Friday, March 29, 2024
45.0°F

Legals for May, 31 2022

| May 31, 2022 12:00 AM

EPHRATA SCHOOL DISTRICT: Ephrata High School Vo-Ag Roof Replacement, Ephrata, WA INVITATION TO BID EPHRATA SCHOOL DISTRICT No. 16 DESIGN WEST ARCHITECTS 111 4 th Avenue N 905 West Riverside Avenue, Suite 605 Ephrata, WA 98823 Spokane, WA 99201 You are invited to bid on a General Contract for construction in the City of Ephrata for the construction of the Ephrata High School Vo-Ag Roof Replacement, Ephrata, WA. The project consists of a replacement of the existing roof of approximately 280 SF. The work includes Structure and Overhead Coiling Doors. Preliminary Base Bid Cost Range: $50,000 Proposals will be accepted by the District until 3:00pm (Base Bid), prevailing time, on Tuesday, May 31, 2022 at the Ephrata High School at 333 4 th Ave NW, Ephrata, WA 98823. Base Bid proposals will be opened publicly and read aloud at 3:00pm. Interested parties are invited to attend. A Pre-Bid Conference, optional for all General Contractor prospective bidders, will be held Tuesday, May 24, 2022, at 1:30pm it will begin at Ephrata High School, 333 4 th Ave NW, Ephrata, WA 98823. Plans and Specifications are available, beginning May 16, 2022, through the Architect. E-mailed PDF drawings and specifications are available at no cost. Printed paper sets are available at $100 per set (limit 2 sets to General Contractors and 1 set for subcontractors). The cost is refundable provided the documents are returned in good condition within 10 days after bid opening to the office of the architect. Additional sets may be purchased at cost, non-refundable. Contact Michell Kaminski, Office Administrator with Design West Architects by e-mail at mkaminski@designwestpnw.com to request documents. Bid security amounting to five percent (5%) of the total Base Bid must accompany each Bidder's proposal in accordance with Instructions to Bidders. Bid documents will be available for examination during the bidding period at the following locations: Abadan Regional Plan Center -Spokane, WA Associated Builders & Contractors, Inc.- Spokane, WA Builders Exchange of Washington - Everett, WA Daily Journal of Commerce Plan Center -Seattle, WA Hermiston Plan Center -Hermiston, OR Spokane Regional Plan Center -Spokane, WA Tri-City Construction Council - Kennewick, WA Walla Walla Valley Plan Center - Walla Walla, WA Wenatchee Plan & Copy Center - Wenatchee, WA Yakima Plan Center - Yakima, WA No bidder may withdraw his proposal after the date and time set for opening thereof or before Award of Contract, unless said award is delayed beyond 30 days. Substantial Completion shall be achieved in compliance with Section 01 10 00 of the project specifications. The project requires compliance with prevailing wage under RCW 39.12. The District reserves the right to accept or reject any or all proposals, and in particular, to reject a proposal not accompanied by the required bid security or data required. The process shall comply with WAC 180-29-105, RCW 28A.335.190 and RCW 43.19.1906. #05039/534803 Pub;May 23, 31, 2022

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF GRANT BANK UNITED N.A., | No. 21-2-00818-13 | Plaintiff, | CIVIL SUMMONS | vs. | . | UNKNOWN HEIRS AND DEVISEES OF | DENNIS C. JOHNSON, DECEASED; | PATRICIA DIETZMAN, FORMER | PERSONAL REPRESENTATIVE FOR | THE ESTATE OF DENNIS CHARLES | JOHNSON; UNKNOWN SUCCESSOR | PERSONAL REPRESENTATIVE FOR | THE ESTATE OF DENNIS CHARLES | JOHNSON; AQUA FINANCE, INC.; | DESERT AIRE OWNERS | ASSOCIATION; JOHN AND/OR JANE | DOE, UNKNOWN OCCUPANTS/CO- | HABITANTS OF THE SUBJECT | PREMISES | | Defendants. | ____________________________________| TO THE DEFENDANTS: Unknown Heirs and Devisees of Dennis C. Johnson, deceased and Unknown Successor Personal Representative for the Esate of Dennis Charles Johnson NOTICE TO DEFENDANT: READ THESE PAPERS CAREFULLY! A lawsuit has been started against you in the above-entitled Court by BANK UNITED N.A., Plaintiff. Plaintif's claim is stated in the written Complaint, a copy of which is on file at the Grant County Courthouse. You must "appear"in this case or the other side will win automatically. To "appear" you must file with the court a legal paper called a "motion" or "answer." The "motion" or "answer" must be given to the court clerk or administrator within 30 days along with the required filing fee. It must be in proper form and have proof of service on the plaintiff's attorney or, if the plaintiff does not have an attorney, proof of service on the plaintiff. The object of the complaint is to foreclose a deed of trust dated September 26, 2017 and recorded as Instrument No. 1384767 given by Dennis C. Johnson, a single man on property commonly known as 503 Desert Aire Drive SW, Mattawa, WA 99349 and legally described as: LOT 14, DESERT AIRE NO. 8, PHASE II, ACCORDING TO THE PLAT THEREOF RECORDED IN VOLUME 13 OF PLATS, PAGES 71, 72 AND 73, RECORDS OF GRANT COUNTY, WASHINGTON. The complaint seeks to foreclose and terminate all interest of Unknown Heirs and Devisees of Dennis C. Johnson, deceased and Unknown Successor Personal Representative for the Estate of Dennis Charles Johnson and all other interests in the property. The "motion" or "answer" (or "reply") must be given to the court clerk or administrator within 30 days of the date of first publication specified herein along with the required filing fee. The date of first publication of the summons is May 10, 2022. If you are in the active military service of the United States, or believe that you may be entitled to protection of the SCRA, please contact our office. If you do not contact us, we will report to the court that we do not believe that you are protected under the SCRA. If you have questions, you should see an attorney immediately. If you need help in finding an attorney, you may contact the Washington State Bar's Lawyer Referral Service online at www.wsba.org or by calling (206) 443-9722 (in the Portland metropolitan area) or toll- free elsewhere in Washington at (800) 945-9722. Attorneys for Plaintiff JANEWAY LAW FIRM, LLC By: /s/James A. Craft_ James A Craft WSBA#47763 [jcraft@janewaylaw.com] 1499 SE Tech Center Place, Suite 255, Vancouver, WA 98683 (360) 260-2253; Fax (360) 260-2285 #06001/532157 Pub;May 10, 17, 24, 31, 2022 & June 7, 14, 2022

Othello School District No. 147 Request for Fuel Bid The Othello School District is accepting bids for Fuel (diesel & unleaded) for the 2022- 23 school year. Bids will be accepted until 10:00 a.m., Monday, June 20, 2022. Submit sealed bids to Othello School District, Attn: Sheree Cantu, 1025 S. 1st Avenue, Othello, WA 99344. Bids are to be in a sealed envelope clearly marked "Fuel Sealed Bid". For Specifications, please contact Marian Shade at the Transportation office at (509) 488-3741, Ext. 1101, MShade@othelloschools.org. _________________________ Pete Perez, Superintendent #06012/536815 Pub;May 31, 2022 & June 2, 7, 9, 2022