW, ENID TREVVINGER, and ALSO ALL OTHER PERSONS OR PARTIES UNKNOWN CLAIMING ANY RIGHT, TITLE, ESTATE, LIEN, OR INTEREST IN THE REAL ESTATE DESCRIBED IN THE COMPLAINT HEREIN:  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after the 14th day of March, 2023, and defend the above entitled action in the above titled court, and answer the complaint of the plaintiff MIDDLE BAR C, LLC, and serve a copy of your answer upon the undersigned attorneys for the Plaintiff Middle Bar C, LLC at its office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court.  This action arises from a complaint to quiet title in real property in Grant County, Washington.  Dated this 8th day of March, 2023. LUKINS & ANNIS, P.S. By /s/ Court A. Hall___________ TREVOR R. PINCOCK, WSBA #36818 COURT A. HALL, WSBA #54016 Attorneys for Plaintiff 717 W. Sprague Ave., Ste. 1600 Spokane, WA 99201 (509) 455-9555 #04001/6464 Pub: March 14, 21, 28, 2023 & April 4, 11, 18, 2023

SMALL WORKS ROSTER   Columbia Basin Hydropower is preparing a small works roster of responsible contractors who request to submit bid quotations on contracted construction projects of less than $300,000 to be awarded to the lowest responsible bidder. To request to be placed on the roster, submit business name and contact information to: info@cbhydropower.org. #03034/6523 Pub: March 21, 28, 2023

APN:111432000 T.S. No. LO-52658-WA U.S. DEPARTMENT OF HOUSING AND URBAN DEVELOPMENT NOTICE OF DEFAULT AND FORECLOSURE SALE. Recorded in accordance with 12 USCA 3764 (c) WHEREAS, on 6/20/2011, a certain Deed of Trust was executed by Thomas E. McCurdy and Nancy McCurdy, husband and wife as trustor in favor of One Reverse Mortgage, LLC as beneficiary, and FNTG-Chicago Title as trustee, and was recorded on 7/13/2011, as Instrument No. 1288475, in Book XX, Page XX, in the Office of the County Recorder of Grant County, Washington; and WHEREAS, the Deed of Trust was insured by the United States Secretary of Housing and Urban Development (the Secretary) pursuant to the National Housing Act for the purpose of providing single family housing; and WHEREAS, the beneficial interest in the Deed of Trust is now owned by the Secretary, pursuant to an Assignment of Deed of Trust dated 1/23/2019, recorded on 5/24/2019, as instrument number 1409554, book XX, page XX, in the Office of the County Recorder, Grant County, Washington; and WHEREAS, a default has been made in the covenants and conditions of the Deed of Trust in that the payment due on 5/18/2022, was not made due to an obligation of the borrower under this security instrument is not performed and remains wholly unpaid as of the date of this notice, and no payment has been made sufficient to restore the loan to currency; and WHEREAS, the entire amount delinquent as of3/9/2023 is $190,734.26; and WHEREAS, by virtue of this default, the Secretary has declared the entire amount of the indebtedness secured by the Deed of Trust to be immediately due and payable;  NOW THEREFORE, pursuant to powers vested in me by the Single Family Mortgage Foreclosure Act of 1994, 12 U.S.C. 3751 et seq., by 24 CFR part 27, subpart B, and by the Secretary’s designation of Law Offices of Jason C Tatman APC as Foreclosure Commissioner, recorded on 10/19/2020 as instrument number 1435815, book XX, page XX notice is hereby given that on 4/14/2023 at 10:00 AM local time, all real and personal property at or used in connection with the following described property will be sold at public auction to the highest bidder: Legal Description: LOT 3, BLOCK 1, VANCE-EMERY SUBDIVISION, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 3 OF PLATS, PAGE 33, RECORDS OF GRANT COUNTY, WASHINGTON. Commonly known as: 613 S Pacific St, Moses Lake, WA 98837 The sale will be held at At the Police Justice County Building, 401 Balsam Street NKA 411 South Balsam Street, Moses Lake, WA. The Secretary of Housing and Urban Development will bid an estimate of$195,834.04. For Sales information visit www.SuperiorDefault.com or call 855-986-9342 There will be no proration of taxes, rents or other income or liabilities, except that the purchaser will pay, at or before closing, his prorata share of any real estate taxes that have been paid by the Secretary to the date of the foreclosure sale.  When making their bids, all bidders except the Secretary must submit a deposit totaling $19,583.40 [ 10% of the Secretary’s bid] in the form of a certified check or cashier’s check made out to the Secretary of HUD. Each oral bid need not be accompanied by a deposit. If the successful bid is oral, a deposit of $19,583.40 must be presented before the bidding is closed. The deposit is nonrefundable. The remainder of the purchase price must be delivered within 30 days of the sale or at such other time as the Secretary may determine for good cause shown, time being of the essence. This amount, like the bid deposits, must be delivered in the form of a certified or cashier’s check. If the Secretary is the high bidder, he need not pay the bid amount in cash. The successful bidder will pay all conveyancing fees, all real estate and other taxes that are due on or after the delivery of the remainder of the payment and all other costs associated with the transfer of title. At the conclusion of the sale, the deposits of the unsuccessful bidders will be returned to them. The Secretary may grant an extension of time within which to deliver the remainder of the payment. All extensions will be for 15-day increments for a fee of $500.00, paid in advance. The extension fee shall be in the form of a certified or cashier’s check made payable to the Secretary of HUD. If the high bidder closes the sale prior to the expiration of any extension period, the unused portion of the extension fee shall be applied toward the amount due. If the high bidder is unable to close the sale within the required period, or within any extensions of time granted by the Secretary, the high bidder may be required to forfeit the cash deposit or, at the election of the foreclosure commissioner after consultation with the HUD Field Office representative, will be liable to HUD for any costs incurred as a result of such failure. The commissioner may, at the direction of the HUD field office Representative, offer the Property to the second highest bidder for an amount equal to the highest price offered by that bidder. There is no right of redemption, or right of possession based upon a right of redemption, in the mortgagor or others subsequent to a foreclosure completed pursuant the Act. Therefore, the Foreclosure commissioner will issue a Deed to the purchaser(s) upon receipt of the entire purchase price in accordance with the terms of the sale as provided herein. HUD does not guarantee that the property will be vacant. The amount that must be paid if the Mortgage is to be reinstated prior to the scheduled sale is $195,834.04, as of 4/13/2023, plus all other amounts that would be due under the mortgage agreement if payments under the mortgage had not been accelerated, advertising costs and postage expenses incurred in giving notice, mileage by the most reasonable road distance for posting notices and for the Foreclosure Commissioner’s attendance at the sale, reasonable and customary costs incurred for title and lien record searches, the necessary out-of-pocket costs incurred by the Foreclosure Commissioner for recording documents, a commission for the Foreclosure Commissioner, and all other costs incurred in connection with the foreclosure prior to reinstatement.  Tender of payment by certified or cashier’s check or application for cancellation of the foreclosure sale shall be submitted to the address of the Foreclosure Commissioner provided below. Date: 3/13/23 By: Rhonda Rorie  rr@tatmanlegal.com Law Offices of Jason C Tatman, APC U.S. Dept. of HUD Foreclosure Commissioner 5677 Oberlin Dr., Ste 210 San Diego, CA 92121 (858) 201-3590 Fax (858) 348-4976 (TS# LO-52658-WA SDI-26228)  #04002/6666 Pub:March 20, 27, 2023 & April 3, 2023

============ 2022 NOTICE OF CONSTRUCTION COMPLETION ============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Engineer’s Office has completed the following County Forces conducted road projects in 2022 with final true and complete costs as follows:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion Road 3-NE Phase 4 BST Surface after 22-01 County Forces $277,000 Contractor Preparations Total = $277,000 The maximum allowable construction work by County forces is $1,307,338. The 2022 County Forces completed work is well under the maximum allowed.   Dated this 16th day of March 2023 ========================== END OF NOTICE=========================== #03046/6752 Pub”March 22, 24, 27, 30, 2023

============ 2023 NOTICE OF COUNTY FORCES CONSTRUCTION============ NOTICE IS HEREBY GIVEN in accordance with RCW 36.77.070 that the Grant County Board of County Commissioners intends to have the following road(s) improved by County Forces (using county crews and equipment) in calendar year 2023:      Road/Project Name CRP# Construction Engineer’s Estimate For Construction Portion ADA Ramp / Sidewalk Upgrades ADA Ramp and/or Sidewalk County Forces $120,000 Miscellaneous Projects Safety/Drainage/Guardrail/ Bridge/Roads County Forces $250,000 B-SE Culverts Replace Culverts 18-10 County Forces $200,000 Road 23 NE Bridge Replacement 23 NE Bridge 171 Replacement 22-04 County Forces $100,000 Gravel to Oil Program (1.5 Miles) Portions of Road 8-NE and Road 12-NE County Forces $400,000 Total = $1,070,000 The maximum allowable new construction work by County forces is $1,307,338. The 2023 proposed work is well under the maximum allowed. All other new construction shall be contracted out for 2023. Dated this 16th day of March 2023 ========================== END OF NOTICE ========================== #03045/6756 Pub: March 22, 24, 27, 30, 2023

WASHINGTON STATE SUPERIOR COURT  COUNTY OF GRANT United States Department of Agriculture | (USDA), | No.  | Plaintiff, | SUMMONS (60 days) v. | | Eddie L. Rayoum, an individual and martial | community; Alice F. Rayoum, an individual | and martial community; and John and Jane | Does I through X; occupants of the subject | real property; and all other persons or parties | unknown claiming any right, title, interest, | lien or Estate in the property herein describe. |  | Defendants. | ____________________________________ | TO THE DEFENDANTS: A lawsuit has been started against you in the above entitled court by United States Department of Agriculture (“USDA”), hereinafter “Plaintiff”. Plaintiff’s claim is stated in the written complaint, a copy of which is available upon request and is on file with the court.  You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after 28th day of March, 2023 and defend the above entitled action in the above entitled court, and answer the complaint of the plaintiff, and serve a copy of your answer upon the undersigned attorneys for plaintiff at their office below stated; and in case of your failure so to do, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. The purpose of this suit is to foreclosure on your interest in the following described property:  The North 36 feet of Lot 19 and the South 27 feet of Lot 20, Block 11, Ephrata Heights First Addition to Ephrata, according to the plat thereof recorded in Volume 3 of Plats, page 4, records of Grant County, Washington. Which is located at:  140 H St. SE, Ephrata, WA 98823. In order to defend against this lawsuit, you must respond to the complaint by stating your defense in writing, and by serving a copy upon the person signing the summons within 60 days after the service of this summons, excluding the day of service, or a default judgment may be entered against you without notice. A default judgment is one where plaintiff is entitled to what he or she asks for because you have not responded. If you serve a notice of appearance on the undersigned person, you are entitled to notice before a default judgment may be entered. IMPORTANT NOTICE If judgment is taken against you, either by default or after hearing by the court, your property will be sold at public auction. You may prevent the sale by paying the amount of the judgment at any time prior to the sale. If your property is sold, you may have the right to redeem the property during the redemption period if applicable, by paying the amount for which the property was sold, plus interest and costs of the sale. If you wish to seek the advice of an attorney in this matter, you should do so promptly so that your written response, if any, may be served on time.  This summons is issued pursuant to rule 4 of the Superior Court Civil Rules of the State of Washington and RCW 4.28.100(7). Dated this 7th day of March, 2023. WONG FLEMING /s/ Wong Fleming_____________ Vanessa Moore, WSBA #52668 Attorney for Plaintiff #05001/6441 Pub: March 28, 2023, April 4, 11, 18, 25, 2023 & May 2, 2023

NOTICE IS HEREBY GIVEN that a petition dated April 5, 2023, was filed with the Board of Directors of the East Columbia Basin Irrigation District by Loeffelbein Family Trust, the holders of title to all the land hereinafter described, prayed that the following described land be included within the District: South Half of the Southeast Quarter of Section 16, Township 20N, Range 30E, Parcel Number 181356010 Grant County;  All persons interested in or that may be affected by such inclusion of the land described above are hereby notified to appear at the office of the Board at Othello, Adams County, Washington, May 3, 2023, this being the regular meeting of the Board next after the last day of publication of this Notice of Hearing, and show cause in writing, if any they have, why such land should not be included within the District as prayed for in the petition. #04017/7213 Pub: April 11, 18, 25, 2023

NOTICE IS HEREBY GIVEN that a petition dated April 5, 2023, was filed with the Board of Directors of the East Columbia Basin Irrigation District by Kevin J. Lyle, the holders of title to all the land hereinafter described, prayed that the following described land be included within the District: North Half of the North Half of Section 10, Township 15N, Range 31E.W.M., Parcel Number 2531100110001 Adams County;  All persons interested in or that may be affected by such inclusion of the land described above are hereby notified to appear at the office of the Board at Othello, Adams County, Washington, May 3, 2023, this being the regular meeting of the Board next after the last day of publication of this Notice of Hearing, and show cause in writing, if any they have, why such land should not be included within the District as prayed for in the petition. #04018/7218 Pub: April 11, 18, 25, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD May 09, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider a petition to amend Section 6.08.650 “Special regulations to specific lakes in Grant County” of the Grant County Code, adding Warden Lake. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2483 386 7206) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #05004/7607 Pub: April 23, 2023 & May 2, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD May 09, 2023 at  3:30p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to declare surplus Public Works county-owned property and order the sale thereof via public auction at www.publicsurplus.com to the highest bidder. If you would like to receive the list of miscellaneous surplus items, please contact the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2483 386 7206) followed by password (26220629), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz Deputy Clerk of the Board Grant County Commissioners #05007/7616 Pub: April 25, 2023 & May 2 2023

CITY OF MOSES LAKE PUBLIC HEARING on The Refuge at Mae Valley (TRAMV) First Addition Development Agreement 6:30 P.M. ON TUESDAY, MAY 9, 2023 MOSES LAKE COUNCIL CHAMBERS MOSES LAKE CIVIC CENTER 401 S BALSAM ST MOSES LAKE, WA 98837 The City Council of the City of Moses Lake invites all interested parties to attend a Public Hearing on May 9, 2023, at 6:30 p.m. to offer testimony on the approval of the TRAMV First Edition Development Agreement. The development agreement would approve a request to use a portion of Well Site 31 property to address a safe street design in exchange for public improvements along Well Site 31 property and Montana Street at a value of approximately $32,000. Contact Senior Planner Nathan Pate via email npate@cityofml.com, or by calling 509-764-3752 with questions related to Development Agreement. A copy of the complete staff report will be in the online meeting packet the Friday prior to the hearing which can be found posted on the City’s website: www.cityofml.com then select Government, then Agendas & Minutes. Interested persons may provide testimony either in writing or by participating in the Public Hearing. The form to register to speak at the meeting will also be on the posted agenda, or you can contact the City Clerk’s Office to receive the form in advance. The speaker request form must be completed no later than 3 p.m. on the day of the meeting to speak remotely. Written comments can also be delivered to the City Council prior to the Public Hearing, via mail to the City of Moses Lake, Attn: City Clerk’s Office, #04045/7961 Pub: April 25, 2023

Notice is hereby given that Grant County Developments Services will be re-scheduling the public hearing for the following project: Conditional Use Permit Application and SEPA Checklist were received by Grant County on February 14, 2023 from CPM Development Corp Attn: Jana McDonald and were found to be Technically Complete on March 9, 2023. Grant County expects to issue a Mitigated Determination of Non-Significance for this proposal and the Optional DNS Process in WAC 197-11-355 is being used.] This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROPOSED MITIGATION MEASURES: 1. The proposed development shall not inflict upon adjacent land(s) smoke, dust, glare, dirt, steam, vibration, noise, electrical interference, excessive hazards, or pollution which exceeds applicable local, state, or federal standards. 2. Existing vegetation will be removed from the site during mining operations. The site shall subsequently be replanted according to the approved Washington State Department of Natural Resources Reclamation Plan. 3. If any Native American Grave site(s) or archaeological/cultural resources (Indian Artifacts) are found all construction activity shall stop and the owner/developer shall immediately notify the Grant County Planning Department, the Colville Confederated Tribes and the Washington State Office of Archaeology and Historic Preservation. 5. Best management practices as specified by the Department of Ecology to mitigate fugitive dust and noise have been and will continue to be used for the duration of mining. PROJECT: A Conditional Use Permit and SEPA to allow the establishment of a surface mine and extraction operation for sand products. Approximately 250,000 cubic yards of material are estimated to be removed from this site, which will involve 40 acres on a vacant parcel. Currently there are no activities at the location. The site has also been assessed for cultural resources and an Inadvertent Discovery Plan is included in the application materials. A Wildlife Habitat Management Plan has a/so been developed in coordination with WDFW for Shrubsteppe and Mule Deer. STUDIES REQUIRED: None. LOCATION: The site address of the subject parcel would be in the 6300 block of Road 4 SW. The site is located approximately 9 miles north of Royal City.  The site is the northeast ¼ of Section 24, Township 18 N, Range 25 E, W.M., Grant County, WA Parcel #15-1670-000. ZONING: Rural Resource. PUBLIC HEARING: Grant County Hearings Examiner scheduled for Wednesday, June 14, 2023 at 12:00 pm in the Commissioner’s Hearing Room on the bottom floor of the Grant County Courthouse in Ephrata, WA. At this time, any person(s) may provide testimony for the hearing. Grant County is providing access to this scheduled hearing for the public via Webex audio connection only, members of the public may be present in the hearing room. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code 2480 2191 741 ,, you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure please call Development Services in advance of the hearing. CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials (File #P23-0053 & P23-0054) are available from Kent Ziemer, (kziemer@gratncountywa.gov) Grant County Planning Department, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2538. Office Lobby hours: 8 am – 5 pm, M-F. Comments can be submitted to the Planning Department no later than 5 pm on June 6, 2023. Comments should be as specific as possible and may be mailed, hand-delivered, or sent by email. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials.     #04048/8029 Pub: April 25, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF MAX LEE WALKER CASE NO. 23-7-00137-13 DOB: 04/27/2017 MINOR CHILD. NOTICE OF SUMMONS BY PUBLICATION (TERMINATION) TO: Brianna L. Christensen and anyone claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 04/07/2023. A Fact-Finding Hearing will be held 06/20/2023 at 9:00 a.m. This hearing will be held via WebEx in Superior Court of Washington, Grant County Juvenile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for instructions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be re-quired to observe social distancing and facial mask guidelines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. YOU ARE NOT REPRE-SENTED BY A LAWYER IN THIS TERMOINATION PROCEEDING EVEN IF YOU WERE APPOINTED A LAWYER IN THE PRIOR DEPEND-ENCY CASE. YOU MUST REAPPLY FOR APPOINTMENT OF A LAWYER IN THIS CASE. IF YOU OR A LAW-YER ON YOUR BEHALF DOES NOT APPEAR IN THIS CASE, YOU WILL BE DEFAULTED AND TERMINA-TION OF YOUR PARENTAL RIGHTS GRANTED. To request a copy of the Notice, Summons, and Termination Peti-tion, call DSHS at 509-764-5757. View information about your rights in this pro-ceeding at www.atg.wa.gov/DPY.aspx Dated this 9th day of May 2023. /s Deputy Clerk #05037/8923 Pub: May 17, 24, 31, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF JACK F. JOHSNON DOB: 02/17/2021 NO. 23-7-00172-13, LILY A. JOHNSON DOB: 07/23/2016 NO. 23-7-00173-13, ZOEY M. JOHNSON DOB: 04/14/2014 NO. 23-7-00174-13 MINOR CHILDREN. NOTICE OF SUMMONS BY PUBLICATION (TERMINATION) TO: Jessica Haddican, Brandon Johnson and anyone claiming a paternal interest. A petition to TERMINATE YOUR PA-RENTAL RIGHTS was filed on 05/01/2023. A Fact-Finding Hearing will be held 06/27/2023 at 9:00 a.m. This hear-ing will be held via WebEx in Superior Court of Washington, Grant County Juve-nile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for in-structions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be required to observe social distancing and facial mask guide-lines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 9882. YOU SHOULD BE PRESENT AT THIS HEARING. YOU ARE NOT REPRESENTED BY A LAWYER IN THIS TERMINATION PROCEEDING EVEN IF YOU WERE APPOINTED A LAWYER IN THE PRIOR DEPENDENCY CASE. YOU MUST REAPPLY FOR APPOINT-MENT OF A LAWYER IN THIS CASE. IF YOU OR A LAWYER ON YOUR BEHALF DOES NOT APPEAR IN THIS CASE, YOU WILL BE DE-FAULTED AND TERMINATION OF YOUR PARENTAL RIGHTS GRANT-ED. To request a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View infor-mation about your rights in this proceed-ing at www.atg.wa.gov/DPY.aspx Dated this 23 day of May 2023. /s Deputy Clerk #06012/9530 Pub: May 31, 2023 & June 7, 14, 2023

ORDINANCE NO. 3023 AN ORDINANCE AMENDING THE MOSES LAKE MUNICIPAL CODE TITLE 13 WATER, SEWERS, AND PUBLIC UTILITIES The ordinance amends Municipal Code with changes that are required by the City of Moses Lake’s National Pollutant Discharge Elimination Phase II Eastern Washington Permit.    #05018/8297 Pub: May 1, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF BABY BOY DIAZ CASE NO. 22-7-00253-13 DOB: 11/25/2021 MINOR CHILD. NOTICE OF SUM-MONS BY PUBLICATION (TERMI-NATION) TO: Jessica Diaz, Valentin Diaz Medina and anyone claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 11/10/2022. A Fact-Finding Hearing will be held 06/06/2023 at 9:00 a.m. This hear-ing will be held via WebEx in Superior Court of Washington, Grant County Juve-nile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for in-structions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be required to observe social distancing and facial mask guide-lines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE HEARING WILL DETERMINE IF YOUR PARENTAL RIGHTS TO YOUR CHILD ARE TERMINATED. IF YOU DO NOT APPEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE TERMINATING YOUR PARENTAL RIGHTS. To request a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View infor-mation about your rights in this proceed-ing at www.atg.wa.gov/DPY.aspx Dated this 25th day of January 2023. /s Deputy Clerk #05019/8299 Pub: May 1, 8, 15, 2023___

NOTICE TO BIDDERS Sealed bids will be received by the Public Utility District No. 2 of Grant County at 154 A Street SE Ephrata, Washington 98823 no later than 2:00 P.M on May 16, 2023, for West Canal Substation Labor Contract - Rebid as more fully described in Contract Documents 130-11694HR. The Bids will be opened and read aloud via Teams on May 17, 2023. All bids shall be subject to and shall comply with the “Instructions to Bidders” contained in the Contract Documents, copies of which are available at our ProcureWare site https://gcpud.procureware.com. When reaching this site you will need to register as a new vendor if you are not already on our electronic vendor system. Public Utility District No. 2 of Grant County, Washington By: Nicona Butler Procurement Officer #05021/8337 Pub: May 1, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR SPOKANE COUNTY  In Re the Estate of:  | NO. 23400445-32  | PAUL EUGENE MAYBEE  | PROBATE NOTICE TO CREDITORS | RCW 11.40.030  Deceased.  | ____________________________ | The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.  Date of first publication: March 22, 2023 Personal Representative: David Eugene Maybee  Attorney for Personal Representative: Andrew M. Ouimet  Address for Mailing or Service:  DATED this 16th day of  March 2023.  David Eugene Maybee, Personal Representative  ANDREW M. OUIMET, WSBA #46512  PROBATE NOTICE TO CREDITORS  RCW 11.40.030  #04004/6747 Pub: March 22, 29, 2023 & April 5, 2023

2023 AQUATIC TREATMENTS REQUEST FOR PROPOSALS The Moses Lake Irrigation and Rehabilitation District (MLIRD) respectfully requests cost proposals to survey & treat portions of Moses Lake within the District. This effort would inventory aquatic plants by species and coverage and make recommendations for a prioritized treatment plan for species not conducive to recreation or water intake and/or detrimental to water quality. Contractor must have all applicable licenses for professional work of this nature in Washington State. The project would include the following: Survey work: • Must be consistent with WA State DOE Aquatic Plant Sampling Protocols; and  • Requires previous experience identifying aquatic plants in similar waters & climates. • Contractor submitted & approved work plan based on survey(s) results. Survey & Application personnel should be familiar with Moses Lake water bathymetry. Treatment work: • MLIRD reserves final determination of contractor proposal or recommendations. Contractor should plan an estimated 200 acres, which may include: Diquat; Aquathol; Procellacor; Alum. • Proposal should include chemical price per gallon and application cost per acre for each chemical. • Selected Contractor will be responsible for the generation of all mailing lists, mailed notices, posted signs & water testing, agency reporting & required notifications within ¼ mile radius of work. • All chemicals used must be approved for aquatic use in WA State and under federal law. • Proof of $3,000,000 insurance required w/RFP, request ‘Packet’ for more detail. • GPS equipment required to plot and track treatments • All personnel & equipment supplied by Contractor Deliverables: 20 paper copies of a final report and a digital version in formats to be determined. Report to include: • Lake maps based on GPS data showing inventory findings and work performed • Recommended prioritized treatment plan for undesirable species discovered in survey(s) • Native ArcGIS shape files of treatments recommended and performed • Detailed Final Report provided by contractor Evaluation Factors for Proposal: • Positive Aquatic Survey & Applicator experience in Washington State: 25 points possible • Neat, Comprehensive, Understandable proposal: 25 Points • Summaries of other Aquatic Survey work and the results thereof in similar condi tions: 25 points possible • References & Examples showing other Aquatic Survey work: 25 points possible • Cost: 25 points possible (firm with lowest cost proposal awarded 25 points) MLIRD reserves the right to reject any or all submittals for any reason or no reason, to waive insubstantial or immaterial informalities, and select the RFP that, in the selection team’s judgment, best serves the needs of MLIRD and the people we serve. MLIRD may, in its sole discretion, renew this contract/agreement in each of three subsequent years. All completed RFP documents should include proposed survey and treatment timeframes and must be received by MLIRD no later than Tuesday – April 25, 2023, at 3:00 PM PST at 932 E Wheeler RD, Moses Lake, WA 98837. Call for Packet. (509)765-8716 #04005/7015 Pub: April 5, 12, 19, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR KING COUNTY IN PROBATE Estate of  ) NO. 23-4-02167-1 SEA ) ROY V. KOVAL, ) PROBATE NOTICE TO CREDITORS ) Deceased. ) (RCW 11.40.020; 11.40.030) ) The Personal Representative named below has been appointed and has qualified as Personal Representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative, or the Personal Representative’s attorney at the address stated below, a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of:(1) Thirty days after the Personal Representative served or mailed the notice to the creditors as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate assets and nonprobate assets. Date of First Publication: March 29, 2023  /s/Kathy L. Koval Kathy L. Koval, Personal Representative Court of Probate Proceedings:   King County Superior Court Cause No. 23-4-02167-1 SEA Attorneys for Personal Representative:  OGDEN MURPHY WALLACE PLLC By:  /s/Teresa Byers     Teresa Byers, WSBA #34388 Address for Mailing or Service: Teresa Byers OGDEN MURPHY WALLACE PLLC 901 Fifth Avenue Suite 3500 Seattle, WA 98164 206.447.7000 #04006/7022 Pub: March 29, 2023 & April 5, 12, 2023

NOTICE TO CONTRACTORS Sealed bids, plainly marked “BID FOR Patton Boulevard & Loring Drive Signal Project 2023”, will be received by the Grant County Department of Public Works, located at 124 Enterprise St. S.E., Ephrata, WA, 98823, until Tuesday, May 02, 2023 at 9:00 A.M. and will then and there be opened and publicly read. All bid proposals shall be accompanied by a bid proposal deposit in cash, certified check, cashier’s check, or surety bond in an amount equal to five percent (5%) of the amount of such bid proposal. No conditional bid bond will be accepted. Should the successful bidder fail to enter into such contract and furnish a satisfactory performance bond within the time stated in the specifications, the bid proposal deposit shall be forfeited to Grant County. Maps, plans and specifications may be purchased from the office of the County Engineer, 124 Enterprise St. S.E., Ephrata, WA 98823, upon payment of the amount of $25.00 (non-refundable). Informational copies of the maps, plans and specifications are on file for inspection at the Grant County Public Works Building, 124 Enterprise St. S.E., Ephrata, WA 98823, and in various plan centers located in Washington. The Board of County Commissioners of Grant County, Washington, reserves the right to reject any and all bids. The award of this contract, if made, will be to the lowest responsible bidder. The improvement for which bids will be received follows: Patton Boulevard & Loring Drive Signal Project 2023 This contract provides for removing the existing traffic signal cabinet and signal controller at Patton Boulevard and Loring Drive in rural Grant County Washington, and install a replacement McCain 350i ATC traffic signal cabinet, controller, and battery backup system. The Contractor shall install the County provided LED count down pedestrian modules, new pedestrian push buttons, 12” LED red, yellow, & green balls, and Wavetronix Smart Sensor Digital Wave Radar traffic detection system. #05003/7052 Pub: March 29, 2023, April 5, 12, 19, 26, 2023 & May 2, 2023

Fisher Construction Group, Inc., Chris Lang, 625 Fisher Ln Burlington, WA 98233-3431, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Simplot Moses Rainier HBF 23F012, is located at Northeast of Rd. O and Rd. 2 NE Intersection Parcel #180218000 in Moses Lake in Grant county. This project involves 91.6 acres of soil disturbance for Industrial construction activities. All discharges and runoff goes to ground water. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696   #04010/7072 Pub: March 29, 2023 & April 5, 2023

PUBLIC NOTICE - The April meeting of the Noxious Weed Control Board of Grant County will be held Wednesday, April 12, 2023, at 10:00 a.m. The meeting will be held in-person at the Bureau of Reclamation building, 32 C St NW, Room 304B, Ephrata, WA, and via Webex. Please call (509) 237-4567 ahead of the meeting time for remote attendance instructions. Meeting updates will be posted on our website at www.grantcountyweedboard.org. Signed: Ron Tebow, Chairman; Wes Sieg, Vice-Chairman; Summer Sahli, Director; Chuck Sandmann, Director Publish 4/5/23; 4/10/23 #04011/7130 Pub: April 5, 10, 2023

OFFICIAL NOTICE OF NOMINATION MEETING AND ELECTION OF MEMBERS FOR THE WASHINGTON ALFALFA SEED COMMISSION Pursuant to chapter 15.65 RCW, notice is given that a call-in meeting will be held from 10:00 a.m. – 11:00 a.m. on April 24, 2023 to nominate candidates for producer positions 2 and 6 and handler position 7 on the Washington Alfalfa Seed Commission. During the meeting, nominations may be made by calling (360) 902-1887. Notice of this meeting has been mailed to all affected producers entitled to nominate a candidate. For more information regarding how to submit a nomination by mail or the nomination process/meeting, please contact Megan Finkenbinder at (360) 902-1887 or mfinkenbinder@agr.wa.gov. Dated at Olympia, Washington this 5th day of April 2023. Derek I. Sandison, Director Washington State Department of Agriculture #04013/7159 Pub: April 5, 2023

PUBLIC NOTICE The Solid Waste Advisory Committee Meeting is Wednesday, April 12, 2023, at 1 PM, in the Public Works conference room located at 210 W. Alder, Ritzville, WA 99169. Please Call 509-659-3276 if you are unable to attend. #0414/7187 Pub: April 5, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF BABY BOY DIAZ CASE NO. 22-7-00253-13 DOB: 11/25/2021 MINOR CHILD. NOTICE OF SUM-MONS BY PUBLICATION (TERMINATION) TO: Jessica Diaz, Valentin Diaz and any-one claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 11/10/2022. A Fact-Finding Hearing will be held 04/25/2023 at 9:00 a.m. This hearing will be held via WebEx in Superior Court of Washington, Grant County Juvenile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for instructions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be re-quired to observe social distancing and facial mask guidelines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE HEARING WILL DE-TERMINE IF YOUR PARENTAL RIGHTS TO YOUR CHILD ARE TERMINATED. IF YOU DO NOT AP-PEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE TERMINATING YOUR PARENTAL RIGHTS. To re-quest a copy of the Notice, Summons, and Termination Petition, call DSHS at 509-764-5757. View information about your rights in this proceeding at www.atg.wa.gov/DPY.aspx Dated this 25th day of January 2023. /s Deputy Clerk #04023/7281 Pub: April 5, 12, 19, 2023__

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC MEETING WILL BE HELD April 18, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider an Ordinance relating to the amendment of “Title 15, Fire Protection Districts” and the adoption of “Chapter 15 of the Grant County Code, Fire Protection and Administration”. Full context of the ordinance can be requested by contacting the Commissioner’s Office. Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2495 751 5694), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany E. Lutz  Deputy Clerk of the Board Grant County Commissioners #04028/7313 Pub: April 4, 11, 2023_____

Notice of Public Hearings & Determination of Non-Significance Othello Planning Commission & Othello City Council  Zoning Update 2023 – Landscaping & Fencing Notice is hereby given that the City of Othello will hold public hearings to discuss amending the Landscape Chapter, Othello Municipal Code (OMC) 17.74, and the Fence provisions in OMC 14.36, 17.30.100, & 17.40.090. Proposed changes include requiring less landscaping for remodels and addition, reducing the requirement for street trees, requiring landscaping at project completion for all types of permits including single family, requiring fence permits with a fee through the Building & Planning Department, adding a fee for fencing deviation requests, prohibiting fences within right-of-way, prohibiting residential chain link fences, and requiring a lock box for emergency access for fences at commercial & industrial sites. The hearings will be held: • At the Planning Commission meeting, Monday, April 17 at 6:00 PM • At the City Council meeting, Monday, April 24 at 6:00 PM The public hearings will be held at Othello City Hall, Council Chambers, 500 E. Main St. The hearings will also be accessible by internet and phone. All Council and Commission meetings are open to the public. Arrangements to reasonably accommodate special needs, including accessibility or an interpreter, will be made upon receiving 24-hour advance notice.  Check the website at https://www.othellowa.gov/ for more information and the meeting link, or contact the City of Othello at 509-488-5686 or email at ahenning@othellowa.gov The City has also issued a Determination of Non-Significance (DNS) under the State Environmental Policy Act (SEPA) for this action. This project does not have any probable significant adverse environmental impacts. This decision was made after review of an environmental checklist and other information on file with the City. Written comments on the DNS will be accepted until 5:00 PM on April 14 at City Hall, 500 E. Main Street, Othello. For additional information please contact the City of Othello at 509-488-5686. Anne Henning, Community Development Director #04029/7335 Pub: April 5, 2023

Date: Wednesday, April 12, 2023    Address: 408 Intermodal Way Quincy, WA 98848      Time: 11:00 AM Local Time By virtue of default by We The People Trucking, L.L.C.  ( Individually and collectively “Client”), under a Negotiable Promissory Note and Security Agreement(s), Security Agreement(s) Promissory Note(s), Lease Agreement(s) and related documents dated February 23, 2021, payable to Commercial Credit Group Inc. (“CCG”), which obligation is secured by the property described below (the “Equipment”), CCG will sell at Public Auction, to the highest bidder, AS-IS, WHERE-IS, WITHOUT ANY REPRESENTATIONS OR WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR ANY WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE, all of its right, title and interest to the following Equipment: (1) 2015 Utility Reefer Trailer SN: 1UYVS2535FU280502 Terms: Successful bidder must pay 25% of purchase price at time of sale via cash, certified or acceptable bank check, with the balance payable in good funds on the next business day, unless: 1. The bidder has pre-qualified by presenting CCG with a written non-contingent, lending commitment from a source and in a form acceptable to CCG in its sole discretion, in which case we will entertain bids up to the amount of such written commitment; or 2. The bidder has obtained from CCG written credit approval in advance of the scheduled public sale. CCG reserves the right to bid at the sale. Contact Herb Orengo at (630) 718-4684 for additional information or to arrange an inspection of the Equipment. #04032/7376 Pub: April 5, 6, 2023

PUBLIC NOTICE The Solid Waste Advisory Committee Meeting is Wednesday, April 19, 2023, at 1 PM, in the Public Works conference room located at 210 W. Alder, Ritzville, WA 99169. Please Call 509-659-3276 if you are unable to attend.   #04030/7379 Pub: April 5, 12, 2023

SUPERIOR COURT OF WASHINGTON FOR GRANT COUNTY JUVENILE DIVISION. IN THE WELFARE OF DEVINA VELASQUEZ CAUSE NO. 22-7-00235-13 DOB: 03/18/2015 MINOR CHILD NOTICE OF SUMMONS BY PUBLICATION (GUARDIANSHIP) TO: Duwayne Thomas Roeder and anyone claiming a Parental interest. A Title 13 Guardianship Petition was filed on 09/26/2022. A hearing will be held 04/18/2023 at 9:00 a.m. at Grant County Superior Court, Juvenile Division, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. THE PURPOSE OF THE HEARING IS TO HEAR AND CONSIDER EVIDENCE RELATED TO THE PETITION. IF YOU DO NOT APPEAR AT THE HEARING THE COURT MAY ENTER AN ORDER IN YOUR ABSENCE ESTABLISHING A TITLE 13 RCW GUARDIANSHIP AND APPOINT A GUARDIAN. IF GRANTED, COULD RESULT IN SUBSTANTIAL RESTRICTIONS TO THE RIGHTS OF THE PARENT(S) GUARDIAN(S) OR LEGAL CUSTODIAN (S). To request a copy of the Notice, Summons, and Guardian Petition, call DSHS at 509-764-5757. To view information about your rights in this proceeding go to www.atg.wa.gov/DPY.aspx Dated this 22nd day of February of 2023. /s Deputy Clerk  #03007/5936 Pub: March 1, 8, 15, 2023__

Notice of Application With Optional DNS  Othello Hospital Ambulance Facility  Architects West submitted an application to construct a 6000 SF ambulance facility at the Othello Hospital, 315 N. 14th Ave, Lot 2, Othello Community Hospital Major Plat, Parcel 15290380002. Required permits are environmental review, building permits, right-of-way permit, and driveway variance. The City of Othello has reviewed the proposal for probable adverse environmental impacts and expects to issue a Mitigated Determination of Non-Significance (MDNS). The optional DNS process in WAC 197-11-355 is being used. This may be your only opportunity to comment on the environmental impacts of the proposed project. The notice of application and the complete application may be reviewed at City Hall, 500 E. Main St., Othello, WA, 99344 or by contacting Anne Henning, Community Development Director, at 509-488-5686 or ahenning@othellowa.gov. Written comments will be accepted until 5:00 PM on March 14 at the above address.  03012/6084 Pub: March 8, 2023

PUBLIC NOTICE – Noxious weed consultants of the Noxious Weed Control Board of Grant County will begin inspecting properties on March 20, 2023, in accordance with RCW 17.10.160, for the purposes of general inspection, the taking of specimens of weeds, and the performance of eradication or control work. If there is any landowner who objects to these inspections, please notify the Noxious Weed Control Board of Grant County at (509) 754-2011, Ext 4710, by March 20, 2023. Signed: Ron Tebow, Chairman; Wes Sieg, Vice-Chairman; Summer Sahli, Director; Chuck Sandmann, Director  #03018/6183 Pub: March 8, 2023_______

Notice of Application - Date of Notice: March 08, 2023 - Notice is hereby given that a Short Subdivision application was received by Grant County on February 08, 2023, from Shane Heston (Designated Contact: Ostler Land Surveying, P.O. Box 897 Moses Lake, WA 98837), was found to be technically complete on March 2, 2023. PROJECT: A Short Subdivision of two parcels totaling 162.05 acres to create three (3) lots. Lot 1 contains 2.56 acres with an existing home. Lot 2 contains 1.80 acres and is vacant but has a residential capacity. Lot 3 contains 157.2 acres with 81.9 acres dedicated to Open Space. The proposed residential lots will be served by an individual shared well. The property is in the Resource Land - AG zoning district. All lots will have access off Road E NE. LOCATION: The project is known as the Replat of Barnes Short Plat and the site address is 2017 Road E NE, Ephrata, WA. The subject parcels are Lots 1 & 2, Barnes Short Plat, in the SW ¼ of Section 20, Township 19N, Range 26E; W.M., Grant County, WA. (Parcel # 31-2230-000 and 31-2231-000). ZONING: AG. STUDIES REQUIRED: None. PUBLIC HEARING: None. CONSISTENCY STATEMENT: This proposal is subject to, and shall be consistent with, Grant County Code, International Building Code, and International Fire Code. Copies of application materials (File #P23-0050) are available from Aman Walia, Associate Planner, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509) 754-2011, ext. 2536, awalia@grantcountywa.gov. Front Office hours: 8 am to 5 pm, M-F. Comments must be submitted to Development Services no later than 5 pm on March 23, 2023. Comments should be as specific as possible and may be mailed, emailed, or hand delivered. All persons, agencies, or tribes have the right to comment, receive notice, participate hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above-mentioned proposal and materials.  #03019/6203 Pub: March 8, 2023

IN THE SUPERIOR COURT OF WASHINGTON  FOR KING COUNTY  In Re The Estate of: | | No. 23-4-01551-4  | |  JO ANN BRAUN, | Deceased.  | PROBATE NOTICE TO CREDITORS  | (RCW 11.40.030)    | (NTCRD)  _____________________________| The person named below has been appointed as Personal Representative of this Estate.   Any person having a claim against the decedent must, before the time the claim would be  barred by any otherwise applicable statute of limitations, present the claim in the manner as   provided in RCW 11.40.070 by serving on or mailing to the Personal Representative or the   Personal Representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced.   The claim must be presented within the later of: (1) Thirty days after the Personal  Representative served or mailed the notice to the creditor as provided under RCW  11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim  is not presented within this time frame, the claim is forever barred, except as otherwise   provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the   decedent’s probate and nonprobate assets. Date of First Publication: ____March 8, 2023____ S./Karmen M. Williams  ______________________________ Personal Representative  Print Name: KARMEN M. WILLIAMS  S./Eric Landeen  _______________________________ Attorneys for Personal Representative  Print Name and Bar #:ERIC LANDEEN, #53824  Address for Mailing or Service:   Eric Landeen, Attorney  9395 NE Shore, PO Box 163, Indianola, WA 98342  360-265-3554  Court of probate proceedings and cause number:  King County Superior Court  No. 23-4-01551-4 #03021/6247 Pub:March 8, 15, 22, 2023

Superior Court of Washington, County of Grant In the Guardianship of: | No. 22-4-00234-13 | | Summons by Publication | (SM) Chevelle Ann Nelson | Respondent/s (minors/children) | _____________________________|_________________________________________ Summons To: PATRICIA PIERCE 1. The Petitioners, Katherine Nelson and Timothy Nelson, have started a case asking for guardianship of the above-named children under RCW 11.130.185. If the Minor Guardianship Petition is approved, your parenting rights and the rights of the child’s biological farther could be substantially restricted. As part of the Petition, Katherine and Timothy Nelson are asking for sole decision-making authority over the child’s schooling and health care, and travel. 2. You must appear within 60 days after the date of the first publication of this summons, which is January 9, 2023, and defend against this action, and answer the complaint of the Petitioners, and you must serve a copy of your response on the undersigned attorney for Petitioners. You must also file the original response with the clerk of court. 3. If you do not serve your written response within 60 days after the date of the first publication of this summons, the court may enter an order of default against you and the court may, without further notice to you, enter an order and approve or provide for the relief requested in the petition, which has already been filed in this Court. 4. If you wish to seek the advice of a lawyer in this matter, you should do so promptly so that your written response, if any, may be served on time. 5. This summons is issued pursuant to rule 4 of the Superior Court Civil Rules of the State of Washington Dated: January 4, 2023 WSBA #43877 Signature of Petitioner or Lawyer/WSBA No. Brian Christopher Zuanich Print or Type Name File original of your response with Serve a copy of your response on: the clerk of the court at: Petitioner’s Lawyer Brian Christopher Zuanich Zuanich Law PLLC 1420 5th Avenue, Suite 2200 Seattle, WA 98101 Grant County Superior Court Name of Court 35 C Street, NW #2 Ephrata, WA 98823 #02001/4314 Pub: January 9, 16, 23, 30, 2023 & February 6, 13, 2023

NOTICE IS HEREBY GIVEN THAT AN OPEN RECORD PUBLIC HEARING WILL BE HELD February 21, 2023, at  3:15 p.m. in the Grant County Commissioners Hearing Room, Courthouse, Ephrata, WA to consider the following budget extension requests: • Superior Court/Drug Court Fund 102.144 – Dedicated Drug Court Fund: $4,500.00 • Superior Court/Drug Court Fund 127.169 – Law & Justice Funds: $7,000.00 • Sheriff’s Office Fund 142.001 – Vessel Registration: 6,000.00 Any interested persons may appear regarding these matters. Grant County is also providing access to this scheduled hearing via WebEx audio. To participate in the hearing please call in to the hearing at 1 (408) 418-9388 and enter the access code (2486 877 8262), you will be joined to the meeting in a ‘muted’ status until such time as the hearing allows for public testimony. If you have any questions about this procedure, please call the Commissioner’s Office in advance of the hearing. Brittany Lutz, CMC  Deputy Clerk of the Board Grant County Commissioners #02011/4882 Pub: February 6, 13, 2023_

NOTICE IS HEREBY GIVEN in accordance with RCW 47.48.020 that the ROAD-W SE Canal Bridge crossing shall be closed for canal widening work from 2.20.2023 to 3.31.2023. Thereafter, a temporary single lane bridge shall provide local access for vehicles less than 31 Tons and 12’3” wide, through the end of the irrigation water season, from 4.01.2023 to 10.17.2023. Thereafter, the bridge shall be closed for bridge widening work from 10.18.2023 to 01.21.2024, with a planned reopening on or before 1.22.2024. The work will widen the existing bridge by 30’. This requires the construction of a 3rd pier, new abutment on the widened side, and a 4th span of wood beams. This notice is given in accordance with Resolution 23-006 Adopting a Six Year Transportation Improvement plan for 2023-2028, which includes this bridge work. There will be an on-site bridge widening workshop provided by Grant County Public Works Staff at 1PM on 2.15.2023. More information regarding this project and detour planning can be found on the Grant County Public Works website. #02045//5473 Pub# February 13, 14, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON 12 IN AND FOR THE COUNTY OF ADAMS  In the Matter of the Estate of: ) NO: 23-4-00024-01 15  )  Jerry R. Rockey, ) PROBATE NOTICE TO   Deceased. ) CREDITORS   ____________________________ ) RCW 11.40.020  The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the Decedent must,  before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving  on or mailing to the personal representative or the personal representative’s attorney at  the address stated below a copy of the claim and filing the original of the claim with the  court in which the probate proceedings were commenced. The claim must be presented  within the later of: (1) Thirty days after the personal representative served or mailed the  notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after  the date of first publication of the notice. If the claim is not presented within this time  frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and  RCW 11.40.060. This bar is effective as to claims against both the Decedent’s probate and nonprobate assets.  DATE OF FIRST PUBLICATION: May 4, 2023  PERSONAL REPRESENTATIVE: JENNIFER LYNN LIOCE ATTORNEY FOR THE   PERSONAL REPRESENTATIVE: STEVEN H. SACKMANN   ADDRESS FOR MAILING OR Sackmann Law, PLLC 6 SERVICE: PO Box 409   Othello, Washington 99344  #05010/8010 Pub: May 4, 11, 18, 2023

A board seat on the Columbia Basin Conservation District is available for appointment by the Washington State Conservation Commission. Conservation district board supervisors are public officials who serve without compensation and set policy and direction for the conservation district. An applicant must be a registered voter in Washington State and may be required to own land or operate a farm. Applicants for appointed positions do not have to live within the district to apply. For more information, please contact the Columbia Basin Conservation District or read the Guide to Appointment for Conservation District Applicants (https://assets.website-files.com/5ec2d4f7da309c68cdc0655a/5f36cfa9fb8e3e5d59ceaee9_CD-appointment-guide.pdf ) which can be found on the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). To apply, use this direct link (http://www.formstack.com/forms/?1918463-JfwJs6JKCL) or please visit the Conservation Commission website (https://scc.wa.gov/elections-and-appointments). Applications and supporting materials must be received by the Conservation Commission no later than March 31, 2023. #03004/5884 Pub: February 24, 2023 & March 3, 10, 17, 2023.

SUPERIOR COURT OF WASHINGTON FOR LINCOLN COUNTY In the Matter of the Estate ) ) No. 23-4-00017-22      of ) ) PROBATE NOTICE TO WILLA J. EVERS, ) CREDITORS ) RCW 11.40.030           Deceased  ) ) _____________________ ) The Personal Representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent that arose before the decedent’s death must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorneys at the address stated below a copy of the claim and filing the original of the claim with the Clerk of this Court. The claim must be presented within the later of (1) thirty days after the Personal Representative served or mailed the Notice to the Creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of this notice. If the claim is not presented within this time frame, the claim will be forever barred, except as otherwise provided in RCW Section 11 and RCW 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: 03/03/2023 Personal Representative: CHARLES L. EVERS Attorney for P.R.: Norman D. Brock Address for Mailing or Service: Brock Law Firm, P.S. 111 S. Post St., Ste. 2280 Spokane, Washington 99201 /s/Charles L. Evers Charles L. Evers Personal Representative #03014/6146 Pub: March 3, 10, 17, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FRO THE COUNTY OF GRANT In the matter of the Estate of: ) ) NO. 23-4-00021-13 MARCELO PRUNEDA, ) ) PROBATE NOTICE TO CREDITORS Deceased. ) ____________________________ ) The Personal Representative named below has been appointed as Personal Representative of this estate. Any person having a claim against the decedent must, before the time claim would be barred by any other wise applicable statute of limitations, present the claim in the manner as provieded in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s Attorney at the address stated below a copy of the claim and filing the original of the claim with the court. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provieded under RCW 11.40.020(1)(c): or (2) four months after the date of first publication of the noitce. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 abd 11.40.060. This bar is efffective as to claims against both the decedent’s probate and nonprobate assets. Date of First Publication: Date March 10, 2023 Personal Representative: Elida Martinez Street P.O.Box 14 City, State, Zip Warden, WA 98857 #03022/6317 Pub: March 10, 17, 24, 2022

NOTICE OF PUBLIC AUCTION Date: Friday, March 24, 2023 Address: 408 Intermodal Way Quincy, WA 98848    Time: 11:30 AM Local Time By virtue of default by LDH Xpress Inc  ( Individually and collectively “Client”), under a Negotiable Promissory Note and Security Agreement(s), Security Agreement(s) Promissory Note(s), Lease Agreement(s) and related documents dated May 3, 2022, payable to Commercial Credit Group Inc. (“CCG”), which obligation is secured by the property described below (the “Equipment”), CCG will sell at Public Auction, to the highest bidder, AS-IS, WHERE-IS, WITHOUT ANY REPRESENTATIONS OR WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OF MERCHANTABILITY OR ANY WARRANTY OF FITNESS FOR A PARTICULAR PURPOSE, all of its right, title and interest to the following Equipment: (1) 2023 Utility VS2RA Reefer Trailer SN 1UYVS2532P2662810 Terms: Successful bidder must pay 25% of purchase price at time of sale via cash, certified or acceptable bank check, with the balance payable in good funds on the next business day, unless: 1. The bidder has pre-qualified by presenting CCG with a written non-contingent, lending commitment from a source and in a form acceptable to CCG in its sole discretion, in which case we will entertain bids up to the amount of such written commitment; or 2. The bidder has obtained from CCG written credit approval in advance of the scheduled public sale. CCG reserves the right to bid at the sale. Contact Herb Orengo at (630) 718-4684 for additional information or to arrange an inspection of the Equipment. #03041/6680 Pub: March 17, 20, 2023

IN THE SUPERIOR COURT OF WASHINGTON FOR SNOHOMISH COUNTY IN THE MATTER OF ESTATE ) NO. 23 4 00464 31 ) ) PROBATE NOTICE ) TO CREDITORS SHANE ANTHONY ARNOLD, ) ) Deceased, ) RCW. 11.40.030 ____________________________________) The personal representative named below has been appointed as personal representative of the estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1) (C); or (2) four months after the date of first publication of this notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and no-probate assets. Date of First Publication: March 17, 2023___ Personal Representative: /s/ Derek Arnold___ Derek Arnold Attorney for Personal Representative: /s/ Terry Simon____ Terry H. Simon, WSBA #15409 Address for Mailing or Service: 113. N Lewis Street Monroe, WA 98272 (360) 794-7101 #03042/6681 Pub: March 17, 24. 31, 2023

Quincy Valley Medical Center – REPLACEMENT HOSPITAL NOTICE OF INFORMATIONAL MEETING       Graham Construction (GCCM) will be conducting a virtual and in-person informational meeting on March 21, 2023, at 9:00 am PDT for the following bid packages: 1. Electrical and Low Voltage 2. Mechanical and Plumbing For the replacement hospital on the Quincy Valley Medical Center campus in Quincy, WA. Please contact Tony Zuniga Sanchez tonyzunigasanchez@grahamus.com for access to the virtual link or attend in person at the Annex building at 908 Tenth Ave SW, Quincy, WA. Anticipated Schedule: Initial advertisement:              March 21, 2023 MEP Procurement Period:          Late March - April 2023 Construction Start:                September 2023 Phase 1 Complete:               December 2024 Phase 2 Complete:                May 2025 Meeting attendance is not mandatory to participate in the procurement process. QMVC and Graham Construction are Equal Opportunity Employers and encourage bids from all interested firms including disadvantaged, women, minority, disabled veterans, and small emerging business enterprises #03043/6688 Pub: March 17, 2023

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON 12 IN AND FOR THE COUNTY OF ADAMS  In the Matter of the Estate of: ) NO: 23-4-00024-01 15  )  Jerry R. Rockey, ) PROBATE NOTICE TO   Deceased. ) CREDITORS   ____________________________ ) RCW 11.40.020  The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the Decedent must,  before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving  on or mailing to the personal representative or the personal representative’s attorney at  the address stated below a copy of the claim and filing the original of the claim with the  court in which the probate proceedings were commenced. The claim must be presented  within the later of: (1) Thirty days after the personal representative served or mailed the  notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after  the date of first publication of the notice. If the claim is not presented within this time  frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and  RCW 11.40.060. This bar is effective as to claims against both the Decedent’s probate and nonprobate assets.  DATE OF FIRST PUBLICATION: May 4, 2023  PERSONAL REPRESENTATIVE: JENNIFER LYNN LIOCE ATTORNEY FOR THE   PERSONAL REPRESENTATIVE: STEVEN H. SACKMANN   ADDRESS FOR MAILING OR Sackmann Law, PLLC 6 SERVICE: PO Box 409   Othello, Washington 99344  #05010/8010 Pub: May 4, 11, 18, 2023

Horizon Tower, LLC is proposing to construct a 154-foot overall height monopole telecommunications structure located near 17449 W Hwy 26, Royal City, Grant County, Washington (N46° 53’ 56.7”, W119° 51’ 44.6”). Horizon Tower, LLC invites comments from any interested party on the impact the proposed undertaking may have on any districts, sites, buildings, structures, or objects significant in American history, archaeology, engineering, or culture that are listed or determined eligible for listing in the National Register of Historic Places. Comments may be sent to Environmental Corporation of America, ATTN: Annamarie Howell, 1375 Union Hill Industrial Court, Suite A, Alpharetta, GA 30004 or via email to publicnotice@eca-usa.com. Ms. Howell can be reached at (770) 667-2040 x 405 during normal business hours. Comments must be received within 30 days of the date of this notice. 23-001565 DMG #05036/8920 Pub: May 18, 2023

Fisher Construction Group, Inc., Chris Lang, 625 Fisher Ln Burlington, WA 98233-3431, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit. The proposed project, Simplot Moses Rainier HBF 23F012, is located at Northeast of Rd. O and Rd. 2 NE Intersection Parcel #180217000 & 180218000 in Moses Lake in Grant county. This project involves 91.6 acres of soil disturbance for Industrial construction activities. The receiving waterbody is Existing Wetland. Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320. Comments can be submitted to: ecyrewqianoi@ecy.wa.gov, or ATTN: Water Quality Program, Construction Stormwater Washington State Department of Ecology P.O. Box 47696 Olympia, WA 98504-7696 #05040/8969 Pub: May 18, 25, 2023

SUPERIOR COURT OF WASHINGTON COUNTY OF BENTON In re the Matter of the Estate of ) ) No. 23-4-00272-03 CHARLES R. CONDREAY, ) ) AMENDED     Deceased. ) PROBATE NOTICE TO CREDITORS ) ) ____________________________ ) The personal representative named below has been appointed as personal representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the Court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and RCW 11.40.060. This bar is effective as to claims against both the decedent’s probate and non-probate assets. Date of first publication: May 10, 2023 Personal Representative: Deborah Condreay-Garber Attorney for the Personal Representative: Ronald F. St. Hilaire Liebler & St. Hilaire, P.S. Address for Mailing or Service: 602 N. Colorado St., Suite 124 P.O. Box 6125 Kennewick, WA 99336-0125 DATED this 4 day of May, 2023. LIEBLER & ST. HILAIRE, P.S. By /s/ Ronald F. St Hilaire   Ronald F. St. Hilaire, WSBA #31713   Attorneys for Personal Representative #05029/8629 Pub: May 10, 17, 24, 2023

SUPERIOR COURT OF WASHING-TON FOR GRANT COUNTY JUVE-NILE DIVISION. IN THE WEL-FARE OF MAX LEE WALKER CASE NO. 23-7-00137-13 DOB: 04/27/2017 MINOR CHILD. NOTICE OF SUMMONS BY PUBLICATION (TERMINATION) TO: Brianna L. Christensen and anyone claiming a paternal interest. A petition to TERMINATE YOUR PARENTAL RIGHTS was filed on 04/07/2023. A Fact-Finding Hearing will be held 06/20/2023 at 9:00 a.m. This hearing will be held via WebEx in Superior Court of Washington, Grant County Juvenile Courtroom. To access telephonically call 1-408-418-9388. Access Code 146 201 1473. To access via computer please refer to the grant county website for instructions on downloading the WebEx program. Meeting Password UPkJH9sGX42. Any questions regarding access please contact the juvenile dept 509-754-5690. If you wish to appear in person, you will be re-quired to observe social distancing and facial mask guidelines. The hearing will be held at Grant County Juvenile Court, 303 Abel Road, Ephrata, WA, 98823. YOU SHOULD BE PRESENT AT THIS HEARING. YOU ARE NOT REPRE-SENTED BY A LAWYER IN THIS TERMOINATION PROCEEDING EVEN IF YOU WERE APPOINTED A LAWYER IN THE PRIOR DEPEND-ENCY CASE. YOU MUST REAPPLY FOR APPOINTMENT OF A LAWYER IN THIS CASE. IF YOU OR A LAW-YER ON YOUR BEHALF DOES NOT APPEAR IN THIS CASE, YOU WILL BE DEFAULTED AND TERMINA-TION OF YOUR PARENTAL RIGHTS GRANTED. To request a copy of the Notice, Summons, and Termination Peti-tion, call DSHS at 509-764-5757. View information about your rights in this pro-ceeding at www.atg.wa.gov/DPY.aspx Dated this 9th day of May 2023. /s Deputy Clerk #05037/8923 Pub: May 17, 24, 31, 2023

Notice of Application - Date of Notice: May 17, 2023 - Notice is hereby given that a Discretionary Use Application and SEPA checklist were received by Grant County Development Services on April 21, 2023, from New Cingular Wireless, (Designated Contact: Nancy Sears, 1997 Annapolis Exchange Pkwy Suite 200, Annapolis, MD 21401) and were found to be Technically Complete on May 11, 2023. Grant County expects to issue a Determination of Non-Significance for this proposal, and the Optional DNS Process in WAC 197-11-355 is being used. This proposal may include mitigation measures under applicable codes, and the project review process may incorporate or require mitigation measures regardless of whether an EIS is prepared. This may be the only opportunity to comment on the environmental impacts of the proposal and the proposed mitigation measures. A copy of the subsequent threshold determination may be obtained upon request. PROJECT: A Discretionary Use Application and SEPA Checklist to build a Wireless Communication Facility (WCF) on an approximately 72-acres parcel. The WCF will include a 149-ft. tall (overall height) monopole-type tower, associated antennas, and ground-level support equipment within a 50-ft. x 50-ft. fenced compound. STUDIES REQUIRED NONE. LOCATION: The subject parcel is north of Road 12 SW, approximately 5 miles east of the city limits of Royal City. The parcel is Lot 1 Randy Niessner Farm Unit 18 SP 19-93, W.M., Grant County. Parcel # 31-29-54-000. ZONING: Agriculture. PUBLIC HEARING: NONE CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with the Grant County Code, International Building Code, and International Fire Code. Copies of application materials (Files #P23-0125 and #P23-0126) are available from Aman Walia, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509)754-2011, ext. 2536, awalia@grantcountywa.gov. Front Office hours: 8 am –5 pm, M-F. Comments must be submitted to Development Services no later than 5 pm on June 1, 2023. Comments should be as specific as possible and may be mailed, e-mailed, or hand-delivered. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above-listed materials.  #05038/8939 Pub: May 17, 2023

NOTICE OF CALL FOR BID FOR A 3000 GALLON WATER TANK       Notice is hereby given that Adams County Fire Protection District No. 5 will open bids at the office of said District located at 220 South Broadway, Othello, Washington, 99344, for the manufacturing and installation of one 3000 gallon steel water tank. To include all equipment and specifications listed. Specifications are on file in the office of the Adams County Fire Protection District No. 5. Bids shall be attached to the specifications so as to become part of any bid submitted. The District reserves the right to reject any or all bids and to waive any minor formalities. Bids shall be sealed and plainly marked “Bid on 3000 Gallon Tank” and delivered to the office of said District or to the Secretary of said District on or before the hour of 5:00 p.m. on June 12th , 2023.   DATED May 12th , 2023. #05039/8949 Pub: May 17, 24, 2023