ADVERTISEMENT FOR BIDS
ROAD DISTRICT NO. 2 SHOP FACILITY
GRANT COUNTY PUBLIC WORKS DEPARTMENT
MOSES LAKE, WASHINGTON
Notice is hereby given that sealed bids, plainly marked "BID FOR ROAD DISTRICT NO. 2 SHOP, MOSES LAKE" will be received by the Board of County Commissioners of Grant County, at the Commissioners' Office, Grant County Courthouse, Ephrata, Washington 98823 until 1:30 p.m. local time on Tuesday, the 6th day of May, 2008, and then publicly opened and read. Contract Documents may be examined at the following locations:
Grant County Public Works Department, Ephrata, Washington
Wenatchee Plan & Copy Center, Wenatchee, Washington
Tri-City Construction Council, Kennewick, Washington
Yakima Plan Center, Yakima, Washington
Spokane Regional Plan Center, Spokane, Washington
Associated Builders and Contractors, Spokane, Washington
AGC, Spokane, Washington
Construction Data, Seattle, Washington
Copies of the Contract Documents may be obtained by Prime Bidders and by bona fide Mechanical and Electrical Contracts from the office of Zeck Butler Architects, P.S., 421 West Riverside Ave., Suite 860, Spokane, Washington 99201-0433, (509) 456-8236, upon deposit of $200.00 for each set. A maximum of two sets will be issued to each Prime Bidder and one set will be issued to each Mechanical and/or Electrical Contractor. Any such plan holder, upon returning the Contract Documents promptly and in unmarked and unadulterated condition will be refunded the deposit.
Contract Documents may be purchased by anyone from Zeck Butler Architects, P.S. Purchasers of Contract Documents shall be responsible for verifying completeness of sets purchased and if any Addenda are issued. Purchases will not be refunded, nor will the purchaser be obligated to return the Documents.
Each proposal must be submitted on the prescribed forms and accompanied by a cashier's check, certified check or bid bond executed on the prescribed form, payable to Grant County in an amount not less than five (5%) percent of the amount of bid. No bidder may withdraw his bid after the hour set for opening thereof, unless contract award is delayed for a period exceeding 60 days.
A Pre-bid Conference will be held at the existing facility on site, 12171 Rd. 3 - NE (Wheeler Road), Moses Lake, Washington at 1:30 to 3:30 p.m. local time on Thursday, the 24th day of April, 2008. This conference is not mandatory, but is strongly recommended for all interested bidders.
The Grant County Board of Commissioners reserves the right to accept or reject any or all bids or to waive any informalities therein.
#04046
Pub.: April 11, 18, 25, 2008
Adams County Development Council
P.O. Box 504, Ritzville, WA 99169
REQUEST FOR PROPOSALS
Comprehensive Marketing Services and Materials
The Adams County Development Council was formed in August of 2007 for the purpose of promoting economic development in Adams County, Washington.
The non-profit Council seeks a qualified, experienced and professionally accredited practitioner or agency to provide the Council with comprehensive marketing and public relations services and materials including the establishment of the organization's official "branding."
Adams County Development Council
"Working for diverse economic opportunities."
Mission Statement:
"To enhance, retain and attract commercial, industrial and agricultural growth, development and diversity within Adams County and its cities, towns and ports."
Vision:
The Adams County Development Council was formed to create a public-private partnership focused on improving the overall economic health of Adams County while preserving the natural attributes of the region and the history and cultural influences of our communities. The Adams County Development Council will help facilitate careful, well-planned growth throughout the county. Our focus will include working with regional educational institutions and agencies to facilitate workforce development; we will serve as a resource to existing businesses as they explore retention and expansion opportunities; we will actively market Adams County as a viable location for new business; and we will endeavor to provide logistical support to potential new businesses and industry as they consider Adams County as a location for their investment.
Scope of Work:
1. Branding strategic plan/campaign proposal that encompasses statewide and regional marketing efforts as well as proposed annual budgetary requirements to effectively market Adams County.
2. Graphic design of key branding elements (i.e., design of ACDC logos).
3. Web site development and launch.
4. Marketing/trade show materials: including brochures, trade show displays and marketing materials capable of introducing potential clients to the business and industry trends in Adams County and the quality of life featured in each of the county's cities and towns.
5. Print and radio advertising materials, institutional materials to establish the Council's branding efforts and promote the availability of Adams County to housing developers/commercial and industrial corporations/site selectors.
6. Pulse survey of existing business and industry leaders to accentuate the value of doing business in Adams County.
7. High definition digital video of Adams County for distribution and streaming on the Web site.
Submission of proposal requirements:
1. Background statement regarding capabilities and understanding of the work to be done;
2. A summary of the Firm's approach;
3. A statement of commitment to perform the work within the project time period;
4. A proposed schedule of activity and benchmarks identifying a project checklist;
5. Identification of the person or persons who will be responsible for the Plan development, including a list of their recent work done in this area and related experience;
6. A minimum of 4 references from other public agencies or non-profit clients where the firm has performed similar comprehensive services. (include names, e-mail addresses and phone numbers of the individuals to be contacted);
7. A cost summary for the proposed work, including an hourly rate schedule for all persons associated with the project;
8. The location of the office from which the work will be done;
9. The ability to complete all projects and materials, expanding project budget prior to June 30, 2008.
Submittal conditions:
1. The deadline for proposals is close of business day, 5 p.m., May 5, 2008
2. The proposal must be mailed to the attention of:
Stephen McFadden
Adams County Development Council
P.O. Box 504
Ritzville, WA 99169
3. Submit one (1) signed original and five (5) copies of the proposal clearly marked "Adams County Development Council Marketing Plan Proposal."
4. The Adams County Development Council reserves the right to reject any and all proposals, to compare the relative merits of the respective proposals, and to choose that proposal or components of those proposals which, in the opinion of the Council, will best serve the interests of the Council.
5. Each proposal prepared in response to this RFP shall be done at the sole cost and expense of each proposing firm and with the express understanding that no claims against the Council for reimbursement will be accepted.
#04060
Pub.: April 18, 25, 2008
NOTICE: ANNOUNCEMENT OF AVAILABILITY OF DRAFT PERMIT
PERMIT NO.: ST-8107
APPLICANT: D&L Foundry, Inc.
P.O. Box 1319
Moses Lake, WA 98837
FACILITY: D&L Foundry & Supply
12970 RD 3 NE (Wheeler Road)
Moses Lake, WA 98837
D&L Foundry, Inc. has applied for a State Waste Discharge permit in accordance with the provisions of Chapter 90.48 Revised Code of Washington (RCW) and Chapter 173-216 Washington Administrative Code (WAC).
D&L Foundry, Inc. presently owns or operates a gray and ductile foundry which is designed to handle a maximum daily flow of 106,000 gallons per day. The wastewater, following treatment, must meet the requirements of the Washington State Water Pollution Control Act and applicable regulations for a permit to be issued.
Following evaluation of the application and other available information, a draft permit has been developed which would allow the discharge of treated wastewater from D&L Foundry & Supply to the City of Moses Lake's Dunes POTW.
A tentative determination has been made on the effluent limitations and special permit conditions that will prevent and control pollution. A final determination will not be made until all timely comments received in response to this notice have been evaluated.
PUBLIC COMMENT AND INFORMATION
The draft permit and fact sheet may be viewed at the Department of Ecology (Department) website at http://www.ecy.wa.gov/programs/wq/permits/eastern_permits.html. The application, fact sheet, proposed permit, and other related documents are also available at the Department's Eastern Regional Office for inspection and copying between the hours of 8:00 a.m. and 5:00 p.m., weekdays. To obtain a copy or to arrange to view copies please call the permit coordinator at (509) 329-3455, e-mail at stra461@ecy.wa.gov or write to the address below.
Interested persons are invited to submit written comments regarding the proposed permit. All comments must be submitted within 30 days after publication of this notice to be considered for the final determination. Comments should be sent to:
Permit Coordinator
Department of Ecology
4601 N. Monroe Street
Spokane, WA 99205
Any interested party may request a public hearing on the proposed permit within 30 days of the publication date of this notice. The request for a hearing shall state the interest of the party and the reasons why a hearing is necessary. The request should be sent to the above address. The Department will hold a hearing if it determines that there is significant public interest. If a hearing is to be held, public notice will be published at least 30 days in advance of the hearing date. Any party responding to this notice with comments will be mailed a copy of a hearing public notice.
Please bring this public notice to the attention of persons who you know would be interested in this matter. Ecology is an equal opportunity agency. If you need this publication in an alternate format, please contact us at (509) 329-3455 or TTY (for the speech and hearing impaired) at 711 or 1-800-833-6388.
#04071
Pub.: April 25, 2008
NOTICE
Grant County Juvenile Court is accepting bids for adding a security alarm system and video surveillance to the Moses Lake office. The System will consist of an approved U.L. listed commercial grade intrusion alarm system as well as one video surveillance camera system. A mandatory walk-through can be scheduled with Garth Kofoed at 509-754-5690 Ext 29. Bids shall be received no later than April 29. System requirements shall be given at the time of walk-through.
#04072
Pub.: April 25, 2008
LOAN NO. xxxxxxxxxx4199 T.S. NO. 1133799-12 PARCEL NO. 04 0749 000 NOTICE OF TRUSTEE'S SALE I. NOTICE IS HEREBY GIVEN that the undersigned Trustee, Cal-Western Reconveyance Corporation of Washington, will on May 30, 2008, at the hour of 10:00am, At the county courthouse, 35 c street nw in the city of Ephrata, State of Washington, sell at public auction to the highest and best bidder, payable at the time of sale, the following described real property, situated in the County(ies) of Grant, State of Washington to-wit: Lot 12, block 5, johnson's 4th addition to quincy, according to the plat thereof recorded in volume 3 of plats, page 2, records of Grant county, Washington.. Commonly known as: 117 H Street Southeast Quincy Wa 98848 which is subject to that certain Deed of Trust dated October 21, 2003, recorded October 29, 2003, under Auditor's File No. 1137151, Book xx, Page xx, records of Grant County, Washington, from Angela M. Apfel Who Acquired Title As A. Mericia Apfel, An Unmairried Person as Grantor, to as Trustee, to secure an obligation in favor of Bank of America, N.a. as Beneficiary, the beneficial interest in which was assigned by to Bank of America, N.a. II. No action commenced by the Beneficiary of the Deed of Trust is now pending to seek satisfaction of the obligation in any Court by reason of the Borrower's or Grantor's default on the obligation secured by the Deed of Trust. III. The default(s) for which this foreclosure is/are made as follows: Failure to pay when due the following amounts which are now in arrears: $5,738.26 (together with any subsequent payments, late charges, advances, costs and fees thereafter due). IV. The sum owing on the obligation secured by the Deed of Trust is: Principal Balance of $47,771.41, together with interest as provided in the note or other instrument secured from July 06, 2007, and such other costs and fees as are due under the Note or other instrument secured, and as are provided by statute. V. The above-described real property will be sold to satisfy the expense of sale and the obligation secured by the Deed of Trust as provided by statute. The sale will be made without warranty, express or implied regarding title, possession or encumbrances on May 30, 2008. The default(s) referred to in paragraph III, must be cured by May 19, 2008 (11 days before the sale date), to cause a discontinuance of the sale. The sale will be discontinued and terminated if at any time on or before May 19, 2008 (11 days before the sale date), the default(s) as set forth in paragraph III is/are cured and the Trustee's fees and costs are paid. The sale may be terminated any time after May 19, 2008 (11 days before the sale date), and before the sale by the Borrower, Grantor, any Guarantor or the holder of any recorded junior lien or encumbrance paying the entire principal and interest secured by the Deed of Trust, plus costs, fees, and advances, if any, made pursuant to the terms of the obligation and/or Deed of Trust and curing all other defaults. VI. A written notice of default was transmitted by the Beneficiary or Trustee to the Borrower and Grantor at the following addresses: Angela M Apfel, 117 H Street Southeast, Quincy Wa 98848; A Mericia Apfel, 117 H Street Southeast, Quincy Wa 98848; Angela M Apfel, Pl Se Po Box 6053, Bellevue Wa 98008; A Mericia Apfel, Pl Se Po Box 6053, Bellevue Wa 98008; Angela M Apfel, 117 H Street Se, Quincy Wa 98848; A Mericia Apfel, 117 H Street Se, Quincy Wa 98848 by both first class and certified mail on proof of which is in the possession of the Trustee; and on the written notice of default was posted in a conspicuous place on the real property described in the paragraph I above, and the Trustee has possession of proof of such posting. VII. The Trustee whose name and address are set forth below will provide in writing to anyone requesting it, a statement of all costs and fees due at any time prior to the sale. VIII. The effect of the sale will be to deprive the Grantor and all those who hold by, through or under the Grantor of all their interest in the above-described property. IX. Anyone having any objections to the sale on any grounds whatsoever will be afforded an opportunity to be heard as to those objections if they bring a lawsuit to restrain the sale pursuant to RCW 61.24.130. Failure to bring such a lawsuit may result in a waiver of any proper grounds for invalidating the Trustee's sale. X. NOTICE TO OCCUPANTS OR TENANTS The purchaser at the trustee's sale is entitled to possession of the property on the 20th day following the sale, as against the grantor under the Deed of Trust (the owner) and anyone having an interest junior to the Deed of Trust, including occupants and tenants. After the 20th day following the sale the purchaser has the right to evict occupants and tenants by summary proceedings under the unlawful detainer act, Chapter 59.12 RCW. Date February 27, 2008 Cal-Western Reconveyance Corporation of Washington P.O. Box 22004 525 East Main Street El Cajon CA 92022-9004 (800) 546-1531 Signature/By LORRIE WOMACK. R-168547 04/25/08, 05/16/08
#05001
Pub.: April 25, May 16, 2008
Superior Court of Washington
County of GRANT
In re the Marriage of: )
PAMELA K FARRIS ) No. 08-3-00071-1
) Summons by Publication
Petitioner, ) (SMPB)
And )
ROBERT P. BAILEY )
Respondent. )
To the Respondent: ROBERT P. BAILEY
1. The petitioner has started an action in the above court requesting that your marriage be dissolved.
2. The petition also requests that the Court grant the following relief:
Dispose of property and liabilities.
3. You must respond to this summons by serving a copy of your written response on the person signing this summons and by filing the original with the clerk of the court. If you do not serve your written response within 60 days after the date of the first publication of this summons (60 days after the day of February, 2008), the court may enter an order of default against you, and the court may, without further notice to you, enter a decree and approve or provide for other relief requested in this summons. In the case of a dissolution of marriage, the court will not enter the final decree until at least 90 days after service and filing. If you serve a notice of appearance on the undersigned person, you are entitled to notice before an order or default or a decree may be entered.
4. Your written response to the summons and petition must be on form:
WPF DR 01.0300, Reponse to Petition (Domestic Relations).
Information about how to get this form may be obtained by contacting the clerk of the court, by con- tacting the Administrative Office of the Courts at (360) 705-5328, or from the Internet at the Washington State Courts homepage:
http://www.courts.wa.gov/forms
5. If you wish to seek the advice of an attorney in this matter, you should do so promptly so that your writ- ten response, if any, may be served on time.
6. One method of serving a copy of your response on the petitioner is to send it by certified mail with return receipt requested.
7. Other:
This summons is issued pursuant to RCW 4.28.100 and Superior Court Civil Rule 4.1 of the State of Washington.
Dated 2/25/08 s/Steven D. Talbot Steven D. Talbot, WSBA #21355
Lawyer for Petitioner
File Original of Serve a Copy of Your Your Response Response on:
with the Clerk of
Court at:
Clerk of the Court Steven D. Talbot
Grant County Court Steven D. Talbot, P.S.
Law & Justice Center 835 E. Colonial Ave,
P.O. Box 37 Suite 103
Ephrata, WA, 98823 Moses Lake, WA 98837
#05002
April 18, 25, May 2, 9, 16, 23, 2008
Notice of Condemnation Final Action
Pursuant to RCW 8.25.290 and 8.12.005 notice is given that the City of Moses Lake, Washington, City Council will on May 13, 2008, at 7:00 p.m. in the City Council Chambers at 401 S. Balsam Street, Moses Lake, WA 98837, consider final action to approve an ordinance directing the condemnation of the fee title for purposes of completion of the Japanese Peace Garden Park of the following property:
Grant County Assessor's Parcel Number: 11 0095 000.
#05006
Pub.: April 25, May 2, 2008
NOTICE
REQUEST FOR PROFESSIONAL SERVICES PROPOSAL
Firms wishing to be considered for architectural/engineering design and related services for the Moses Lake School District #161 are requested to submit Statements of Qualifications to Steve Chestnut, Superintendent, 920 W. Ivy Ave, Moses Lake, WA 98837, (509) 766-2650.
Project: Construction of a Grant County Skill Center facility.
Budget: Approximately $24,000,000
Schedule: Pre-Design: Summer and Fall 2008
Construction Start: Summer, 2009 (assuming funding by the Washington State Legislature)
Funding: This project will be funded entirely by the Capital Project Budget of the Washington State Legislature.
Requests from interested firms are to be submitted as follows:
1. Submittals should identify:
a. Experience designing new or major modernized projects in the State of Washington.
b. Land planning/landscape architecture capabilities.
c. Experience in Washington State "D" Form process.
2. Limit proposals to 20 pages total, including all sheets.
3. Submittals must be received at the District Office: 920 W. Ivy Ave, Moses Lake, WA 98837
4. Five (5) copies to be received no later than May 16, 2008, at 5:00 p.m.
Sub consultants are to submit proposals with prime consultant applicants rather than submitting them separately.
Questions should be directed to Steve Chestnut, Superintendent, (509)766-2650.
The Moses Lake School District is an equal opportunity employer and encourages all qualified women and minority consulting firms to apply.
#05008
Pub.: April 24, 25, 29, May 1, 2008
STATE OF WASHINGTON
DEPARTMENT OF ECOLOGY
NOTICE OF APPLICATION FOR CHANGE/TRANSFER OF WATER RIGHT UNDER ONE (1) GROUND WATER CLAIM
TAKE NOTICE:
That John d. Pryor of Moses Lake, Washington has made application for change/transfer of water right in order add a point of withdrawal (POW) as claimed under Ground Water Claim No. 200073C together with certificate of change No.'s Vol. I-3, PP. 451 & Vol. II-3, PP 11.
That said claim together with the certificate of changes claims the withdrawal of 850 gallons per minute, 840 acre-feet per year for seasonal irrigation of 140 acres.
That the claimed POW's are from 3 wells located within the NE1/4SW1/4, NE1/4SW1/4SW1/4 and NE1/4SE1/4SW1/4 of Sec. 24, T. 19 N., R. 27 E.W.M.
That the claimed place of use is 140 acres within the SW1/4 of Sec. 24, T. 19 N., R. 27 E.W.M.
That he propose to add one-(1) POW to be located on his property within Lot 4 of the Soil Spray Aid Inc. Short Plat of Sec. 24, T. 19 N., R. 27 E.W.M.
That he proposes to utilitize 60 gallons per minute, 3.5 acre-feet per year for the irrigation of 5 acres on his property located within Lot 4 of the Soil Spray Aid Inc. Short Plat of Sec. 24, T. 19 N., R. 27 E.W.M.
All within Grant County, Washington.
Protests or objections to approval of this application must include a detailed statement of the basis for objections; protests must be accompanied by a fifty-dollar ($50.00) recording fee and filed with the Deparment of Ecology, at the address shown below, within thirty-days (30) from May 2, 2008.
STATE OF WASHINGTON
DEPARTMENT OF ECOLOGY
WATER RESOURCES PROGRAM-ERO
PO BOX 5128
LACEY WA 98509-5128
#05010
Pub.: April 25, May 2, 2008
NOTICE TO BIDDERS
CITY OF MOSES LAKE
DEPARTMENT OF MUNICIPAL SERVICES
EQUIPMENT RENTAL DIVISION
Sealed bids will be received by the City of Moses Lake at the office of the City Clerk at City Hall, 321 South Balsam (P.O. Box 1579), Moses Lake, Washington 98837 until 2:00 p.m., Tuesday, May 13, 2008. Bids will be opened and publicly read at that time for the following item:
BID NO. 519-2008-19 ROTARY TRIM MOWER-REBID
Bid Proposal Package may be obtained or reviewed at the office of Municipal Services, 321 South Balsam Street, Moses Lake, Washington. All bids will be submitted on the prescribed Bid Proposal Package furnished by the Municipal Services Department. The Moses Lake City Council reserves the right to reject any or all bids.
Contact Person: Tim Varney, Public Works Superintendent (509) 766-9224.
Estimated Cost:
Bid No. 519-2008-09 Rotary Trim Mower $34,528
#04076
Pub.: April 25, 2008