Legals for February, 9 2021

ADVERTISEMENT FOR BID Grant County Fire District No. 5 Multi-Agency Admin Building Sealed bids will be received by Grant County Fire District No. 5 at 11058 Nelson Road N.E., Moses Lake, WA 98837, for the construction of the Grant County Fire District No. 5 Multi-Agency Admin Building. Please wear masks when delivering bids. Only deliver bids Monday through Friday between 8:00 am and 5:00 pm. Sealed base bids must be received by 3:00 p.m. local time on February 24, 2021 and must be marked "Sealed Bid - Grant County Fire District No. 5 Multi-Agency Admin Building". Bids received after this time will not be considered. Sealed bids will be opened and publicly read at 3:30 p.m. local time on February 24, 2021 via MSN Teams. The link will be posted at: www.architectswestplans.com. Project documents are available at www.architectswestplans.com. Bidders may download digital files at no cost; Hardcopy sets are available with a refundable deposit of $300.00 per set plus a non-refundable fee of $30.00 per set for handling to be submitted by separate checks. General Contractor may obtain two (2) sets of documents; Mech/Elec/First Tier subcontractors may obtain one (1) set of documents via checks payable to Architects West and mailed to Abadan Reprographics, 603 E. 2nd Ave., Spokane, WA 99202. Deposits will be returned on receipt of documents for a period of ten days after bid opening, provided they are complete and in clean, usable condition. Additional or partial sets may be purchased. Bidders are encouraged to register as a plan holder at www.architectswestplans.com, and select "Add me as a Plan Holder". Questions regarding the plan room contact Auron (509) 747-2964 or repro@abadanspokane.com. A complete set of contract documents will also be filed with the Plan Centers listed at www.architectswestplans.com. A non-mandatory Pre-Bid Conference is scheduled for 3:00 p.m. local time on February 11, 2021 via MSN Teams. The link will be posted at: www.architectswestplans.com. It is highly encouraged to attend. No bidder may withdraw their bid after hour set for opening thereof, unless award is delayed for a period exceeding 60 days. Grant County Fire District No. 5 reserves the right to reject any or all bids and to waive informalities or irregularities in any bid. GRANT COUNTY FIRE DISTRICT NO. 5 Dan Smith, Fire Chief #02015/434708 Pub: February 2, 9, 2021

Notice of Application - Date of Notice: February 9, 2021 Notice is hereby given that a Preliminary Short Subdivision application was received by Grant County on January 19, 2021 from Janett & Associates LLC (Designated Contact: Prairie Land Surveying, 5134 Road E.7 NE, Moses Lake, WA 98837), and was found to be technically complete on January 28, 2021. PROJECT: Janett & Associates Short Plat. Subdivision of the current parcel totaling 91.15 acres into two (2) proposed lots. Lot one (1) will be 6.29 acres with residential capacity, lot two (2) will be 84.86 acres with residential capacity. LOCATION: NKA, Royal City WA 99357. Parcel 21-0778-000. In the Northwest quarter of Section 1, Township 16 North, Range 25 East W.M., Grant County, WA. ZONING: Urban Residential 3 (UR3) CONSISTENCY STATEMENT: This proposal is subject to and shall be consistent with Grant County Code, International Building Code, and International Fire Code. Copies of application materials P 21-0026 are available from Mike Manning, Grant County Development Services, 264 West Division Avenue, PO Box 37, Ephrata, WA 98823, (509) 754-2011, ext. 2522. Office hours: 8 am-5 pm, M-F. Comments must be submitted to the Planning Department no later than 5 pm on February 23, 2021. Comments should be as specific as possible and may be mailed, hand-delivered, or sent by facsimile. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials.WA 98823, (509) 754-2011, ext. 2522. Office hours: 8 am-5 pm, M-F. Comments must be submitted to the Planning Department no later than 5 pm on February 19, 2021. Comments should be as specific as possible and may be mailed, hand-delivered, or sent by facsimile. All persons, agencies, or tribes have the right to comment, receive notice, participate in any hearings, request a copy of the final decision, and/or appeal the decision as provided by law and County Code. This may be the only opportunity to comment on the above listed materials. #02030/436610 Pub: February 9, 2021

IN THE SUPERIOR COURT FOR THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF GRANT GLORIA ANN ARMSTRONG, | Cause No.: 19-2-01732-13 | Plaintiff, | SUMMONS BY PUBLICTION | v. | | SELECT RENTALS AT CRESCENT BAR, | LLC, a Washington limited liability | company; and MARK and JANE DOE | MAGNUSSEN, husband and wife and the | marital community comprised thereof; | FRITZ NICHOLS, INC., dba | WINDERMERE REAL ESTATE/FN, a | Washington profit corporation; and CARL | and JILL NICHOLSON, husband and wife | and in their capacity as Real Estate Brokers; | and CRESCENT BAR CONDOMINIUM | MASTER ASSOCIATION, a mutual | corporation; and UNKNOWN BUSINESS | ENTITY 1-5; and JOHN DOE 1-5. | | Defendants. | ____________________________________| The State of Washington to the said Defendants, MARK and JANE DOE MAGNUSSEN, husband and wife: You are hereby summoned to appear within sixty days after the date of the first publication of this summons, to wit, within sixty days after the 26th day of January, 2021, and defend the above entitled action in the above entitled court, and answer the complaint of the Plaintiff, GLORIA ANN ARMSTRONG, and serve a copy of your answer upon the undersigned attorneys for plaintiff, at their office below stated; and in case of your failure to do so, judgment will be rendered against you according to the demand of the complaint, which has been filed with the clerk of said court. The object of this action being for money damages related to personal injuries sustained in a fall on a set of stairs at a vacation rental condominium caused by Defendants, MARK and JANE DOE MAGNUSSEN'S negligence. DATED this 21st day of January, 2021. INJURY LAW GROUP NW /s/ A. Troy Hunter ___________________________________ A. Troy Hunter, WSBA No. 29243 Ryan C. Sobotka, WSBA No. 51217 Of Attorneys for Plaintiff #03001/432852 Pub: Janury 26, 2021 & February 2, 9, 16, 23, 2021 & March 2, 2021